Additional Services Requiring Owner’s Written Authorization. A. If authorized in writing by Owner, Engineer shall provide Additional Services of the types listed below. These services are not included as part of Basic Services and will be paid for by Owner as indicated in Paragraph 7 of the governing Task Order. 1. Obtain or provide specified additional Specific Project-related information and data to enable Engineer to complete its Basic and Additional Services. 2. Preparation of special and customized reporting, invoicing, and related support documentation in addition to that identified to be provided under Basic Services. 3. Preparation of applications and supporting documents (in addition to those furnished under Basic Services) for private or governmental grants, loans, or advances in connection with the Specific Project; preparation or review of environmental assessments and impact statements; review and evaluation of the effects on the design requirements for the Specific Project of any such statements and documents prepared by others; and assistance in obtaining approvals of authorities having jurisdiction over the anticipated environmental impact of the Specific Project. 4. Services to make measured drawings of existing conditions or facilities, to conduct tests or investigations of existing conditions or facilities, or to verify the accuracy of drawings or other information furnished by Owner or others. 5. Services resulting from significant changes in the scope, extent, or character of the portions of the Specific Project designed or specified by Engineer, or the Specific Project’s design requirements, including, but not limited to, changes in size, complexity, Owner’s schedule, character of construction, or method of financing; and revising previously accepted studies, reports, Drawings, Specifications, or Construction Contract Documents when such revisions are required by changes in Laws and Regulations enacted subsequent to the Effective Date or are due to any other causes beyond Engineer’s control. 6. Services resulting from Owner’s request to evaluate additional Study and Report Phase alternative solutions beyond those agreed to in Exhibit A Paragraph 1.02.A.1. 7. Services required as a result of Owner’s providing incomplete or incorrect Specific Project information to Engineer. 8. Providing renderings or models for Owner’s use, including development, management, and other services in support of building information modeling or civil integrated management. 9. Undertaking investigations and studies including, but not limited to: a. All-hazards risk assessments and other studies to evaluate the feasibility of enhancing the resiliency of the design; b. detailed consideration of operations, maintenance, and overhead expenses; c. the preparation of feasibility studies (such as those that include projections of output capacity, utility project rates, project market demand, or project revenues) and cash flow analyses, provided that such services are based on the engineering and technical aspects of the Specific Project, and do not include rendering advice regarding municipal financial products or the issuance of municipal securities; d. preparation of appraisals; e. with respect to proprietary systems or processes requiring licensing, providing services necessary to assist Owner in obtaining such licensing. f. detailed quantity surveys of materials, equipment, and labor; and g. audits or inventories required in connection with construction performed or furnished by Owner. 10. Furnishing services of Subconsultants for other than Basic Services. 11. Providing data or services of the types described in Article 2, when Owner retains Engineer to provide such data or services instead of Owner furnishing the same. 12. Providing the following services: a. Services attributable to more prime construction contracts than specified in Exhibit A Paragraph 1.04.A.1. b. Services to arrange for performance of construction services for Owner by contractors other than the principal prime Contractor, and administering Owner’s contract for such services. 13. Services during out-of-town travel required of Engineer, other than for visits to the Site or Owner’s office as required in Basic Services (Article 1 of Exhibit A). 14. Preparing for, coordinating with, participating in and responding to structured independent review processes, including, but not limited to, construction management, cost estimating, project peer review, value engineering, and constructability review requested by Owner; and performing or furnishing services required to revise studies, reports, Drawings, Specifications, or other documents as a result of such review processes. 15. Preparing additional bidding-related documents (or requests for proposals or other construction procurement documents); preparing pre-qualification procedures and documents, and participating in pre-qualifying prospective Bidders; and preparing Construction Contract Documents for alternate bids. 16. Assistance in connection with bid protests, rebidding, or renegotiating contracts for construction, materials, equipment, or services. 17. Preparing conformed Construction Contract Documents that incorporate and integrate the content of all addenda and any amendments negotiated by Owner and Contractor. 18. Services to assist Owner in developing or modifying protocols for transmittal of Electronic Documents by Electronic Means after the effective date of this Agreement, either by revising or adapting Exhibit F to the Specific Project or implementing other Electronic Documents protocols among Specific Project participants. 19. Any services by Engineer in connection with Owner or Engineer providing a Document to a Requesting Party, or any other distribution of a Document to a third party. Such services may include but are not limited to preparing the data contained in the requested Document in a manner deemed appropriate by Engineer; creating or otherwise preparing and distributing the Document in a format necessary to respond to Owner’s direction or decision to provide the Document to a requesting party, including Contractor, in a format other than that required for deliverables from Engineer to Owner; and services in connection with obtaining required releases from the third parties to which the Documents will be distributed. Compensation for these Additional Services is not contingent upon Owner’s reimbursement from the requesting party. 20. Providing Construction Phase services beyond the original date for completion and readiness for final payment of Contractor, but only if such services increase the total quantity of services to be performed in the Construction Phase, rather than merely shifting performance of such services to a later date. 21. Preparing Record Drawings, and furnishing such Record Drawings to Owner. 22. Supplementing Record Drawings with information regarding the completed Specific Project, Site, and immediately adjacent areas obtained from field observations, Owner, utility companies, and other reliable sources. 23. Conducting surveys, investigations, and field measurements to verify the accuracy of Record Drawing content obtained from Contractor, Owner, utility companies, and other sources; revise and supplement Record Drawings as needed. 24. Preparation of operation, maintenance, and staffing manuals. 25. Protracted or extensive assistance in refining and adjusting of Specific Project equipment and systems (such as initial startup, testing, and balancing). 26. Assistance to Owner in training Owner’s staff to operate and maintain Specific Project equipment and systems. 27. Assistance to Owner in developing systems and procedures for (a) control of the operation and maintenance of Specific Project equipment and systems, and (b) related recordkeeping. 28. Preparing to serve or serving as a consultant or witness for, or producing documents for or on behalf of, Owner in any litigation, arbitration, mediation, lien or bond claim, or other legal or administrative proceeding involving the Specific Project (but not including disputes between Owner and Engineer). 29. Overtime work requiring higher than regular rates. 30. Providing construction surveys and staking to enable Contractor to perform its work other than as required under Exhibit A Paragraph 1.06.B.9; any type of property surveys or related engineering services needed for the transfer of interests in real property; providing construction and property surveys to replace reference points or property monuments lost or destroyed during construction; and providing other special field surveys. 31. Providing more extensive services required to enable Engineer to issue notices or certifications requested by Owner. 32. Extensive services required during any correction period, or with respect to monitoring Contractor’s compliance with warranties and guarantees called for in the Construction Contract (except as agreed to under Basic Services). 33. Other additional services performed or furnished by Engineer not otherwise provided for in this Agreement. Owner: [Name of Owner] Engineer: [Name of Engineer] Effective Date of Agreement: [Effective Date of Agreement] Nature of Amendment: (Check those that apply) ☐ Modifications to responsibilities of Owner ☐ Modifications of payment to Engineer ☐ Modifications to term of Agreement ☐ Modifications to other terms and conditions of the Agreement Description of Modifications: Owner and Engineer hereby agree to modify the above-referenced Agreement as set forth in this Amendment. The Effective Date of the Amendment is [Enter Effective Date of Amendment]. Owner Engineer (typed or printed name of organization) (typed or printed name of organization) By: By: (individual’s signature) (individual’s signature) Date: Date: (date signed) (date signed) Name: Name: (typed or printed) (typed or printed) Title: Title: (typed or printed) (typed or printed)
Appears in 1 contract
Sources: Agreement Between Owner and Engineer for Professional Services
Additional Services Requiring Owner’s Written Authorization. A. If authorized in writing by Owner, Engineer shall provide Additional Services of the types listed below. These services are not included as part of Basic Services and will be paid for by Owner as indicated in Paragraph 7 of the governing Task Order.
1. Obtain or provide specified additional Specific Project-related information and data to enable Engineer to complete its Basic and Additional Services.
2. Preparation of special and customized reporting, invoicing, and related support documentation in addition to that identified to be provided under Basic Services.
3. Preparation of applications and supporting documents (in addition to those furnished under Basic Services) for private or governmental grants, loans, or advances in connection with the Specific Project; preparation or review of environmental assessments and impact statements; review and evaluation of the effects on the design requirements for the Specific Project of any such statements and documents prepared by others; and assistance in obtaining approvals of authorities having jurisdiction over the anticipated environmental impact of the Specific Project.
4. Services to make measured drawings of existing conditions or facilities, to conduct tests or investigations of existing conditions or facilities, or to verify the accuracy of drawings or other information furnished by Owner or others.
5. Services resulting from significant changes in the scope, extent, or character of the portions of the Specific Project designed or specified by Engineer, or the Specific Project’s design requirements, including, but not limited to, changes in size, complexity, Owner’s schedule, character of construction, or method of financing; and revising previously accepted studies, reports, Drawings, Specifications, or Construction Contract Documents when such revisions are required by changes in Laws and Regulations enacted subsequent to the Effective Date or are due to any other causes beyond Engineer’s control.
6. Services resulting from Owner’s request to evaluate additional Study and Report Phase alternative solutions beyond those agreed to in Exhibit A Paragraph 1.02.A.1.
7. Services required as a result of Owner’s providing incomplete or incorrect Specific Project information to Engineer.
8. Providing renderings or models for Owner’s use, including development, management, and other services in support of building information modeling or civil integrated management.
9. Undertaking investigations and studies including, but not limited to:
a. All-hazards risk assessments and other studies to evaluate the feasibility of enhancing the resiliency of the design;
b. detailed consideration of operations, maintenance, and overhead expenses;
c. the preparation of feasibility studies (such as those that include projections of output capacity, utility project rates, project market demand, or project revenues) and cash flow analyses, provided that such services are based on the engineering and technical aspects of the Specific Project, and do not include rendering advice regarding municipal financial products or the issuance of municipal securities;
d. preparation of appraisals;
e. with respect to proprietary systems or processes requiring licensing, providing services necessary to assist Owner in obtaining such licensing.
f. detailed quantity surveys of materials, equipment, and labor; and
g. audits or inventories required in connection with construction performed or furnished by Owner.
10. Furnishing services of Subconsultants or Engineer’s Subcontractors for other than Basic Services.
11. Providing data or services of the types described in Article 2, when Owner retains Engineer to provide such data or services instead of Owner furnishing the same.
