Treatment of Unallowable Costs Previously Submitted for Payment Defendants further agree that within 90 days of the Effective Date of this Agreement they shall identify to applicable Medicare and TRICARE fiscal intermediaries, carriers, and/or contractors, and Medicaid and FEHBP fiscal agents, any Unallowable Costs (as defined in this paragraph) included in payments previously sought from the United States, or any State Medicaid program, including, but not limited to, payments sought in any cost reports, cost statements, information reports, or payment requests already submitted by Defendants or any of their subsidiaries or affiliates, and shall request, and agree, that such cost reports, cost statements, information reports, or payment requests, even if already settled, be adjusted to account for the effect of the inclusion of the Unallowable Costs. Defendants agree that the United States, at a minimum, shall be entitled to recoup from Defendants any overpayment plus applicable interest and penalties as a result of the inclusion of such Unallowable Costs on previously-submitted cost reports, information reports, cost statements, or requests for payment. Any payments due after the adjustments have been made shall be paid to the United States pursuant to the direction of the Department of Justice and/or the affected agencies. The United States reserves its rights to disagree with any calculations submitted by Defendants or any of their subsidiaries or affiliates on the effect of inclusion of Unallowable Costs (as defined in this paragraph) on Defendants or any of their subsidiaries or affiliates’ cost reports, cost statements, or information reports.
Complete Work without Extra Cost Except to the extent otherwise specifically stated in this contract, the Contractor shall obtain and provide, without additional cost to the City, all labor, materials, equipment, transportation, facilities, services, permits, and licenses necessary to perform the Work.
PROGRESS EVALUATION Engineer shall, from time to time during the progress of the Engineering Services, confer with County at County’s election. Engineer shall prepare and present such information as may be pertinent and necessary, or as may be reasonably requested by County, in order for County to evaluate features of the Engineering Services. At the request of County or Engineer, conferences shall be provided at Engineer's office, the offices of County, or at other locations designated by County. When requested by County, such conferences shall also include evaluation of the Engineering Services. County may, from time to time, require Engineer to appear and provide information to the Williamson County Commissioners Court. Should County determine that the progress in Engineering Services does not satisfy an applicable Work Authorization or any Supplemental Work Authorization related thereto, then County shall review same with Engineer to determine corrective action required. Engineer shall promptly advise County in writing of events which have or may have a significant impact upon the progress of the Engineering Services, including but not limited to the following: A. Problems, delays, adverse conditions which may materially affect the ability to meet the objectives of an applicable Work Authorization or any Supplemental Work Authorization related thereto, or preclude the attainment of Project Engineering Services units by established time periods; and such disclosure shall be accompanied by statement of actions taken or contemplated, and County assistance needed to resolve the situation, if any; and B. Favorable developments or events which enable meeting goals sooner than anticipated in relation to an applicable Work Authorization’s or any Supplemental Work Authorization related thereto.
Indemnification for Expenses of a Party Who is Wholly or Partly Successful Notwithstanding any other provisions of this Agreement except for Section 27, to the extent that Indemnitee was or is, by reason of Indemnitee’s Corporate Status, a party to (or a participant in) and is successful, on the merits or otherwise, in any Proceeding or in defense of any claim, issue or matter therein, in whole or in part, the Company shall, to the fullest extent permitted by applicable law, indemnify, hold harmless and exonerate Indemnitee against all Expenses actually and reasonably incurred by him or her in connection therewith. If Indemnitee is not wholly successful in such Proceeding but is successful, on the merits or otherwise, as to one or more but less than all claims, issues or matters in such Proceeding, the Company shall, to the fullest extent permitted by applicable law, indemnify, hold harmless and exonerate Indemnitee against all Expenses actually and reasonably incurred by him or her or on his or her behalf in connection with each successfully resolved claim, issue or matter. If Indemnitee is not wholly successful in such Proceeding, the Company also shall, to the fullest extent permitted by applicable law, indemnify, hold harmless and exonerate Indemnitee against all Expenses reasonably incurred in connection with a claim, issue or matter related to any claim, issue, or matter on which Indemnitee was successful. For purposes of this Section and without limitation, the termination of any claim, issue or matter in such a Proceeding by dismissal, with or without prejudice, shall be deemed to be a successful result as to such claim, issue or matter.
Statewide HUB Program Statewide Procurement Division Note: In order for State agencies and institutions of higher education (universities) to be credited for utilizing this business as a HUB, they must award payment under the Certificate/VID Number identified above. Agencies, universities and prime contractors are encouraged to verify the company’s HUB certification prior to issuing a notice of award by accessing the Internet (▇▇▇▇▇://▇▇▇▇▇.▇▇▇.▇▇▇▇▇.▇▇.▇▇/tpasscmblsearch/index.jsp) or by contacting