BUILDER’S RISK FOR CONSTRUCTION RENOVATION PROJECTS If the project is CONSTRUCTION RENOVATION of an existing structure, and the State has already determined that Contractor will not be obligated to obtain and maintain Builder’s Risk insurance, then the following provisions apply: (1) The State will maintain property insurance upon the construction site and will not require Contractor to purchase and maintain Builder's Risk Insurance upon the entire work at the site. (2) The decision of the State to waive the requirement that the Contractor maintain builder’s risk coverage does not waive Contractor’s liability for damage to the State’s real and personal property. Contractor’s liability for loss to the State’s real and personal property will be limited to the first $100,000 of each and every property loss at the work site provided such loss is covered under the State’s property insurance coverage. If the Contractor elects to meet this obligation by purchase of commercial insurance, this insurance shall name the Contractor and the State of Vermont as Named Insureds and shall include the interests of the Contractor and Subcontractors. Other parties shall be insured as the State may reasonably require. (3) Contractor shall effect and maintain insurance on portions of the work stored off-site, on site and in transit. Boiler & Machinery Insurance may be used in conjunction with this coverage if it is required to meet the testing requirement. The cost of any deductible applicable to loss covered by insurance provided hereunder shall be borne by the Contractor. (4) Except as provided for in 11.2.2 (1)-(3) above the State and Contractor waive all rights against each other and the Subcontractor, Sub-subcontractors, agents and employees of the other.
BUILDER’S RISK FOR NEW CONSTRUCTION PROJECTS If the project is NEW CONSTRUCTION, then the following provisions apply: (1) The State will require Contractor to purchase and maintain Builder's Risk Insurance. The Contractor shall name the Contractor and the State of Vermont as their interest may occur. Other parties shall be insured as the State may reasonably require. (2) Contractor shall effect and maintain insurance on portions of the work stored off-site, on site and in transit. Boiler & Machinery Insurance may be used in conjunction with this coverage if it is required to meet the testing requirement. (3) Any deductible applicable to loss covered by insurance provided hereunder shall be borne by the Contractor. (4) Except as provided for in (1) above the State and Contractor waive all rights against each other and the Subcontractor, Sub-subcontractors, agents and employees of the other.
Commencement and Completion of Construction Subject to Unavoidable Delays, Developer shall cause construction of the Minimum Improvements to be undertaken and completed: (i) by no later than June 1, 2020; or (ii) by such other date as the parties shall mutually agree upon in writing. Time lost as a result of Unavoidable Delays shall be added to extend this date by a number of days equal to the number of days lost as a result of Unavoidable Delays. All work with respect to the Minimum Improvements shall be in conformity with the Construction Plans approved by the building official or any amendments thereto as may be approved by the building official. Developer agrees that it shall permit designated representatives of the City, upon reasonable notice (which does not have to be written), to enter upon the Development Property during the construction of the Minimum Improvements to inspect such construction and the progress thereof.
Law; Construction This Agreement and any claim, counterclaim or dispute of any kind or nature whatsoever arising out of or in any way relating to this Agreement (“Claim”), directly or indirectly, shall be governed by, and construed in accordance with, the internal laws of the State of New York.
Review and Construction of Documents Each Party herein expressly represents and warrants to all other Parties hereto that (a) before executing this Agreement, said Party has fully informed itself of the terms, contents, conditions and effects of this Agreement; (b) said Party has relied solely and completely upon its own judgment in executing this Agreement; (c) said Party has had the opportunity to seek and has obtained the advice of its own legal, tax and business advisors before executing this Agreement; (d) said Party has acted voluntarily and of its own free will in executing this Agreement; and (e) this Agreement is the result of arm’s length negotiations conducted by and among the Parties and their respective counsel.