12. Providing the following services:
a. Services attributable to more prime construction contracts than specified in Exhibit A Paragraph 1.04.A.1.
b. Services to arrange for performance of construction services for Owner by contractors other than the principal prime Contractor, and administering Owner’s contract for such services.
13. Services during out-of-town travel required of Engineer, other than for visits to the Site or Owner’s office as required in Basic Services (Article 1 of Exhibit A).
14. Preparing for, coordinating with, participating in and responding to structured independent review processes, including, but not limited to, construction management, cost estimating, project peer review, value engineering, and constructability review requested by Owner; and performing or furnishing services required to revise studies, reports, Drawings, Specifications, or other documents as a result of such review processes.
15. Preparing additional bidding-related documents (or requests for proposals or other construction procurement documents); preparing pre-qualification procedures and documents, and participating in pre-qualifying prospective Bidders; and preparing Construction Contract Documents for alternate bids.
16. Assistance in connection with bid protests, rebidding, or renegotiating contracts for construction, materials, equipment, or services.
17. Preparing conformed Construction Contract Documents that incorporate and integrate the content of all addenda and any amendments negotiated by Owner and Contractor.
18. Services to assist Owner in developing or modifying protocols for transmittal of Electronic Documents by Electronic Means after the effective date of this Agreement, either by revising or adapting Exhibit F to the Specific Project or implementing other Electronic Documents protocols among Specific Project participants.
19. Any services by Engineer in connection with Owner or Engineer providing a Document to a Requesting PartyParty under Exhibit F Paragraph 1.01.D (see Exhibit F, Electronic Documents Protocol), or any other distribution of a Document to a third party. Such services may include but are not limited to preparing the data contained in the requested Document in a manner deemed appropriate by Engineer; creating or otherwise preparing and distributing the Document in a format necessary to respond to Owner’s direction or decision to provide the Document to a requesting party, including Contractor, in a format other than that required for deliverables from Engineer to Owner; and services in connection with obtaining required releases from the third parties to which the Documents will be distributed. Compensation for these Additional Services is not contingent upon Owner’s reimbursement from the requesting party.
20. Providing Construction Phase services beyond the original date for completion and readiness for final payment of Contractor, but only if such services increase the total quantity of services to be performed in the Construction Phase, rather than merely shifting performance of such services to a later date.
21. Preparing Record Drawings, and furnishing such Record Drawings to Owner.
22. Supplementing Record Drawings with information regarding the completed Specific Project, Site, and immediately adjacent areas obtained from field observations, Owner, utility companies, and other reliable sources.
23. Conducting surveys, investigations, and field measurements to verify the accuracy of Record Drawing content obtained from Contractor, Owner, utility companies, and other sources; revise and supplement Record Drawings as needed.
24. Preparation of operation, maintenance, and staffing manuals.
25. Protracted or extensive assistance in refining and adjusting of Specific Project equipment and systems (such as initial startup, testing, and balancing).
26. Assistance to Owner in training Owner’s staff to operate and maintain Specific Project equipment and systems.
27. Assistance to Owner in developing systems and procedures for (a) control of the operation and maintenance of Specific Project equipment and systems, and (b) related recordkeeping.
28. Preparing to serve or serving as a consultant or witness for, or producing documents for or on behalf of, Owner in any litigation, arbitration, mediation, lien or bond claim, or other legal or administrative proceeding involving the Specific Project (but not including disputes between Owner and Engineer).
29. Overtime work requiring higher than regular rates.
30. Providing construction surveys and staking to enable Contractor to perform its work other than as required under Exhibit A Paragraph 1.06.B.9; any type of property surveys or related engineering services needed for the transfer of interests in real property; providing construction and property surveys to replace reference points or property monuments lost or destroyed during construction; and providing other special field surveys.
31. Providing more extensive services required to enable Engineer to issue notices or certifications requested by Owner.
32. Extensive services required during any correction period, or with respect to monitoring Contractor’s compliance with warranties and guarantees called for in the Construction Contract (except as agreed to under Basic Services).
33. Other additional services performed or furnished by Engineer not otherwise provided for in this Agreement. Owner: [Name of Owner] Engineer: [Name of Engineer] Effective Date of Agreement: [Effective Date of Agreement] Nature of Amendment: (Check those that apply) ☐ Modifications to responsibilities of Owner ☐ Modifications of payment to Engineer ☐ Modifications to term of Agreement ☐ Modifications to other terms and conditions of the Agreement Description of Modifications: Owner and Engineer hereby agree to modify the above-referenced Agreement as set forth in this Amendment. The Effective Date of the Amendment is [Enter Effective Date of Amendment]. Owner Engineer (typed or printed name of organization) (typed or printed name of organization) By: By: (individual’s signature) (individual’s signature) Date: Date: (date signed) (date signed) Name: Name: (typed or printed) (typed or printed) Title: Title: (typed or printed) (typed or printed).
ARTICLE 1— RESIDENT PROJECT REPRESENTATIVE SERVICES
Appears in 1 contract
Sources: Master Agreement for Engineering Professional Services
Additional Services Requiring Owner’s Written Authorization. A. If authorized in writing by Owner, Engineer ENGINEER shall provide furnish or obtain from others Additional Services of the types listed below. These services are not included as part of Basic Services and will be paid for by Owner as indicated in Paragraph 7 of the governing Task Order.
1. Obtain or provide specified additional Specific Project-related information and data to enable Engineer to complete its Basic and Additional Services.
2. Preparation of special and customized reporting, invoicing, and related support documentation in addition to that identified to be provided under Basic Services.
3. Preparation of applications and supporting documents (in addition to those furnished under Basic Services) for private or governmental grants, loans, or advances in connection with the Specific Project; preparation or review of environmental assessments and impact statements; review and evaluation of the effects on the design requirements for the Specific Project of any such statements and documents prepared by others; and assistance in obtaining approvals of authorities having jurisdiction over the anticipated environmental impact of the Specific Project.
4. Services to make measured drawings of existing conditions or facilities, to conduct tests or investigations of existing conditions or facilities, or to verify the accuracy of drawings or other information furnished by Owner or others.
5. A. Services resulting from significant changes in the scope, extent, or character of the portions of the Specific Project designed or specified by Engineer, ENGINEER or the Specific Project’s its design requirements, requirements including, but not limited to, changes in size, complexity, Owner’s schedule, character of construction, or method of financing; and revising previously accepted studies, reports, Drawings, Specifications, or Construction Contract Documents when such revisions are required by changes in Laws and Regulations enacted subsequent to the Effective Date of this Agreement or are due to any other causes beyond Engineer’s control.
6. Services resulting from OwnerB. Furnishing services of Engineer’s request Consultants for other than Basic Services.
C. OWNER requested revisions to evaluate additional Study and Report Phase alternative solutions the Engineer’s work following previous approval, acceptance, or concurrence of that work by the OWNER.
D. The evaluation of alternatives, means, or methods to determine options or ways to reduce costs after prior OWNER approval of the Project, or beyond those agreed to described in Exhibit A Paragraph 1.02.A.1Basic Engineering Services.
7. E. Services to make measured drawings of or to investigate existing conditions or facilities, or to verify the accuracy of drawings or other information furnished by OWNER or others.
F. Services required as a result of Owner’s providing incomplete or incorrect Specific Project information to EngineerENGINEER.
8. G. Engineering services related to “green” design, sustainable design, or to achieve any level of USGBC LEED certification.
H. Preparation of applications and supporting documents (in addition to those furnished under Basic Services) for private or governmental grants in connection with the Project; preparation or review of environmental assessments and impact statements; review and evaluation of the effects on the design requirements for the Project of any such statements and documents prepared by others; and assistance in obtaining approvals of authorities having jurisdiction over the anticipated environmental impact of the Project.
I. Providing renderings or models for Owner’s use, including development, management, and other services in support of building information modeling or civil integrated management.
9. J. Special project insurance requirements and associated premiums beyond that provided in the aforementioned Basic Services fee or in excess of that currently maintained by Engineer.
K. Undertaking investigations and studies including, but not limited to:
a. All-hazards risk assessments and other studies to evaluate the feasibility of enhancing the resiliency of the design;
b. , detailed consideration of operations, maintenance, and overhead expenses;
c. ; the preparation of feasibility studies (such as those that include projections of output capacitystudies, utility project rates, project market demand, or project revenues) and cash flow analysesand economic evaluations, provided that such services are based on the engineering and technical aspects of the Specific Projectrate schedules, and do not include rendering advice regarding municipal financial products or appraisals; assistance in obtaining financing for the issuance of municipal securities;
d. preparation of appraisals;
e. with respect to proprietary systems or Project; evaluating processes requiring available for licensing, providing services necessary to assist Owner and assisting OWNER in obtaining such process licensing.
f. ; detailed quantity surveys of materials, equipment, and labor; and
g. and audits or inventories required in connection with construction performed or furnished by OwnerOWNER.
10. Furnishing services of Subconsultants for other than Basic Services.
11. L. Providing data or services of the types described assistance with Environmental Assessments, archeological reconnaissance, environmental reviews performed by others, and/or in Article 2, when Owner retains Engineer to provide such data or services instead of Owner furnishing the same.
12. Providing the following services:
a. Services attributable to more prime construction contracts than specified resolving any Hazardous Environmental Condition in Exhibit A Paragraph 1.04.A.1.
b. Services to arrange for performance of construction services for Owner by contractors other than the principal prime Contractor, and administering Owner’s contract for such services.
13. Services during out-of-town travel required of Engineer, other than for visits to the Site or Owner’s office as required in Basic Services (Article 1 of Exhibit A).
14. Preparing for, coordinating with, participating in and responding to structured independent review processes, including, but not limited to, construction management, cost estimating, project peer review, value engineering, and constructability review requested by Owner; and performing or furnishing services required to revise studies, reports, Drawings, Specifications, or other documents as a result of such review processes.
15. Preparing additional bidding-related documents (or requests for proposals or other construction procurement documents); preparing pre-qualification procedures and documents, and participating in pre-qualifying prospective Bidders; and preparing Construction Contract Documents for alternate bids.
16. Assistance in connection with bid protests, rebidding, or renegotiating contracts for construction, materials, equipment, or services.
