Termination and Suspension Customer is entitled to suspend the performance of its obligations in whole or in part or terminate the Agreement with immediate effect, without prejudice to its right to claim damages and without any compensation to or indemnification of Supplier (i) in case Supplier has been declared bankrupt, is in a state of liquidation, has ceased or suspended whole or a substantial part of its business, is subject of a court order or preventative legal scheme of settlement, (ii) in case of non- compliance with the Compliance Requirements or the provisions of safety, health, environment and security or (iii) in case of not approved changes pursuant to article 10. After such termination Customer may return received Goods and/or Services in whole or partly against repayment and retransfer of ownership therein to Supplier.
Termination; Suspension (a) Either Party may terminate this Compact without cause in its entirety by giving the other Party thirty (30) days’ prior written notice. MCC may also terminate this Compact or MCC Funding without cause in part by giving the Government thirty (30) days’ prior written notice. (b) MCC may, immediately, upon written notice to the Government, suspend or terminate this Compact or MCC Funding, in whole or in part, and any obligation related thereto, if MCC determines that any circumstance identified by MCC, as a basis for suspension or termination (as notified to the Government in writing) has occurred, which circumstances include but are not limited to the following: (i) the Government fails to comply with its obligations under this Compact or any other agreement or arrangement entered into by the Government in connection with this Compact or the Program; (ii) an event or series of events has occurred that makes it probable that the Program Objectives or any of the Project Objectives will not be achieved during the Compact Term or that the Government will not be able to perform its obligations under this Compact; (iii) a use of MCC Funding or continued implementation of this Compact or the Program violates applicable law or United States Government policy, whether now or hereafter in effect; (iv) the Government or any other person or entity receiving MCC Funding or using Program Assets is engaged in activities that are contrary to the national security interests of the United States; (v) an act has been committed or an omission or an event has occurred that would render Benin ineligible to receive United States economic assistance under Part I of the Foreign Assistance Act of 1961, as amended (22 U.S.C. 2151 et seq.), by reason of the application of any provision of such act or any other provision of law; (vi) the Government has engaged in a pattern of actions inconsistent with the criteria used to determine the eligibility of Benin for assistance under the MCA Act; and (vii) the Government or another person or entity receiving MCC Funding or using Program Assets is found to have been convicted of a narcotics offense or to have been engaged in drug trafficking.
Certification Regarding Debarment, Suspension, Ineligibility and Voluntary Exclusion First Tier Participants: a. The prospective first tier participant certifies to the best of its knowledge and belief, that it and its principals: (1) Are not presently debarred, suspended, proposed for debarment, declared ineligible, or voluntarily excluded from participating in covered transactions by any Federal department or agency; (2) Have not within a three-year period preceding this proposal been convicted of or had a civil judgment rendered against them for commission of fraud or a criminal offense in connection with obtaining, attempting to obtain, or performing a public (Federal, State or local) transaction or contract under a public transaction; violation of Federal or State antitrust statutes or commission of embezzlement, theft, forgery, bribery, falsification or destruction of records, making false statements, or receiving stolen property; (3) Are not presently indicted for or otherwise criminally or civilly charged by a governmental entity (Federal, State or local) with commission of any of the offenses enumerated in paragraph (a)(2) of this certification; and (4) Have not within a three-year period preceding this application/proposal had one or more public transactions (Federal, State or local) terminated for cause or default. b. Where the prospective participant is unable to certify to any of the statements in this certification, such prospective participant shall attach an explanation to this proposal.
CERTIFICATION REGARDING DEBARMENT AND SUSPENSION The undersigned (authorized official signing for the contracting organization) certifies to the best of his or her knowledge and belief, that the contractor, defined as the primary participant in accordance with 45 CFR Part 76, and its principals: are not presently debarred, suspended, proposed for debarment, declared ineligible, or voluntarily excluded from covered transactions by any Federal Department or agency have not within a 3-year period preceding this contract been convicted of or had a civil judgment rendered against them for commission of fraud or a criminal offense in connection with obtaining, attempting to obtain, or performing a public (Federal, State, or local) transaction or contract under a public transaction; violation of Federal or State antitrust statutes or commission of embezzlement, theft, forgery, bribery, falsification or destruction of records, making false statements, or receiving stolen property; are not presently indicted or otherwise criminally or civilly charged by a governmental entity (Federal, State, or local) with commission of any of the offenses enumerated in Section 2 of this certification; and have not within a 3-year period preceding this contract had one or more public transactions (Federal, State, or local) terminated for cause or default. Should the Contractor or Subrecipient not be able to provide this certification, an explanation as to why should be placed after the assurances page in the contract. The contractor agrees by signing this contract that it will include, without modification, the clause above certification in all lower tier covered transactions (i.e., transactions with sub-grantees and/or contractors) and in all solicitations for lower tier covered transactions in accordance with 45 CFR Part 76.
TERMINATION OR SUSPENSION § 9.1 If the Owner fails to make payments to the Architect in accordance with this Agreement, such failure shall be considered substantial nonperformance and cause for termination or, at the Architect’s option, cause for suspension of performance of services under this Agreement. If the Architect elects to suspend services, the Architect shall give seven days’ written notice to the Owner before suspending services. In the event of a suspension of services, the Architect shall have no liability to the Owner for delay or damage caused the Owner because of such suspension of services. Before resuming services, the Owner shall pay the Architect all sums due prior to suspension and any expenses incurred in the interruption and resumption of the Architect’s services. The Architect’s fees for the remaining services and the time schedules shall be equitably adjusted. § 9.2 If the Owner suspends the Project, the Architect shall be compensated for services performed prior to notice of such suspension. When the Project is resumed, the Architect shall be compensated for expenses incurred in the interruption and resumption of the Architect’s services. The Architect’s fees for the remaining services and the time schedules shall be equitably adjusted. § 9.3 If the Owner suspends the Project for more than 90 cumulative days for reasons other than the fault of the Architect, the Architect may terminate this Agreement by giving not less than seven days’ written notice. § 9.4 Either party may terminate this Agreement upon not less than seven days’ written notice should the other party fail substantially to perform in accordance with the terms of this Agreement through no fault of the party initiating the termination. § 9.5 The Owner may terminate this Agreement upon not less than seven days’ written notice to the Architect for the Owner’s convenience and without cause. § 9.6 If the Owner terminates this Agreement for its convenience pursuant to Section 9.5, or the Architect terminates this Agreement pursuant to Section 9.3, the Owner shall compensate the Architect for services performed prior to termination, Reimbursable Expenses incurred, and costs attributable to termination, including the costs attributable to the Architect’s termination of consultant agreements. § 9.7 In addition to any amounts paid under Section 9.6, if the Owner terminates this Agreement for its convenience pursuant to Section 9.5, or the Architect terminates this Agreement pursuant to Section 9.3, the Owner shall pay to the Architect the following fees: