Agreement or Dispute Sample Clauses

The "Agreement or Dispute" clause defines the procedures and expectations for resolving disagreements that may arise between parties under a contract. Typically, this clause outlines steps such as negotiation, mediation, or arbitration before resorting to litigation, and may specify timelines or forums for dispute resolution. Its core function is to provide a clear, structured process for addressing conflicts, thereby minimizing uncertainty and reducing the risk of prolonged or costly legal battles.
Agreement or Dispute. The agreement of the parties as to the specific relief to be given the Developer on account of a Supervening Event shall be evidenced by a Contract Administration Memorandum, a Comprehensive Agreement Amendment or a Change Order, as applicable. Either party may refer any dispute regarding a Supervening Event to Mediation or to the Dispute Resolution Procedure.
View Source
Agreement or Dispute. The agreement of the Parties as to the specific relief to be given the Contractor on account of an Uncontrollable Circumstance shall be evidenced by a Contract Administration Memorandum or a Contract Amendment. Either Party may refer any dispute for resolution in accordance with Section 13.1 (Dispute Resolution Procedures).
View Source
Agreement or Dispute. The agreement of the parties as to the specific relief to be given the Design-Builder on account of an Uncontrollable Circumstance shall be evidenced by a Change Order, a Contract Amendment or other written agreement between the parties. Either party may refer any dispute for resolution in accordance with Section 36.1..
View Source
Agreement or Dispute. The agreement of the parties as to the specific relief to be given the DBOM Contractor on account of an Uncontrollable Circumstance will be evidenced by a Contract Administration Memorandum (subject to the limitations set forth in Section 22.3 (Service Agreement Administration)), Change Order (entered into in accordance with Section 16.1 (Change Procedures)) or a Contract Amendment, as applicable. In the event of any dispute of the parties concerning Uncontrollable Circumstance relief, the DBOM Contractor may initiate the dispute resolution procedures in accordance with Section 16.3 (Authority to Resolve Contract and Breach of Contract Controversies).
View Source
Agreement or Dispute. 11.2.10.1 The agreement of the Parties as to the specific compensation, time extension and/or other relief to be given Developer on account of a Relief Event shall be evidenced by a written confirmation that includes all pertinent information, references, and data to support the claim, including updated analyses, descriptions, actual amounts and impacts (including, with respect to any Relief Event Delay, information required under Section 11.2.4.4, updated to reflect actual amounts and impacts), and any other documentation covering the same scope of information as required for the request for specific relief, which written confirmation shall be promptly prepared by the Parties and signed by the Parties’ Authorized Representatives. 11.2.10.2 Developer shall submit the full and final documentation of the Relief Event Claim in the form attached as Appendix 25-D, certified by Developer’s Authorized Representative to be accurate, truthful and complete. Information submitted subsequent to the full and final documentation submittal will not be considered. No full and final documentation of a Relief Event Claim will be considered that does not have the same nature, scope (except for reductions) and circumstances, and basis of claim, as those specified in the Relief Event Notice and any updates submitted in accordance with Section 11.2.3 and in the Relief Event Claim. 11.2.10.3 In the event the Parties are unable to agree as to the specific compensation, time extension and/or other relief to be given Developer on account of a Relief Event, the Owner shall pay or grant, as applicable, any undisputed portion of compensation, time extension and/or other relief, and either Party may refer the disputed portion of the Relief Event Claim to the Dispute Resolution Procedures. If the Owner is deemed to have rejected the Relief Event Claim as provided in Section 11.2.9, Developer may refer the matter to the Dispute Resolution Procedures.
View Source

Related to Agreement or Dispute

  • Dispute In the event of any dispute whatsoever in respect of the sale, the Purchaser hereby expressly agrees to resolve the same with the Assignee.

  • Settlement of Dispute Any disputes under the Agreement shall be settled at first through friendly consultation between the parties hereto. In case no settlement can be reached through consultation, each party shall have the right to submit such disputes to China International Economic and Trade Arbitration Commission in Beijing. The Place of arbitration is Beijing. The arbitration award shall be final and binding on both parties.

  • Litigation; Disputes No legal action may be brought against NCCI, its shareholders, officers, employees, and/or agents for actions taken reasonably and in good faith in fulfilling the specifically stated responsibilities of NCCI under this Agreement. NCCI reserves the right to obtain a determination from a court of competent jurisdiction as to the ownership of funds and/or documents in its possession in the event it receives conflicting instructions, instructions which are, in the opinion of NCCI, inconsistent with this Agreement, or if NCCI fails to receive instructions which NCCI concludes that it requires to fulfill its duties under this Agreement.

  • Settlement of Disputes between the contracting parties 1. Any dispute between the Contracting Parties concerning the interpretation or application of this Agreement shall, if possible, be settled through diplomatic channels. 2. If any dispute between the Contracting Parties cannot be settled within six months (6) It shall upon the request of either Contracting Party, be submitted to an arbitral tribunal. 3. Such an arbitral tribunal shall be constituted for each individual case in the following way. Within two (2) months of the receipt of the request for arbitration, each Contracting Party shall appoint one member of the Tribunal. The two members shall then select a national of a third State, who on approval by the two Contracting Parties shall be appointed Chairman of the Tribunal. The Chairman shall be appointed within two (2) months from the date of appointment of the other two members. 4. If within the periods specified in paragraph 3 of this article the necessary appointments have not been made, either Contracting Party may, in the absence of any other agreement, invite the President of the International Court of Justice to make the necessary appointments. If the President is a national of either Contracting Party or if he is otherwise prevented from discharging the said function, the Vice-President shall be invited to make the necessary appointments. if the Vice- President is a national of either Contracting Party or if he is also prevented from discharging the function, the said member of the International Court of Justice the oldest who is not a national of either Contracting Party shall be invited to make the necessary appointments. 5. The arbitral tribunal shall reach its decisions by a majority of votes and shall be binding on both contracting parties. each Contracting Party shall assume the costs of its own member of the Tribunal and of its representation in the arbitral proceedings; the cost of the Chairman and the remaining costs shall be borne in equal parts by the contracting parties. The Tribunal may, however, in its decision that a higher proportion of direct costs shall be borne by one of the two contracting parties, and this decision shall be binding on both contracting parties. the tribunal shall determine its own rules of procedure for all other matters. 6. The arbitral tribunal shall make its decision on the basis of this Agreement and any agreement in force between the two parties and international law in general and take into account, as appropriate, the domestic law of the Contracting Party where the investment concerned is located.

  • Payment Disputes We will not exercise Our rights under Section 6.3 (Overdue Charges) or 6.4 (Suspension of Service and Acceleration) above if You are disputing the applicable charges reasonably and in good faith and are cooperating diligently to resolve the dispute.