17. Preparing conformed Construction Contract Documents that incorporate and integrate the content of all addenda and any amendments negotiated by Owner and Contractor.
18. Services to assist Owner in developing or modifying protocols for transmittal of Electronic Documents by Electronic Means after the effective date of this Agreement, either by revising or adapting Exhibit F to the Specific Project or implementing other Electronic Documents protocols among Specific Project participants.
19. Any services by Engineer in connection with Owner or Engineer providing a Document to a Requesting Party, or any other distribution of a Document to a third party. Such services may include but are not limited to preparing the data contained in the requested Document in a manner deemed appropriate by Engineer; creating or otherwise preparing and distributing the Document in a format necessary to respond to Owner’s direction or decision to provide the Document to a requesting party, including Contractor, in a format other than that required for deliverables from Engineer to Owner; and services in connection with obtaining required releases from the third parties to which the Documents will be distributed. Compensation for these Additional Services is not contingent upon Owner’s reimbursement from the requesting party.
20. Providing Construction Phase services beyond the original date for completion and readiness for final payment of Contractor, but only if such services increase the total quantity of services to be performed in the Construction Phase, rather than merely shifting performance of such services to a later date.
21. Preparing Record Drawings, and furnishing such Record Drawings to Owner.
22. Supplementing Record Drawings with information regarding the completed Specific Project, Site, and immediately adjacent areas obtained from field observations, Owner, utility companies, and other reliable sources.
23. Conducting surveys, investigations, and field measurements to verify the accuracy of Record Drawing content obtained from Contractor, Owner, utility companies, and other sources; revise and supplement Record Drawings as needed.
24. Preparation of operation, maintenance, and staffing manuals.
25. Protracted or extensive assistance in refining and adjusting of Specific Project equipment and systems (such as initial startup, testing, and balancing).
26. Assistance to Owner in training Owner’s staff to operate and maintain Specific Project equipment and systems.
27. Assistance to Owner in developing systems and procedures for (a) control of the operation and maintenance of Specific Project equipment and systems, and (b) related recordkeeping.
28. Preparing to serve or serving as a consultant or witness for, or producing documents for or on behalf of, Owner in any litigation, arbitration, mediation, lien or bond claim, or other legal or administrative proceeding involving the Specific Project (but not including disputes between Owner and Engineer).
29. Overtime work requiring higher than regular rates.
30. Providing construction surveys and staking to enable Contractor to perform its work other than as required under Exhibit A Paragraph 1.06.B.9; any type of property surveys or related engineering services needed for the transfer of interests in real property; providing construction and property surveys to replace reference points or property monuments lost or destroyed during construction; and providing other special field surveys.
31. Providing more extensive services required to enable Engineer to issue notices or certifications requested by Owner.
32. Extensive services required during any correction period, or with respect to monitoring Contractor’s compliance with warranties current Laws and guarantees called for in the Construction Contract (except as agreed to under Basic Services)Regulations.
33. Other additional services performed or furnished by Engineer not otherwise provided for in this Agreement. Owner: [Name of Owner] Engineer: [Name of Engineer] Effective Date of Agreement: [Effective Date of Agreement] Nature of Amendment: (Check those that apply) ☐ Modifications to responsibilities of Owner ☐ Modifications of payment to Engineer ☐ Modifications to term of Agreement ☐ Modifications to other terms and conditions of the Agreement Description of Modifications: Owner and Engineer hereby agree to modify the above-referenced Agreement as set forth in this Amendment. The Effective Date of the Amendment is [Enter Effective Date of Amendment]. Owner Engineer (typed or printed name of organization) (typed or printed name of organization) By: By: (individual’s signature) (individual’s signature) Date: Date: (date signed) (date signed) Name: Name: (typed or printed) (typed or printed) Title: Title: (typed or printed) (typed or printed)
Appears in 1 contract
Sources: Engineering Services Agreement
Additional Services Requiring Owner’s Written Authorization. A. If authorized in writing by Owner, Engineer shall provide furnish or obtain from others Additional Services of the types listed below. These services are not included as part of Basic Services and will be paid for by Owner as indicated in Paragraph 7 of the governing Task Order.
1. Obtain or provide specified additional Specific Project-related information and data to enable Engineer to complete its Basic and Additional Services.
2. Preparation of special and customized reporting, invoicing, and related support documentation in addition to that identified to be provided under Basic Services.
3. Preparation of applications and supporting documents (in addition to those furnished under Basic Services) for private or governmental grants, loans, or advances in connection with the Specific Project; preparation or review of environmental assessments and impact statements; review and evaluation of the effects on the design requirements for the Specific Project of any such statements and documents prepared by others; and assistance in obtaining approvals of authorities having jurisdiction over the anticipated environmental impact of the Specific Project.
4. Services to make measured drawings of existing conditions or facilities, to conduct tests or investigations of existing conditions or facilities, or to verify the accuracy of drawings or other information furnished by Owner or others.
5. A. Services resulting from significant changes in the scope, extent, or character of the portions of the Specific Project designed or specified by Engineer, Engineer or the Specific Project’s its design requirements, requirements including, but not limited to, changes in size, complexity, Owner’s schedule, character of construction, or method of financing; and revising previously accepted studies, reports, Drawings, Specifications, or Construction Contract Documents when such revisions are required by changes in Laws and Regulations enacted subsequent to the Effective Date of this Agreement or are due to any other causes beyond Engineer’s control.
6. Services resulting from B. Furnishing services of Engineer’s Consultants for other than Basic Services.
C. Owner requested revisions to the Engineer’s work following previous approval, acceptance, or concurrence of that work by the Owner’s request .
D. The evaluation of alternatives, means, or methods to evaluate additional Study and Report Phase alternative solutions determine options or ways to reduce costs after prior Owner approval of the Project, or beyond those agreed to described in Exhibit A Paragraph 1.02.A.1Basic Engineering Services.
7. E. Services to make measured drawings of or to investigate existing conditions or facilities, or to verify the accuracy of drawings or other information furnished by Owner or others.
F. Services required as a result of Owner’s providing incomplete or incorrect Specific Project information to Engineer.
8. G. Engineering services related to “green” design, sustainable design, or to achieve any level of USGBC LEED certification.
H. Preparation of applications and supporting documents (in addition to those furnished under Basic Services) for private or governmental grants in connection with the Project; preparation or review of environmental assessments and impact statements; review and evaluation of the effects on the design requirements for the Project of any such statements and documents prepared by others; and assistance in obtaining approvals of authorities having jurisdiction over the anticipated environmental impact of the Project.
I. Providing renderings or models for Owner’s use, including development, management, and other services in support of building information modeling or civil integrated management.
9. J. Special project insurance requirements and associated premiums beyond that provided in the aforementioned Basic Services fee or in excess of that currently maintained by Engineer.
K. Undertaking investigations and studies including, but not limited to:
a. All-hazards risk assessments and other studies to evaluate the feasibility of enhancing the resiliency of the design;
b. , detailed consideration of operations, maintenance, and overhead expenses;
c. ; the preparation of feasibility studies (such as those that include projections of output capacitystudies, utility project rates, project market demand, or project revenues) and cash flow analysesand economic evaluations, provided that such services are based on the engineering and technical aspects of the Specific Projectrate schedules, and do not include rendering advice regarding municipal financial products or appraisals; assistance in obtaining financing for the issuance of municipal securities;
d. preparation of appraisals;
e. with respect to proprietary systems or Project; evaluating processes requiring available for licensing, providing services necessary to assist and assisting Owner in obtaining such process licensing.
f. ; detailed quantity surveys of materials, equipment, and labor; and
g. and audits or inventories required in connection with construction performed or furnished by Owner.
10. Furnishing services of Subconsultants for other than Basic Services.
11. L. Providing data or services of the types described assistance with Environmental Assessments, archeological reconnaissance, environmental reviews performed by others, and/or in Article 2, when Owner retains Engineer to provide such data or services instead of Owner furnishing the same.
12. Providing the following services:
a. Services attributable to more prime construction contracts than specified resolving any Hazardous Environmental Condition in Exhibit A Paragraph 1.04.A.1.
b. Services to arrange for performance of construction services for Owner by contractors other than the principal prime Contractor, and administering Owner’s contract for such services.
13. Services during out-of-town travel required of Engineer, other than for visits to the Site or Owner’s office as required in Basic Services (Article 1 of Exhibit A).
14. Preparing for, coordinating with, participating in and responding to structured independent review processes, including, but not limited to, construction management, cost estimating, project peer review, value engineering, and constructability review requested by Owner; and performing or furnishing services required to revise studies, reports, Drawings, Specifications, or other documents as a result of such review processes.
15. Preparing additional bidding-related documents (or requests for proposals or other construction procurement documents); preparing pre-qualification procedures and documents, and participating in pre-qualifying prospective Bidders; and preparing Construction Contract Documents for alternate bids.
16. Assistance in connection with bid protests, rebidding, or renegotiating contracts for construction, materials, equipment, or services.
17. Preparing conformed Construction Contract Documents that incorporate and integrate the content of all addenda and any amendments negotiated by Owner and Contractor.
18. Services to assist Owner in developing or modifying protocols for transmittal of Electronic Documents by Electronic Means after the effective date of this Agreement, either by revising or adapting Exhibit F to the Specific Project or implementing other Electronic Documents protocols among Specific Project participants.
19. Any services by Engineer in connection with Owner or Engineer providing a Document to a Requesting Party, or any other distribution of a Document to a third party. Such services may include but are not limited to preparing the data contained in the requested Document in a manner deemed appropriate by Engineer; creating or otherwise preparing and distributing the Document in a format necessary to respond to Owner’s direction or decision to provide the Document to a requesting party, including Contractor, in a format other than that required for deliverables from Engineer to Owner; and services in connection with obtaining required releases from the third parties to which the Documents will be distributed. Compensation for these Additional Services is not contingent upon Owner’s reimbursement from the requesting party.
20. Providing Construction Phase services beyond the original date for completion and readiness for final payment of Contractor, but only if such services increase the total quantity of services to be performed in the Construction Phase, rather than merely shifting performance of such services to a later date.
21. Preparing Record Drawings, and furnishing such Record Drawings to Owner.
22. Supplementing Record Drawings with information regarding the completed Specific Project, Site, and immediately adjacent areas obtained from field observations, Owner, utility companies, and other reliable sources.
