Additional Reporting and Delivery Requirements on Completion Date Clause Samples

Additional Reporting and Delivery Requirements on Completion Date. On or prior to the Completion Date, the Construction Agent shall deliver to the Agent an Officer’s Certificate in the form attached hereto as EXHIBIT E or in such other form as is satisfactory to the Agent, in its commercially reasonable discretion, specifying (a) the address for the Property, (b) the Completion Date, (c) the Property Cost and (d) that every representation and warranty of each Credit Party contained in the Operative Agreements to which it is a party is true and correct on and as of the Completion Date in all material respects, except for any representation or warranty that is qualified by materiality or references Material Adverse Effect, which such representation or warranty shall be true and correct in all respects (except for any such representation and warranty that by its terms is made only as of an earlier date, which representation and warranty shall remain true and correct in all material respects as of such earlier date, except for any representation and warranty that is qualified by materiality or references Material Adverse Effect, which such representation and warranty shall be true and correct in all respects as of such earlier date). The Agent shall have the right to reasonably contest the information contained in such Officer’s Certificate. Furthermore, on or prior to the Completion Date, the Construction Agent shall deliver or cause to be delivered to the Agent (unless previously delivered to the Agent) originals of the following relating to the Property, each of which shall be in form and substance acceptable to the Agent, in its commercially reasonable discretion: (v) a title insurance endorsement regarding the title insurance policy delivered in connection with the requirements of Section 5.3(g), but only to the extent such endorsement is necessary to provide for insurance in an amount at least equal to the maximum total Property Cost and, if endorsed, the endorsement shall not include a title change or exception that has or could reasonably be expected to have a Material Adverse Effect; (w) an as‑built survey for the Property; (x) insurance certificates respecting the Property as required hereunder and under the Lease; (y) at the Lessor’s prior written request, an Appraisal regarding the Property; and (z) with respect to any Advances not contemplated in the original applicable Construction Budget, including by the Lessor pursuant to Section 5.16, the Lessee shall have caused to be delivered to the Agent an amendment to ...
View SourceView Similar (11)
Additional Reporting and Delivery Requirements on Completion Date. On or prior to the Completion Date, the Construction Agent shall deliver to the Collateral Agent an Officer's Certificate in the form attached hereto as Exhibit D or in such other form as is acceptable to the Collateral Agent specifying (a) the Completion Date, (b) the aggregate Property Cost, (c) detailed, itemized documentation supporting the asserted Property Cost and (d) that all representations and warranties of the Construction Agent and Lessee in each of the Related Documents and each certificate delivered pursuant thereto (including, without limitation, the Incorporated Representations and Warranties) are true and correct in all material respects as of the Completion Date. The Collateral Agent shall have the right to contest the information contained in such Officer's Certificate. Furthermore, on or prior to the Completion Date, the Construction Agent shall deliver or cause to be delivered to the Collateral Agent (unless previously delivered to the Collateral Agent) originals of the following, each of which shall be in form and substance acceptable to the Collateral Agent, in its reasonable discretion: (x) a title insurance endorsement regarding the title insurance policy delivered in connection with the requirements of Section 5.3(g), but only to the extent such endorsement is necessary to provide for insurance in an amount at least equal to the maximum total Property Cost and, if endorsed, the endorsement shall not include a title change or exception objectionable to the Collateral Agent; (y) an as-built survey for the Property, (z) insurance certificates respecting the Property as required hereunder and under the Master Lease.
View Source

Related to Additional Reporting and Delivery Requirements on Completion Date

  • Additional Reporting Requirements Contractor agrees to submit written quarterly reports to H-GAC detailing all transactions during the previous three (3) month period. Reports must include, but are not limited, to the following information: a. Customer Name b. Product/Service purchased, including Product Code if applicable c. Customer Purchase Order Number

  • Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.

  • Service Delivery Requirements The following sections describe in detail the work activity required by this program. All CONTRACTORS will be expected to fulfill the work activity requirements in these areas. A. Staff Requirements & Policies CONTRACTOR shall provide the necessary management and administrative personnel whose expertise will ensure efficient operation of SNEMT services. OoA recognizes that a high quality operation begins with key personnel. Therefore, a minimum level of required staffing is described for the positions and functions described below. 1. Program Manager/Director The program manager/director will be in charge of all management and day- to-day operations of the CONTRACTOR’s SNEMT program. The position will maintain consistent and sufficient contact and communication with the OoA and be responsible for all CONTRACT obligations.

  • Additional Compliance If any Proposed Key Holder Transfer is not consummated within forty-five (45) days after receipt of the Proposed Transfer Notice by the Company, the Key Holders proposing the Proposed Key Holder Transfer may not sell any Transfer Stock unless they first comply in full with each provision of this Section 2. The exercise or election not to exercise any right by any Investor hereunder shall not adversely affect its right to participate in any other sales of Transfer Stock subject to this Section 2.2.

  • General Reporting Requirements The MA-PD Sponsor agrees to submit to information to CMS according to 42 CFR §§423.505(f), 423.514, and the "Final Medicare Part D Reporting Requirements," a document issued by CMS and subject to modification each program year.