Acceptance Use of Premises Clause Samples
Acceptance Use of Premises
Acceptance of Premises Except as expressly provided in this Lease, Tenant acknowledges that neither Landlord nor any representative of Landlord has made any representation or warranty with respect to the Premises, the Building or the Project. No representation or warranty is made concerning the suitability or fitness of the Premises, the Building or the Project for any purpose, including without limitation any representations or warranties regarding the compliance of Tenant’s use of the Premises with the applicable zoning or regarding any other land use matters, and Tenant shall be solely responsible as to such matters. Further, neither Landlord nor any representative of Landlord has made any representations or warranties regarding (i) what other tenants or uses may be permitted or intended in the Building or the Project, (ii) any exclusivity of use by Tenant with respect to its permitted use of the Premises as set forth in Item 3 of the Basic Lease Provisions, or (iii) any construction of portions of the Project not yet completed. Except as expressly provided in this Lease, Tenant’s lease of the Premises shall be on an “as is” basis. Landlord shall, at its sole cost and expense, construct, repair and/or replace the items set forth on Schedule A attached to this Lease (collectively, the “Landlord’s Work”). The Landlord’s Work shall be constructed in a good and workmanlike manner in compliance with all applicable building codes and permits, and in accordance with the scheduled completion dates for each component of the Landlord’s Work set forth on attached Schedule A. Landlord shall obtain any customary manufacturers/installers warranties for the Landlord’s Work. Except as expressly provided in this Lease, Tenant shall be conclusively deemed to have accepted the Premises and those portions of the Building and Project in which Tenant has any rights under this Lease as of the “Early Occupancy Date” (as defined in Section 3.2), which acceptance shall mean that it is conclusively established that the Premises and those portions of the Building and Project in which Tenant has any rights under this Lease were in satisfactory condition and in conformity with the provisions of this Lease, subject only to (1) those defective or incomplete portions of the Landlord’s Work which Tenant shall have itemized on a written punch list and delivered to Landlord within forty-five (45) days following Landlord’s written notice(s) that the Landlord’s Work has been substantially completed (or within forty five (45) days following the date of this Lease for items of Landlord’s Work designated as “complete” on the attached Schedule A), and (2) Landlord’s obligations expressly set forth in Section 2.4 below. Landlord shall correct any deficiencies with the Landlord’s Work promptly following delivery of the itemized punch list therefor as provided in the foregoing. Landlord shall also provide two (2) allowances to Tenant as follows: (a) Sixteen Thousand Seven Hundred Dollars ($16,700.00) (the “Access Control Allowance”) towards the cost to repair and/or replace the access control system in the Premises (the “Access Control Work”); and (b) Three Hundred thousand Dollars ($300,000.00) (the “Floor Surface Allowance”) towards the cost of bead blasting, repairing and otherwise preparing the surface of the Building’s slab as more particularly provided in that certain proposal from ▇▇▇▇▇▇’▇ Rug dated June 1, 2005, a copy of which proposal is attached hereto as Exhibit J (the “Floor Surfacing Work”). Tenant shall obtain those warranties from the manufacturers/installers for the Access Control Work and for the Floor Surfacing Work satisfactory to Tenant in its sole discretion, and Landlord shall have no liability whatsoever for the Access Control Work and/or for the Floor Surfacing Work beyond payment of the applicable allowance therefor. Sums from each of the allowances shall be paid within thirty (30) days of Landlord’s receipt of an invoice(s) with respect to the covered work. Promptly from and after the full execution and delivery of this Lease, Landlord shall deliver possession of the Premises to Tenant (such date of delivery of possession (the “Delivery Date”) for Tenant’s construction of those tenant improvements (the “Tenant Improvements”) in the Premises as provided in, and subject to the terms and conditions of, the Work Letter attached as Exhibit X hereto (the “Work Letter”).
Use of Premises Tenant shall not use the premises or any part thereof, or permit the premises or any part thereof to be used, for any purpose other than the use hereinabove specifically mentioned, subject, however, to all the covenants, agreements, terms, provisions and conditions of this Lease. Those portions, if any, of the premises which on the plan(s) attached hereto are shown as toilets and utility areas shall be used by Tenant only for the purposes for which they are designed. Tenant will not at any time use or occupy the premises or any part thereof, or permit the premises or any part thereof to be used or occupied, in violation of the certificate of occupancy (temporary or final) issued for the Building and/or the premises. Tenant shall not ▇▇▇ or permit the use of the premises or any part thereof in any way which would violate any of the covenants, agreements, terms, provisions and conditions of this Lease or for any unlawful purposes or in any unlawful manner and Tenant shall not suffer or permit the premises or any part thereof to be used in any manner or anything to be done therein or suffer or permit anything to be brought into or kept in the premises which, in the judgment of Landlord, shall in any way impair or tend to impair the character, reputation or appearance of the Building as a first-class office building, impair or interfere with or tend to impair or interfere with any of the Building services or the proper and economic heating, cleaning, air conditioning or other servicing of the Building or the premises, or impair or interfere with or tend to impair or interfere with the use of any of the other areas of the Building by, or occasion discomfort, inconvenience or annoyance to, any of the other tenants or occupants of the Building. Tenant shall not install any electrical or other equipment of any kind which, in the judgment of Landlord, might cause any such impairment, interference, discomfort, inconvenience or annoyance. Except as set forth in Article 1 hereof, Tenant will not, and will not permit anyone to, sell or traffic in any spirituous liquors, wine, ale or beer in or from the premises or carry on any manufacturing in the premises. If any governmental license or permit shall be required for the proper and lawful conduct of Tenant's business or other activity carried on it the premises, Tenant, at Tenant's expense, shall duly procure and thereafter maintain such license or permit and submit the same to inspection by Landlord. Tenant, at Tenant's expense, shall, at all times, comply with the terms and conditions of each license or permit.