23. Conducting surveys, investigations, and field measurements to verify the accuracy of Record Drawing content obtained from Contractor, Owner, utility companies, and other sources; revise and supplement Record Drawings as needed.
24. Preparation of operation, maintenance, and staffing manuals.
25. Protracted or extensive assistance in refining and adjusting of Specific Project equipment and systems (such as initial startup, testing, and balancing).
26. Assistance to Owner in training Owner’s staff to operate and maintain Specific Project equipment and systems.
27. Assistance to Owner in developing systems and procedures for (a) control of the operation and maintenance of Specific Project equipment and systems, and (b) related recordkeeping.
28. Preparing to serve or serving as a consultant or witness for, or producing documents for or on behalf of, Owner in any litigation, arbitration, mediation, lien or bond claim, or other legal or administrative proceeding involving the Specific Project (but not including disputes between Owner and Engineer).
29. Overtime work requiring higher than regular rates.
30. Providing construction surveys and staking to enable Contractor to perform its work other than as required under Exhibit A Paragraph 1.06.B.9; any type of property surveys or related engineering services needed for the transfer of interests in real property; providing construction and property surveys to replace reference points or property monuments lost or destroyed during construction; and providing other special field surveys.
31. Providing more extensive services required to enable Engineer to issue notices or certifications requested by Owner.
32. Extensive services required during any correction period, or with respect to monitoring Contractor’s compliance with warranties current Laws and guarantees called for in the Construction Contract (except as agreed to under Basic Services)Regulations.
33. Other additional services performed or furnished by Engineer not otherwise provided for in this Agreement. Owner: [Name of Owner] Engineer: [Name of Engineer] Effective Date of Agreement: [Effective Date of Agreement] Nature of Amendment: (Check those that apply) ☐ Modifications to responsibilities of Owner ☐ Modifications of payment to Engineer ☐ Modifications to term of Agreement ☐ Modifications to other terms and conditions of the Agreement Description of Modifications: Owner and Engineer hereby agree to modify the above-referenced Agreement as set forth in this Amendment. The Effective Date of the Amendment is [Enter Effective Date of Amendment]. Owner Engineer (typed or printed name of organization) (typed or printed name of organization) By: By: (individual’s signature) (individual’s signature) Date: Date: (date signed) (date signed) Name: Name: (typed or printed) (typed or printed) Title: Title: (typed or printed) (typed or printed)
Appears in 1 contract
Sources: Engineering Services Agreement
Additional Services Requiring Owner’s Written Authorization. A. If authorized in writing by Owner, Engineer ENGINEER shall provide furnish or obtain from others Additional Services of the types listed below. These services are not included as part of Basic Services and will be paid for by Owner as indicated in Paragraph 7 of the governing Task Order.
1. Obtain or provide specified additional Specific Project-related information and data to enable Engineer to complete its Basic and Additional Services.
2. Preparation of special and customized reporting, invoicing, and related support documentation in addition to that identified to be provided under Basic Services.
3. Preparation of applications and supporting documents (in addition to those furnished under Basic Services) for private or governmental grants, loans, or advances in connection with the Specific Project; preparation or review of environmental assessments and impact statements; review and evaluation of the effects on the design requirements for the Specific Project of any such statements and documents prepared by others; and assistance in obtaining approvals of authorities having jurisdiction over the anticipated environmental impact of the Specific Project.
4. Services to make measured drawings of existing conditions or facilities, to conduct tests or investigations of existing conditions or facilities, or to verify the accuracy of drawings or other information furnished by Owner or others.
5. Services resulting from significant changes in the scope, extent, or character of the portions of the Specific Project designed or specified by Engineer, ENGINEER or the Specific Project’s its design requirements, requirements including, but not limited to, changes in size, complexity, Owner’s schedule, character of construction, or method of financing; and revising previously accepted studies, reports, Drawings, Specifications, or Construction Contract Documents when such revisions are required by changes in Laws and Regulations enacted subsequent to the Effective Date of this Agreement or are due to any other causes beyond Engineer’s control.
62. Furnishing services of Engineer’s Consultants for other than Basic Services.
3. OWNER requested revisions to the Engineer’s work following previous approval, acceptance, or concurrence of that work by the OWNER.
4. The evaluation of alternatives, means, or methods to determine options or ways to reduce costs after prior OWNER approval of the Project, or beyond those described in Basic Engineering Services.
5. Services resulting from Owner’s request to evaluate additional Study and Report Phase alternative solutions beyond those agreed make measured drawings of or to in Exhibit A Paragraph 1.02.A.1investigate existing conditions or facilities, or to verify the accuracy of drawings or other information furnished by OWNER or others.
76. Services required as a result of Owner’s providing incomplete or incorrect Specific Project information to EngineerENGINEER.
7. Engineering services related to “green” design, sustainable design, or to achieve any level of USGBC LEED certification.
8. Preparation of applications and supporting documents (in addition to those furnished under Basic Services) for private or governmental grants in connection with the Project; preparation or review of environmental assessments and impact statements; review and evaluation of the effects on the design requirements for the Project of any such statements and documents prepared by others; and assistance in obtaining approvals of authorities having jurisdiction over the anticipated environmental impact of the Project.
9. Providing renderings or models for Owner’s use, including development, management, and other services in support of building information modeling or civil integrated management.
9. Undertaking investigations and studies including, but not limited to:
a. All-hazards risk assessments and other studies to evaluate the feasibility of enhancing the resiliency of the design;
b. detailed consideration of operations, maintenance, and overhead expenses;
c. the preparation of feasibility studies (such as those that include projections of output capacity, utility project rates, project market demand, or project revenues) and cash flow analyses, provided that such services are based on the engineering and technical aspects of the Specific Project, and do not include rendering advice regarding municipal financial products or the issuance of municipal securities;
d. preparation of appraisals;
e. with respect to proprietary systems or processes requiring licensing, providing services necessary to assist Owner in obtaining such licensing.
f. detailed quantity surveys of materials, equipment, and labor; and
g. audits or inventories required in connection with construction performed or furnished by Owner.
10. Furnishing services Other Services not specifically listed in the Basic Scope of Subconsultants for other than Basic Services.
11. Providing data or services of the types described in Article 2, when Owner retains Engineer to provide such data or services instead of Owner furnishing the same.
12. Providing the following services:
a. Services attributable to more prime construction contracts than specified in Exhibit A Paragraph 1.04.A.1.
b. Services to arrange for performance of construction services for Owner by contractors other than the principal prime Contractor, and administering Owner’s contract for such services.
13. Services during out-of-town travel required of Engineer, other than for visits to the Site or Owner’s office as required in Basic Services (Article 1 of Exhibit A).
14. Preparing for, coordinating with, participating in and responding to structured independent review processes, including, but not limited to, construction management, cost estimating, project peer review, value engineering, and constructability review requested by Owner; and performing or furnishing services required to revise studies, reports, Drawings, Specifications, or other documents as a result of such review processes.
15. Preparing additional bidding-related documents (or requests for proposals or other construction procurement documents); preparing pre-qualification procedures and documents, and participating in pre-qualifying prospective Bidders; and preparing Construction Contract Documents for alternate bids.
16. Assistance in connection with bid protests, rebidding, or renegotiating contracts for construction, materials, equipment, or services.
17. Preparing conformed Construction Contract Documents that incorporate and integrate the content of all addenda and any amendments negotiated by Owner and Contractor.
18. Services to assist Owner in developing or modifying protocols for transmittal of Electronic Documents by Electronic Means after the effective date of this Agreement, either by revising or adapting Exhibit F to the Specific Project or implementing other Electronic Documents protocols among Specific Project participants.
19. Any services by Engineer in connection with Owner or Engineer providing a Document to a Requesting Party, or any other distribution of a Document to a third party. Such services may include but are not limited to preparing the data contained in the requested Document in a manner deemed appropriate by Engineer; creating or otherwise preparing and distributing the Document in a format necessary to respond to Owner’s direction or decision to provide the Document to a requesting party, including Contractor, in a format other than that required for deliverables from Engineer to Owner; and services in connection with obtaining required releases from the third parties to which the Documents will be distributed. Compensation for these Additional Services is not contingent upon Owner’s reimbursement from the requesting party.
20. Providing Construction Phase services beyond the original date for completion and readiness for final payment of Contractor, but only if such services increase the total quantity of services to be performed in the Construction Phase, rather than merely shifting performance of such services to a later date.
21. Preparing Record Drawings, and furnishing such Record Drawings to Owner.
22. Supplementing Record Drawings with information regarding the completed Specific Project, Site, and immediately adjacent areas obtained from field observations, Owner, utility companies, and other reliable sources.
23. Conducting surveys, investigations, and field measurements to verify the accuracy of Record Drawing content obtained from Contractor, Owner, utility companies, and other sources; revise and supplement Record Drawings as needed.
24. Preparation of operation, maintenance, and staffing manuals.
25. Protracted or extensive assistance in refining and adjusting of Specific Project equipment and systems (such as initial startup, testing, and balancing).
26. Assistance to Owner in training Owner’s staff to operate and maintain Specific Project equipment and systems.
27. Assistance to Owner in developing systems and procedures for (a) control of the operation and maintenance of Specific Project equipment and systems, and (b) related recordkeeping.
28. Preparing to serve or serving as a consultant or witness for, or producing documents for or on behalf of, Owner in any litigation, arbitration, mediation, lien or bond claim, or other legal or administrative proceeding involving the Specific Project (but not including disputes between Owner and Engineer).
29. Overtime work requiring higher than regular rates.
30. Providing construction surveys and staking to enable Contractor to perform its work other than as required under Exhibit A Paragraph 1.06.B.9; any type of property surveys or related engineering services needed for the transfer of interests in real property; providing construction and property surveys to replace reference points or property monuments lost or destroyed during construction; and providing other special field surveys.
31. Providing more extensive services required to enable Engineer to issue notices or certifications requested by Owner.
32. Extensive services required during any correction period, or with respect to monitoring Contractor’s compliance with warranties and guarantees called for in the Construction Contract (except as agreed to under Basic Services).
33. Other additional services performed or furnished by Engineer not otherwise provided for in this Agreement. Owner: [Name of Owner] Engineer: [Name of Engineer] Effective Date of Agreement: [Effective Date of Agreement] Nature of Amendment: (Check those that apply) ☐ Modifications to responsibilities of Owner ☐ Modifications of payment to Engineer ☐ Modifications to term of Agreement ☐ Modifications to other terms and conditions of the Agreement Description of Modifications: Owner and Engineer hereby agree to modify the above-referenced Agreement as set forth in this Amendment. The Effective Date of the Amendment is [Enter Effective Date of Amendment]. Owner Engineer (typed or printed name of organization) (typed or printed name of organization) By: By: (individual’s signature) (individual’s signature) Date: Date: (date signed) (date signed) Name: Name: (typed or printed) (typed or printed) Title: Title: (typed or printed) (typed or printed)
Appears in 1 contract
Sources: Engineering Services Agreement
Additional Services Requiring Owner’s Written Authorization. A. If authorized in writing by Owner, Engineer shall provide Additional Services of the types listed below. These services are not included as part of Basic Services and will be paid for by Owner as indicated in Paragraph 7 Section II. of the governing Task Order.Agreement and Exhibit B.
1. Obtain or provide specified additional Specific Project-related information and data to enable Engineer to complete its Basic and Additional Services.
2. Preparation of special and customized reporting, invoicing, and related support documentation in addition to that identified to be provided under Basic Services.
3. Preparation of applications and supporting documents (in addition to those furnished under Basic Services) for private or governmental grants, loans, or advances in connection with the Specific Project; preparation or review of environmental assessments and impact statements, other than what is specifically defined under Basic Services; review and evaluation of the effects on the design requirements for the Specific Project of any such statements and documents prepared by others; and assistance in obtaining approvals of authorities having jurisdiction over the anticipated environmental impact of the Specific Project.
4. Services to make measured drawings of existing conditions or facilities, to conduct tests or investigations of existing conditions or facilities, or to verify the accuracy of drawings or other information furnished by Owner or others.
5. Services resulting from significant changes in the scope, extent, or character of the portions of the Specific Project designed or specified by Engineer, or the Specific Project’s design requirements, including, but not limited to, changes in size, complexity, Owner’s schedule, character of construction, or method of financing; and revising previously accepted studies, reports, Drawings, Specifications, or Construction Contract Documents when such revisions are required by changes in Laws and Regulations enacted subsequent to the Effective Date or are due to any other causes beyond Engineer’s control.
6. Services resulting from Owner’s request to evaluate additional Study and Report Phase alternative solutions beyond those agreed to in Exhibit A Paragraph 1.02.A.1.
7. Services required as a result of Owner’s providing incomplete or incorrect Specific Project information to Engineer.
8. Providing renderings or models for Owner’s use, including development, management, and other services in support of building information modeling or civil integrated management.
97. Undertaking investigations and studies including, but not limited to:
a. All-hazards risk assessments and other studies to evaluate the feasibility of enhancing the resiliency of the design;
b. detailed consideration of operations, maintenance, and overhead expenses;
c. the preparation of feasibility studies (such as those that include projections of output capacity, utility project rates, project market demand, or project revenuesa) and cash flow analyses, provided that such services are based on the engineering and technical aspects of the Specific Project, and do not include rendering advice regarding municipal financial products or the issuance of municipal securities;
d. preparation of appraisals;
e. with respect to proprietary systems or processes requiring licensing, providing services necessary to assist Owner in obtaining such licensing.
f. detailed quantity surveys of materials, equipment, and labor; and
g. audits or inventories required in connection with construction performed or furnished by Owner.
10. Furnishing services of Subconsultants for other than Basic Services.
11. Providing data or services of the types described in Article 2, when Owner retains Engineer to provide such data or services instead of Owner furnishing the same.
12. Providing the following services:
a. Services attributable to more prime construction contracts than specified in Exhibit A Paragraph 1.04.A.1.
b. Services to arrange for performance of construction services for Owner by contractors other than the principal prime Contractor, and administering Owner’s contract for such services.
13. Services during out-of-town travel required of Engineer, other than for visits to the Site or Owner’s office as required in Basic Services (Article 1 of Exhibit A).
14. Preparing for, coordinating with, participating in and responding to structured independent review processes, including, but not limited to, construction management, cost estimating, project peer review, value engineering, and constructability review requested by Owner; and performing or furnishing services required to revise studies, reports, Drawings, Specifications, or other documents as a result of such review processes.
15. Preparing additional bidding-related documents (or requests for proposals or other construction procurement documents); preparing pre-qualification procedures and documents, and participating in pre-qualifying prospective Bidders; and preparing Construction Contract Documents for alternate bids.
16. Assistance in connection with bid protests, rebidding, or renegotiating contracts for construction, materials, equipment, or services.
17. Preparing conformed Construction Contract Documents that incorporate and integrate the content of all addenda and any amendments negotiated by Owner and Contractor.
18. Services to assist Owner in developing or modifying protocols for transmittal of Electronic Documents by Electronic Means after the effective date of this Agreement, either by revising or adapting Exhibit F to the Specific Project or implementing other Electronic Documents protocols among Specific Project participants.
19. Any services by Engineer in connection with Owner or Engineer providing a Document to a Requesting Party, or any other distribution of a Document to a third party. Such services may include but are not limited to preparing the data contained in the requested Document in a manner deemed appropriate by Engineer; creating or otherwise preparing and distributing the Document in a format necessary to respond to Owner’s direction or decision to provide the Document to a requesting party, including Contractor, in a format other than that required for deliverables from Engineer to Owner; and services in connection with obtaining required releases from the third parties to which the Documents will be distributed. Compensation for these Additional Services is not contingent upon Owner’s reimbursement from the requesting party.
20. Providing Construction Phase services beyond the original date for completion and readiness for final payment of Contractor, but only if such services increase the total quantity of services to be performed in the Construction Phase, rather than merely shifting performance of such services to a later date.
21. Preparing Record Drawings, and furnishing such Record Drawings to Owner.
22. Supplementing Record Drawings with information regarding the completed Specific Project, Site, and immediately adjacent areas obtained from field observations, Owner, utility companies, and other reliable sources.
23. b) Conducting surveys, investigations, and field measurements to verify the accuracy of Record Drawing content obtained from Contractor, Owner, utility companies, and other sources; revise and supplement Record Drawings as needed.
248. Preparation of operation, maintenance, and staffing manuals.
259. Protracted or extensive assistance in refining and adjusting of Specific Project equipment and systems (such as initial startup, testing, and balancing).
26. Assistance to Owner in training Owner’s staff to operate and maintain Specific Project equipment and systems.
27. Assistance to Owner in developing systems and procedures for (a) control of the operation and maintenance of Specific Project equipment and systems, and (b) related recordkeeping.
2810. Preparing to serve or serving as a consultant or witness for, or producing documents for or on behalf of, Owner in any litigation, arbitration, mediation, lien or bond claim, or other legal or administrative proceeding involving the Specific Project (but not including disputes between Owner and Engineer).
2911. Overtime work requiring higher than regular rates.
3012. Providing construction surveys and staking to enable Contractor to perform its work other than as required under in this Exhibit A Paragraph 1.06.B.9A-1; any type of property surveys or related engineering services other than as required in this Exhibit A-1 and needed for the transfer of interests in real property; providing construction and property surveys to replace reference points or property monuments lost or destroyed during construction; and providing other special field surveys.
3113. Providing more extensive services required to enable Engineer to issue notices or certifications requested by Owner.
3214. Extensive services required during any correction period, or with respect to monitoring Contractor’s compliance with warranties and guarantees called for in the Construction Contract (except as agreed to under Basic Services).
3315. Other additional services performed or furnished by Engineer not otherwise provided for in this Agreement. Owner: [Name of Owner] Engineer: [Name of Engineer] Effective Date of Agreement: [Effective Date of Agreement] Nature of Amendment: (Check those that apply) ☐ Modifications to responsibilities of Owner ☐ Modifications of payment to Engineer ☐ Modifications to term of Agreement ☐ Modifications to other terms and conditions of the Agreement Description of Modifications: Owner and Engineer hereby agree to modify the above-referenced Agreement as set forth in this Amendment. The Effective Date of the Amendment is [Enter Effective Date of Amendment]. Owner Engineer (typed or printed name of organization) (typed or printed name of organization) By: By: (individual’s signature) (individual’s signature) Date: Date: (date signed) (date signed) Name: Name: (typed or printed) (typed or printed) Title: Title: (typed or printed) (typed or printed).
Appears in 1 contract
Sources: Engineering Services Agreement
Additional Services Requiring Owner’s Written Authorization. A. If authorized in writing by Owner, Engineer shall provide Additional Services of the types listed below. These services are not included as part of Basic Services and will be paid for by Owner as indicated in Paragraph 7 of the governing Task Order.
1. Obtain or provide specified additional Specific Project-related information and data to enable Engineer to complete its Basic and Additional Services.
2. Preparation of special and customized reporting, invoicing, and related support documentation in addition to that identified to be provided under Basic Services.
3. Exhibit C. Preparation of applications and supporting documents (in addition to those furnished under Basic Services) for private or governmental grants, loans, or advances in connection with the Specific Project; preparation or review of environmental assessments and impact statements; review and evaluation of the effects on the design requirements for the Specific Project of any such statements and documents prepared by others; and assistance in obtaining approvals of authorities having jurisdiction over the anticipated environmental impact of the Specific Project.
4. Services to make measured drawings of existing conditions or facilities, to conduct tests or investigations of existing conditions or facilities, or to verify the accuracy of drawings or other information furnished by Owner or others.
5. Services resulting from significant changes in the scope, extent, or character of the portions of the Specific Project designed or specified by Engineer, or the Specific Project’s design requirements, including, but not limited to, changes in size, complexity, Owner’s schedule, character of construction, or method of financing; and revising previously accepted studies, reports, Drawings, Specifications, or Construction Contract Documents when such revisions are required by changes in Laws and Regulations enacted subsequent to the Effective Date or are due to any other causes beyond Engineer’s control.
6. Services resulting from Owner’s request to evaluate additional Study and Report Phase alternative solutions beyond those agreed to in Exhibit A Paragraph 1.02.A.1.
7A1.01.A.1 and 2. Services required as a result of Owner’s providing incomplete or incorrect Specific Project information to Engineer.