Lease of Premises Landlord hereby leases to Tenant and Tenant hereby leases from Landlord the Premises for the Term and upon the terms and conditions hereinafter set forth.
Expansion of Premises (a) Effective as of the Expansion Date the Premises (and the definition of the “Premises”) shall be modified to mean and include both the Initial Premises and the Expansion Premises. As a result of such expansion, effective upon the Expansion Date, the deemed square footage of the Premises shall be and become 31,684 square feet and Tenant’s Prorata Share and Tenant’s Share of Expenses and Real Estate Taxes shall be one hundred percent (100.00%). (b) If Landlord, for any reason whatsoever, cannot deliver possession of the Expansion Premises to Tenant on before August 1, 2012 for the purpose specified in Section 3(c), this Amendment shall not be void or voidable, Landlord shall not be liable to Tenant for any loss or damage resulting therefrom, and Tenant shall have no obligation to pay monthly Base Rent or Additional Charges with respect to the Expansion Premises until the day following the date on which possession of the Expansion Premises is delivered to Tenant (such date thereupon becoming the “Expansion Date” for purposes of this Amendment). Notwithstanding the foregoing, if Landlord is unable to deliver the Expansion Premises by August 1, 2012 (as extended day-for-day for each day of Force Majeure Delay) (the “Expansion Premises Outside Delivery Date”), then Tenant shall have the right, as its sole remedy, to terminate this Amendment to Lease by providing written notice to Landlord within fifteen (15) business days following the Expansion Premises Outside Delivery Date, in which event the Lease shall continue in full force and effect as if the parties had not entered into this Amendment and Landlord shall promptly return to Tenant the August, 2012 Base Rent for the Expansion Premises paid by Tenant pursuant to the provisions of Section 6(d). For purposes hereof, the failure of the existing tenant of the Expansion Premises to vacate the Expansion Premises shall not be an event of Force Majeure Delay. (c) Notwithstanding the above, Tenant shall be entitled to early occupancy of the Expansion Premises at any time after the Expansion Premises Delivery Date for the sole purposes of (1) installing Tenant’s furniture and telephone and other communications cabling and (2) performing Tenant’s Expansion Work (defined below), provided that (i) Tenant covenants and agrees that Tenant and Tenant’s employees, agents or contractors will cooperate with Landlord to coordinate the performance and completion of the Landlord’s Expansion Work concurrently with Tenant’s Expansion Work, (ii) Landlord shall have no liability to Tenant for delays in completing the Landlord’s Expansion Work which result from, are caused by or arise out of the interference by Tenant or Tenant’s employees, agents or contractors in the performance of the Landlord’s Expansion Work, (iii) Tenant and Tenant’s employees, agents and contractors shall promptly comply with any and all requests made by Landlord or Landlord’s contractor(s) that Tenant remove its property from those areas in or around which Landlord is performing the Landlord’s Expansion Work, and (iv) Landlord shall not be liable for, Tenant hereby waives all claims which Tenant may have against the Landlord Parties, and Tenant shall indemnify and hold harmless Landlord from and defend Landlord against any and all claims or liability for any injury or damage to any person or property in or about the Expansion Premises resulting from or arising out of or in connection with the performance of Tenant’s Expansion Work (except to the extent arising from the negligence or willful misconduct of Landlord). Tenant’s early occupancy of the Expansion Premises for the sole purpose provided in this Section shall be subject to all of the terms and conditions of the Lease, provided that (x) the Premises shall not include the Expansion Premises until the Expansion Date, and (y) Tenant shall not be obligated to pay monthly Base Rent or Additional Charges with respect to the Expansion Premises for the period from the Expansion Premises Delivery Date until the Expansion Date. (d) Within five (5) business days after the Expansion Date, the parties shall execute a letter confirming the Expansion Date and certifying that Tenant has accepted delivery of the Premises, in form substantially similar to EXHIBIT “D” attached to the Lease (the “Expansion Date Memorandum”). Either party’s failure to request execution of, or to execute, the Expansion Date Memorandum shall not in any way alter the Expansion Date.
Demise of Premises Landlord hereby demises and lets to Tenant and Tenant hereby takes and leases from Landlord, for the term and upon the provisions hereinafter specified, the Leased Premises.