8. Providing renderings or models for Owner’s use, including development, management, and other services in support of building information modeling or civil integrated management.
9. Undertaking investigations and studies including, but not limited to:
a. All-hazards risk assessments and other studies to evaluate the feasibility of enhancing the resiliency of the design;
b. : detailed consideration of operations, maintenance, and overhead expenses;
c. ; the preparation of feasibility studies (such as those that include projections of output capacity, utility project rates, project market demand, or project revenues) and cash flow analyses, provided that such services are based on the engineering and technical aspects of the Specific Project, and do not include rendering advice regarding municipal financial products or the issuance of municipal securities;
d. ; preparation of appraisals;
e. with respect to proprietary systems or ; evaluating processes requiring available for licensing, providing services necessary to assist and assisting Owner in obtaining such process licensing.
f. ; detailed quantity surveys of materials, equipment, and labor; and
g. and audits or inventories required in connection with construction performed or furnished by Owner.
10. Furnishing services of Subconsultants Consultants for other than Basic Services.
11. Providing data or services of the types described in Article 2Exhibit B, when Owner retains Engineer to provide such data or services instead of Owner furnishing the same.
12. Providing the following services:
a. : Services attributable to more prime construction contracts than specified in Exhibit A Paragraph 1.04.A.1.
b. A1.03.D. Services to arrange for performance of construction services for Owner by contractors other than the principal prime Contractor, and administering Owner’s contract for such services.
13. Services during out-of-town travel required of Engineer, other than for visits to the Site or Owner’s office as required in Basic Services (Article Part 1 of Exhibit A).
14. Preparing for, coordinating with, participating in and responding to structured independent review processes, including, but not limited to, construction management, cost estimating, project peer review, value engineering, and constructability constructibility review requested by Owner; and performing or furnishing services required to revise studies, reports, Drawings, Specifications, or other documents as a result of such review processes.
15. Preparing additional bidding-related documents (or requests for proposals or other construction procurement documents); preparing pre-qualification procedures and documents, and participating in pre-qualifying prospective Bidders; and preparing ) or Construction Contract Documents for alternate bids.
16bids or cost estimates requested by Owner for the Work or a portion thereof. Assistance in connection with bid protests, rebidding, or renegotiating contracts for construction, materials, equipment, or services.
17. , except when such assistance is required to complete services required by Paragraph 5.02.A and Exhibit F. Preparing conformed Construction Contract Documents that incorporate and integrate the content of all addenda Addenda and any amendments negotiated by Owner and Contractor.
18. Services to assist Owner in developing or modifying protocols for transmittal of Electronic Documents by Electronic Means after the effective date of this Agreement, either by revising or adapting Exhibit F to the Specific Project or implementing other Electronic Documents protocols among Specific Project participants.
19. Any services by Engineer in connection with Owner or Engineer providing a Document to a Requesting Party, or any other distribution of a Document to a third party. Such services may include but are not limited to preparing the data contained in the requested Document in a manner deemed appropriate by Engineer; creating or otherwise preparing and distributing the Document in a format necessary to respond to Owner’s direction or decision to provide the Document to a requesting party, including Contractor, in a format other than that required for deliverables from Engineer to Owner; and services in connection with obtaining required releases from the third parties to which the Documents will be distributed. Compensation for these Additional Services is not contingent upon Owner’s reimbursement from the requesting party.
20. Providing Construction Phase services beyond the original date for completion and readiness for final payment of Contractor, but only if such services increase the total quantity of services to be performed in the Construction Phase, rather than merely shifting performance of such services to a later date.
21. Preparing Record Drawings, and furnishing such Record Drawings to Owner.
22. Supplementing Record Drawings with information regarding the completed Specific Project, Site, and immediately adjacent areas obtained from field observations, Owner, utility companies, and other reliable sources.
23. Conducting surveys, investigations, and field measurements to verify the accuracy of Record Drawing content obtained from Contractor, Owner, utility companies, and other sources; revise and supplement Record Drawings as needed.
24. Preparation of operation, maintenance, and staffing manuals.
25. Protracted or extensive assistance in refining and adjusting of Specific Project equipment and systems (such as initial startup, testing, and balancing).
26. Assistance to Owner in training Owner’s staff to operate and maintain Specific Project equipment and systems.
27. Assistance to Owner in developing systems and procedures for (a) control of the operation and maintenance of Specific Project equipment and systems, and (b) related recordkeeping.
28. Preparing to serve or serving as a consultant or witness for, or producing documents for or on behalf of, Owner in any litigation, arbitration, mediation, lien or bond claim, or other legal or administrative proceeding involving the Specific Project (but not including disputes between Owner and Engineer).
29Project. Overtime work requiring higher than regular rates.
30. Providing construction surveys and staking to enable Contractor to perform its work other than as required under Exhibit A Paragraph 1.06.B.9A1.05.A.8; any type of property surveys or related engineering services needed for the transfer of interests in real property; providing construction and property surveys to replace reference points or property monuments lost or destroyed during construction; and providing other special field surveys.
31. Providing more extensive services required to enable Engineer to issue notices or certifications requested by Owner.
32. Extensive services required during any correction period, or with respect to monitoring Contractor’s compliance with warranties and guarantees called for in the Construction Contract (except as agreed to under Basic Services).
33. Other additional services performed or furnished by Engineer not otherwise provided for in this Agreement. Owner: [Name of Owner] Engineer: [Name of Engineer] Effective Date of Agreement: [Effective Date of Agreement] Nature of Amendment: (Check those that apply) ☐ Modifications to responsibilities of Owner ☐ Modifications of payment to Engineer ☐ Modifications to term of Agreement ☐ Modifications to other terms and conditions of the Agreement Description of Modifications: Owner and Engineer hereby agree to modify the above-referenced Agreement as set forth in this Amendment. The Effective Date of the Amendment is [Enter Effective Date of Amendment]. Owner Engineer (typed or printed name of organization) (typed or printed name of organization) By: By: (individual’s signature) (individual’s signature) Date: Date: (date signed) (date signed) Name: Name: (typed or printed) (typed or printed) Title: Title: (typed or printed) (typed or printed).
Appears in 1 contract
Sources: Professional Services
Additional Services Requiring Owner’s Written Authorization. A. If authorized in writing by Owner, Engineer shall provide Additional Services of the types listed below. These services are not included as part of Basic Services and will be paid for by Owner as indicated in Paragraph 7 of the governing Task Order.Exhibit C.
1. Obtain or provide specified additional Specific Project-related information and data to enable Engineer to complete its Basic and Additional Services.
2. Preparation of special and customized reporting, invoicing, and related support documentation in addition to that identified to be provided under Basic Services.
3. Preparation of applications and supporting documents (in addition to those furnished under Basic Services) for private or governmental grants, loans, or advances in connection with the Specific Project; preparation or review of environmental assessments and impact statements; review and evaluation of the effects on the design requirements for the Specific Project of any such statements and documents prepared by others; and assistance in obtaining approvals of authorities having jurisdiction over the anticipated environmental impact of the Specific Project.
42. Services to make measured drawings of existing conditions or facilities, to conduct tests or investigations of existing conditions or facilities, or to verify the accuracy of drawings or other information furnished by Owner or others.
53. Services resulting from significant changes in the scope, extent, or character of the portions of the Specific Project designed or specified by Engineer, or the Specific Project’s design requirements, including, but not limited to, changes in size, complexity, Owner’s schedule, character of construction, or method of financing; and revising previously accepted studies, reports, Drawings, Specifications, or Construction Contract Documents when such revisions are required by changes in Laws and Regulations enacted subsequent to the Effective Date or are due to any other causes beyond Engineer’s control.
64. Services resulting from Owner’s request to evaluate additional Study and Report Phase alternative solutions beyond those agreed to in Exhibit A Paragraph 1.02.A.1A1.01.A.1 and 2.
75. Services required as a result of Owner’s providing incomplete or incorrect Specific Project information to Engineer.
86. Providing renderings or models for Owner’s use, including development, management, and other services in support of building information modeling or civil integrated management.
97. Undertaking investigations and studies including, but not limited to:
a. All-hazards risk assessments and other studies to evaluate the feasibility of enhancing the resiliency of the design;
b. detailed consideration of operations, maintenance, and overhead expenses;
c. b. the preparation of feasibility studies (such as those that include projections of output capacity, utility project rates, project market demand, or project revenues) and cash flow analyses, provided that such services are based on the engineering and technical aspects of the Specific Project, and do not include rendering advice regarding municipal financial products or the issuance of municipal securities;
d. c. preparation of appraisals;
e. with respect to proprietary systems or d. evaluating processes requiring available for licensing, providing services necessary to assist and assisting Owner in obtaining such process licensing.;
f. e. detailed quantity surveys of materials, equipment, and labor; and
g. f. audits or inventories required in connection with construction performed or furnished by Owner.
108. Furnishing services of Subconsultants Consultants for other than Basic Services.
119. Providing data or services of the types described in Article 2Exhibit B, when Owner retains Engineer to provide such data or services instead of Owner furnishing the same.
1210. Providing the following services:
a. Services attributable to more prime construction contracts than specified in Exhibit A Paragraph 1.04.A.1.A1.03.D.
b. Services to arrange for performance of construction services for Owner by contractors other than the principal prime Contractor, and administering Owner’s contract for such services.
1311. Services during out-of-town travel required of Engineer, other than for visits to the Site or Owner’s office as required in Basic Services (Article Part 1 of Exhibit A).
1412. Preparing for, coordinating with, participating in and responding to structured independent review processes, including, but not limited to, construction management, cost estimating, project peer review, value engineering, and constructability review requested by Owner; and performing or furnishing services required to revise studies, reports, Drawings, Specifications, or other documents as a result of such review processes.
1513. Preparing additional bidding-related documents (or requests for proposals or other construction procurement documents); preparing pre-qualification procedures and documents, and participating in pre-qualifying prospective Bidders; and preparing ) or Construction Contract Documents for alternate bidsbids or cost estimates requested by Owner for the Work or a portion thereof.
1614. Assistance in connection with bid protests, rebidding, or renegotiating contracts for construction, materials, equipment, or services., except when such assistance is required to complete services required by Paragraph 5.02.A and Exhibit F.
1715. Preparing conformed Construction Contract Documents that incorporate and integrate the content of all addenda Addenda and any amendments negotiated by Owner and Contractor.
18. Services to assist Owner in developing or modifying protocols for transmittal of Electronic Documents by Electronic Means after the effective date of this Agreement, either by revising or adapting Exhibit F to the Specific Project or implementing other Electronic Documents protocols among Specific Project participants.
19. Any services by Engineer in connection with Owner or Engineer providing a Document to a Requesting Party, or any other distribution of a Document to a third party. Such services may include but are not limited to preparing the data contained in the requested Document in a manner deemed appropriate by Engineer; creating or otherwise preparing and distributing the Document in a format necessary to respond to Owner’s direction or decision to provide the Document to a requesting party, including Contractor, in a format other than that required for deliverables from Engineer to Owner; and services in connection with obtaining required releases from the third parties to which the Documents will be distributed. Compensation for these Additional Services is not contingent upon Owner’s reimbursement from the requesting party.
2016. Providing Construction Phase services beyond the original date for completion and readiness for final payment of Contractor, but only if such services increase the total quantity of services to be performed in the Construction Phase, rather than merely shifting performance of such services to a later date.
2117. Preparing Record Drawings, and furnishing such Record Drawings to Owner.
2218. Supplementing Record Drawings with information regarding the completed Specific Project, Site, and immediately adjacent areas obtained from field observations, Owner, utility companies, and other reliable sources.
2319. Conducting surveys, investigations, and field measurements to verify the accuracy of Record Drawing content obtained from Contractor, Owner, utility companies, and other sources; revise and supplement Record Drawings as needed.
2420. Preparation of operation, maintenance, and staffing manuals.
2521. Protracted or extensive assistance in refining and adjusting of Specific Project equipment and systems (such as initial startup, testing, and balancing).
2622. Assistance to Owner in training Owner’s staff to operate and maintain Specific Project equipment and systems.
2723. Assistance to Owner in developing systems and procedures for (a) control of the operation and maintenance of Specific Project equipment and systems, and (b) related recordkeeping.
2824. Preparing to serve or serving as a consultant or witness for, or producing documents for or on behalf of, Owner in any litigation, arbitration, mediation, lien or bond claim, or other legal or administrative proceeding involving the Specific Project (but not including disputes between Owner and Engineer)Project.
2925. Overtime work requiring higher than regular rates.
3026. Providing construction surveys and staking to enable Contractor to perform its work other than as required under Exhibit A Paragraph 1.06.B.9A1.05.A.8; any type of property surveys or related engineering services needed for the transfer of interests in real property; providing construction and property surveys to replace reference points or property monuments lost or destroyed during construction; and providing other special field surveys.
3127. Providing more extensive services required to enable Engineer to issue notices or certifications requested by Owner.
3228. Extensive services required during any correction period, or with respect to monitoring Contractor’s compliance with warranties and guarantees called for in the Construction Contract (except as agreed to under Basic Services).
3329. Other additional services performed or furnished by Engineer not otherwise provided for in this Agreement. Owner: [Name of Owner] Engineer: [Name of Engineer] Effective Date of Agreement: [Effective Date of Agreement] Nature of Amendment: (Check those that apply) ☐ Modifications to responsibilities of Owner ☐ Modifications of payment to Engineer ☐ Modifications to term of Agreement ☐ Modifications to other terms and conditions of the Agreement Description of Modifications: Owner and Engineer hereby agree to modify the above-referenced Agreement as set forth in this Amendment. The Effective Date of the Amendment is [Enter Effective Date of Amendment]. Owner Engineer (typed or printed name of organization) (typed or printed name of organization) By: By: (individual’s signature) (individual’s signature) Date: Date: (date signed) (date signed) Name: Name: (typed or printed) (typed or printed) Title: Title: (typed or printed) (typed or printed).
Appears in 1 contract
Sources: Agreement Between Owner and Engineer
Additional Services Requiring Owner’s Written Authorization. A. If authorized in writing by Owner, Engineer shall provide Additional Services of the types listed below. These services are not included as part of Basic Services and will be paid for by Owner as indicated in Paragraph 7 of the governing Task Order.
1. Obtain or provide specified additional Specific Project-related information and data to enable Engineer to complete its Basic and Additional Services.
2. Preparation of special and customized reporting, invoicing, and related support documentation in addition to that identified to be provided under Basic Services.
3. Preparation of applications and supporting documents (in addition to those furnished under Basic Services) for private or governmental grants, loans, or advances in connection with the Specific Project; preparation or review of environmental assessments and impact statements; review and evaluation of the effects on the design requirements for the Specific Project of any such statements and documents prepared by others; and assistance in obtaining approvals of authorities having jurisdiction over the anticipated environmental impact of the Specific Project.
4. Services to make measured drawings of existing conditions or facilities, to conduct tests or investigations of existing conditions or facilities, or to verify the accuracy of drawings or other information furnished by Owner or others.
5. Services resulting from significant changes in the scope, extent, or character of the portions of the Specific Project designed or specified by Engineer, or the Specific Project’s design requirements, including, but not limited to, changes in size, complexity, Owner’s schedule, character of construction, or method of financing; and revising previously accepted studies, reports, Drawings, Specifications, or Construction Contract Documents when such revisions are required by changes in Laws and Regulations enacted subsequent to the Effective Date or are due to any other causes beyond Engineer’s control.
6. Services resulting from Owner’s request to evaluate additional Study and Report Phase alternative solutions beyond those agreed to in Exhibit A Paragraph 1.02.A.1.
7. Services required as a result of Owner’s providing incomplete or incorrect Specific Project information to Engineer.
87. Providing renderings or models for Owner’s use, including development, management, and other services in support of building information modeling or civil integrated management.
8. Preparing a project manual, bidding documents and construction contract documents associated with an EJCDC construction contract.
9. Undertaking investigations and studies includingServices associated with public involvement, but not limited to:
a. All-hazards risk assessments including meetings, mailings and other studies to evaluate the feasibility of enhancing the resiliency of the design;
b. detailed consideration of operations, maintenance, and overhead expenses;
c. the preparation of feasibility studies (such as those that include projections of output capacity, utility project rates, project market demand, or project revenues) and cash flow analyses, provided that such services are based on the engineering and technical aspects of the Specific Project, and do not include rendering advice regarding municipal financial products or the issuance of municipal securities;
d. preparation of appraisals;
e. with respect to proprietary systems or processes requiring licensing, providing services necessary to assist Owner in obtaining such licensing.
f. detailed quantity surveys of materials, equipment, and labor; and
g. audits or inventories required in connection with construction performed or furnished by Ownerassociated tasks.
10. Furnishing services of Subconsultants for other than Basic ServicesServices resulting from Owner’s request to modify previously approved deliverables.
11. Providing data or services of the types described in Article 2, when Owner retains Engineer to provide such data or services instead of Owner furnishing the same.
12. Providing the following services:
a. Services attributable to more prime construction contracts than specified in Exhibit A Paragraph 1.04.A.1.
b. Services to arrange for performance of construction services for Owner by contractors other than the principal prime Contractor, and administering Owner’s contract for such services.
13. Services during out-of-town travel required of Engineer, other than for visits to the Site or Owner’s office as required in Basic Services (Article 1 of Exhibit A).
14. Preparing for, coordinating with, participating in and responding to structured independent review processes, including, but not limited to, construction management, cost estimating, project peer review, value engineering, and constructability review requested by Owner; and performing or furnishing services required to revise studies, reports, Drawings, Specifications, or other documents as a result of such review processes.
15. Preparing additional bidding-related documents (or requests for proposals or other construction procurement documents); preparing pre-qualification procedures and documents, and participating in pre-qualifying prospective Bidders; and preparing Construction Contract Documents for alternate bids.
16. Assistance in connection with bid protests, rebidding, or renegotiating contracts for construction, materials, equipment, or services.
17. Preparing conformed Construction Contract Documents that incorporate and integrate the content of all addenda and any amendments negotiated by Owner and Contractor.
18. Services to assist Owner in developing or modifying protocols for transmittal of Electronic Documents by Electronic Means after the effective date of this Agreement, either by revising or adapting Exhibit F to the Specific Project or implementing other Electronic Documents protocols among Specific Project participants.
1912. Any services by Engineer in connection with Owner or Engineer providing a Document to a Requesting PartyParty under Exhibit F Paragraph 1.01.D (see Exhibit F, Electronic Documents Protocol), or any other distribution of a Document to a third party. Such services may include but are not limited to preparing the data contained in the requested Document in a manner deemed appropriate by Engineer; creating or otherwise preparing and distributing the Document in a format necessary to respond to Owner’s direction or decision to provide the Document to a requesting party, including Contractor, in a format other than that required for deliverables from Engineer to Owner; and services in connection with obtaining required releases from the third parties to which the Documents will be distributed. Compensation for these Additional Services is not contingent upon Owner’s reimbursement from the requesting party.
20. Providing Construction Phase services beyond the original date for completion and readiness for final payment of Contractor, but only if such services increase the total quantity of services to be performed in the Construction Phase, rather than merely shifting performance of such services to a later date.
21. Preparing Record Drawings, and furnishing such Record Drawings to Owner.
22. Supplementing Record Drawings with information regarding the completed Specific Project, Site, and immediately adjacent areas obtained from field observations, Owner, utility companies, and other reliable sources.
23. Conducting surveys, investigations, and field measurements to verify the accuracy of Record Drawing content obtained from Contractor, Owner, utility companies, and other sources; revise and supplement Record Drawings as needed.
24. Preparation of operation, maintenance, and staffing manuals.
25. Protracted or extensive assistance in refining and adjusting of Specific Project equipment and systems (such as initial startup, testing, and balancing).
26. Assistance to Owner in training Owner’s staff to operate and maintain Specific Project equipment and systems.
27. Assistance to Owner in developing systems and procedures for (a) control of the operation and maintenance of Specific Project equipment and systems, and (b) related recordkeeping.
2813. Preparing to serve or serving as a consultant or witness for, or producing documents for or on behalf of, Owner in any litigation, arbitration, mediation, lien or bond claim, or other legal or administrative proceeding involving the Specific Project (but not including disputes between Owner and Engineer).
29. Overtime work requiring higher than regular rates.
30. Providing construction surveys and staking to enable Contractor to perform its work other than as required under Exhibit A Paragraph 1.06.B.9; any type of property surveys or related engineering services needed for the transfer of interests in real property; providing construction and property surveys to replace reference points or property monuments lost or destroyed during construction; and providing other special field surveys.
31. Providing more extensive services required to enable Engineer to issue notices or certifications requested by Owner.
32. Extensive services required during any correction period, or with respect to monitoring Contractor’s compliance with warranties and guarantees called for in the Construction Contract (except as agreed to under Basic Services).
3314. Other additional services performed or furnished by Engineer not otherwise provided for in this Agreement. Owner: [Name of Owner] Engineer: [Name of Engineer] Effective Date of Agreement: [Effective Date of Agreement] Nature of Amendment: (Check those that apply) ☐ Modifications to responsibilities of Owner ☐ Modifications of payment to Engineer ☐ Modifications to term of Agreement ☐ Modifications to other terms and conditions of the Agreement Description of Modifications: Owner and Engineer hereby agree to modify the above-referenced Agreement as set forth in this Amendment. The Effective Date of the Amendment is [Enter Effective Date of Amendment]. Owner Engineer (typed or printed name of organization) (typed or printed name of organization) By: By: (individual’s signature) (individual’s signature) Date: Date: (date signed) (date signed) Name: Name: (typed or printed) (typed or printed) Title: Title: (typed or printed) (typed or printed).
Appears in 1 contract
Sources: Task Order
Additional Services Requiring Owner’s Written Authorization. A. If authorized in writing by Owner, Engineer shall provide furnish or obtain from others Additional Services of the types listed below. These services are not included as part of Basic Services and will be paid for by Owner as indicated in Paragraph 7 of the governing Task Order.
1. Obtain or provide specified additional Specific Project-related information and data to enable Engineer to complete its Basic and Additional Services.
2. Preparation of special and customized reporting, invoicing, and related support documentation in addition to that identified to be provided under Basic Services.
3. Preparation of applications and supporting documents (in addition to those furnished under Basic Services) for private or governmental grants, loans, or advances grants in connection with the Specific Project; preparation or review of environmental assessments and impact statements; review and evaluation of the effects on the design requirements for the Specific Project of any such statements and documents prepared by others; and assistance in obtaining approvals of authorities having jurisdiction over the anticipated environmental impact of the Specific Project.
42. Services to make measured drawings of existing conditions or facilities, to conduct tests or investigations of investigate existing conditions or facilities, or to verify the accuracy of drawings or other information furnished by Owner or others.
53. Services resulting from significant changes in the scope, extent, or character of the portions of the Specific Project designed or specified by Engineer, Engineer or the Specific Project’s its design requirements, requirements including, but not limited to, changes in size, complexity, Owner’s schedule, character of construction, or method of financing; and revising previously accepted studies, reports, Drawings, Specifications, or Construction Contract Documents when such revisions are required by changes in Laws and Regulations enacted subsequent to the Effective Date of this Agreement or are due to any other causes beyond Engineer’s control.
64. Services resulting from Owner’s request to evaluate additional Study and Report Phase alternative solutions beyond those agreed to identified in Exhibit A Paragraph 1.02.A.1this Agreement.
75. Services required as a result of Owner’s providing incomplete or incorrect Specific Project information to Engineer.
86. Providing renderings or models for Owner’s use.
7. Providing assistance with Environmental Assessments, including developmentarcheological reconnaissance, managementenvironmental reviews performed by others, and/or in resolving any Hazardous Environmental Condition in compliance with current Laws and Regulations.
8. Conducting or attending meetings called by the Owner with property owners, business leaders and residents to discuss easements and rights-of-way and land to be acquired, or other services in support elements or matters of building information modeling or civil integrated managementthe Project.
9. Appearances before courts, boards, or commissions on matters of public hearings, permit protests, bid protests or litigation related to the Project.
10. Undertaking investigations and studies including, but not limited to:
a. All-hazards risk assessments and other studies to evaluate the feasibility of enhancing the resiliency of the design;
b. , detailed consideration of operations, maintenance, and overhead expenses;
c. ; the preparation of feasibility studies (such as those that include projections of output capacitystudies, utility project rates, project market demand, or project revenues) and cash flow analysesand economic evaluations, provided that such services are based on the engineering and technical aspects of the Specific Projectrate schedules, and do not include rendering advice regarding municipal financial products or appraisals; assistance in obtaining financing for the issuance of municipal securities;
d. preparation of appraisals;
e. with respect to proprietary systems or Project; evaluating processes requiring available for licensing, providing services necessary to assist and assisting Owner in obtaining such process licensing.
f. ; detailed quantity surveys of materials, equipment, and labor; and
g. and audits or inventories required in connection with construction performed or furnished by Owner.
1011. Preparation of Operation and Maintenance manuals.
12. Furnishing services of Subconsultants Engineer’s Consultants for other than Basic Services.
1113. Providing data or services of the types described in Article 2, when Owner retains Engineer to provide such data or services instead of Owner furnishing the same.
12. Providing the following services:
a. Services attributable to more prime construction contracts than specified in Exhibit A Article I, Paragraph 1.04.A.11.E of this Agreement.
b. Services to arrange for performance of construction services for Owner by contractors other than the principal prime Contractor, and administering Owner’s contract for such services.
1314. Services during out-of-town travel required of Engineer, Engineer other than for visits to the Site or Owner’s office as required in Basic Services (Article 1 of Exhibit A)office.
1415. Preparing for, coordinating with, participating in and responding to structured independent review processes, including, but not limited to, construction management, cost estimating, project peer review, value engineering, and constructability review requested by Owner; and performing or furnishing services required to revise studies, reports, Drawings, Specifications, or other documents Bidding Documents as a result of such review processes.
1516. Preparing additional bidding-related documents (Bidding Documents or requests for proposals or other construction procurement documents); preparing pre-qualification procedures and documents, and participating in pre-qualifying prospective Bidders; and preparing Construction Contract Documents for alternate bidsbids or prices requested by Owner for the Work or a portion thereof.
1617. Determining the acceptability of substitute materials and equipment proposed during the Bidding or Negotiating Phase when substitution prior to the award of contracts is allowed by the Bidding Documents.
18. Assistance in connection with bid Bid protests, rebidding, or renegotiating contracts for construction, materials, equipment, or services.
17. Preparing conformed Construction Contract Documents that incorporate and integrate the content of all addenda and any amendments negotiated by Owner and Contractor.
18. Services to assist Owner in developing or modifying protocols for transmittal of Electronic Documents by Electronic Means after the effective date of this Agreement, either by revising or adapting Exhibit F to the Specific Project or implementing other Electronic Documents protocols among Specific Project participants.
19. Any services by Engineer in connection with Owner or Engineer providing a Document to a Requesting Party, or any other distribution of a Document to a third party. Such services may include but are not limited to preparing the data contained in the requested Document in a manner deemed appropriate by Engineer; creating or otherwise preparing and distributing the Document in a format necessary to respond to Owner’s direction or decision to provide the Document to a requesting party, including Contractor, in a format other than that required for deliverables from Engineer to Owner; and services in connection with obtaining required releases from the third parties to which the Documents will be distributed. Compensation for these Additional Services is not contingent upon Owner’s reimbursement from the requesting party.
20. Providing Construction Phase services beyond the original date for completion and readiness for final payment of Contractor, but only if such services increase the total quantity of services to be performed in the Construction Phase, rather than merely shifting performance of such services to a later date.
21. Preparing Record Drawings, and furnishing such Record Drawings to Owner.
22. Supplementing Record Drawings with information regarding the completed Specific Project, Site, and immediately adjacent areas obtained from field observations, Owner, utility companies, and other reliable sources.
23. Conducting surveys, investigations, and field measurements to verify the accuracy of Record Drawing content obtained from Contractor, Owner, utility companies, and other sources; revise and supplement Record Drawings as needed.
24. Preparation of operation, maintenance, and staffing manuals.
25. Protracted or extensive assistance in refining and adjusting of Specific Project equipment and systems (such as initial startup, testing, and balancing).
26. Assistance to Owner in training Owner’s staff to operate and maintain Specific Project equipment and systems.
27. Assistance to Owner in developing systems and procedures for (a) control of the operation and maintenance of Specific Project equipment and systems, and (b) related recordkeeping.
28. Preparing to serve or serving as a consultant or witness for, or producing documents for or on behalf of, Owner in any litigation, arbitration, mediation, lien or bond claim, or other legal or administrative proceeding involving the Specific Project (but not including disputes between Owner and Engineer).
29. Overtime work requiring higher than regular rates.
30. Providing construction surveys and staking to enable Contractor to perform its work other than as required under Exhibit A Paragraph 1.06.B.9; work, and any type of property surveys or related engineering services needed for the transfer of interests in real property; providing construction and property surveys to replace reference points or property monuments lost or destroyed during construction; and providing other special field surveys.
3120. Providing Construction Phase services beyond the original date for final completion of the Work.
21. Providing assistance in responding to the presence of any Constituent of Concern at the Site, in compliance with current Laws and Regulations.
22. Preparing to serve or serving as a consultant or witness for Owner in any litigation, arbitration, or other dispute resolution process related to the Project.
23. Providing more extensive services required to enable Engineer to issue notices or certifications requested by Owner.
32. Extensive services required during any correction period, or with respect to monitoring Contractor’s compliance with warranties and guarantees called for in the Construction Contract (except as agreed to under Basic Services).
3324. Other additional services performed or furnished by Engineer not otherwise provided for in this Agreement. Owner: [Name of Owner] Engineer: [Name of Engineer] Effective Date of Agreement: [Effective Date of Agreement] Nature of Amendment: (Check those that apply) ☐ Modifications to responsibilities of Owner ☐ Modifications of payment to Engineer ☐ Modifications to term of Agreement ☐ Modifications to other terms and conditions of the Agreement Description of Modifications: Owner and Engineer hereby agree to modify the above-referenced Agreement as set forth in this Amendment. The Effective Date of the Amendment is [Enter Effective Date of Amendment]. Owner Engineer (typed or printed name of organization) (typed or printed name of organization) By: By: (individual’s signature) (individual’s signature) Date: Date: (date signed) (date signed) Name: Name: (typed or printed) (typed or printed) Title: Title: (typed or printed) (typed or printed).
Appears in 1 contract
Sources: Engineering Services Agreement