Approved Project Schedule Clause Samples

The Approved Project Schedule clause defines the official timeline for a project's key milestones, deliverables, and completion dates as agreed upon by all parties. This schedule typically outlines specific deadlines for phases such as design, procurement, construction, and final delivery, and may include provisions for updates or revisions if circumstances change. Its core practical function is to establish a clear, mutually accepted framework for project timing, helping to coordinate activities, manage expectations, and reduce the risk of disputes over delays or missed deadlines.
Approved Project Schedule. Except as the State determines otherwise in writing, the Subrecipient agrees that it shall follow all required project schedules, timelines, and milestone progress reports.
View SourceView Similar (6)
Approved Project Schedule. Developer, in consultation with the General Contractor and Design Consultants, shall prepare for Tenant’s approval a schedule for the preconstruction and construction phases of the Project (the “Approved Project Schedule”) that integrates the services of Contractors, Design Consultants and other third parties for the preparation of all design documents, the processing of all Entitlements and other governmental approvals, environmental remediation activities, the pre-purchasing of materials and equipment, the commencement of construction, and the attainment of designated milestones by the appropriate contractors and for the Project in general, including, without limitation, (a) the commencement of material grading and other site work on the Property in accordance with Entitlements and Approved Plans for the Project (the “Construction Commencement Date”), (b) the filing of the final plat of the Property and obtaining all permits necessary for construction of the Project; (c) the occurrence of Substantial Completion; and (d) the occurrence of Final Completion (the “Scheduled Completion Date”). Notwithstanding the foregoing or anything else herein to the contrary, all milestones included in the Approved Project Schedule (i) shall only be reasonable estimates of certain stages and components of the construction process, and (ii) shall not create any obligation on, or otherwise be binding upon, Developer or cause Developer to be in default under this Agreement if any milestone does not occur on the applicable specified date; provided, that the failure of Final Completion of the Project to occur not later than the Scheduled Completion Date may cause Developer to incur delay damages as provided in Section 2.7.17. Upon approval by Tenant and Developer, the Approved Project Schedule shall be signed titled as such, and shall be signed and dated by Tenant and Developer. No other schedule published by or on behalf of Developer shall be titled “Approved Project Schedule” unless it is a contractual update, agreed to in writing and signed and dated by both Tenant and Developer.
View Source
Approved Project Schedule. Developer and Tenant have approved the project schedule attached hereto as Exhibit “B”, and agree that same constitutes the “Approved Project Schedule” under the Development Agreement.
View Source
Approved Project Schedule. Use the approved Project Schedule to measure the progress of the work and to aid in evaluating time extensions. Make the schedule cost loaded and activity coded. The schedule will provide the basis for all progress payments. If the Contractor fails to submit any schedule within the time prescribed, the Contracting Officer may withhold approval of progress payments until the Contractor submits the required schedule.
View Source

Related to Approved Project Schedule

  • Project Schedule Construction must begin within 30 days of the date set forth in Appendix A, Page 2, for the start of construction, or this Agreement may become null and void, at the sole discretion of the Director. However, the Recipient may apply to the Director in writing for an extension of the date to initiate construction. The Recipient shall specify the reasons for the delay in the start of construction and provide the Director with a new start of construction date. The Director will review such requests for extensions and may extend the start date, providing that the Project can be completed within a reasonable time frame.

  • Project Budget A Project Budget shall be prepared and maintained by Grantee. The Project Budget shall detail all costs for which the Grant will be used during the Term. The Project Budget must be approved in writing by the Project Monitor. Grantee shall carry out the Project and shall incur costs and make disbursements of funds provided hereunder by the Sponsor only in conformity with the Project Budget. The current approved Project Budget is contained in Attachment “C”. Said Project Budget may be revised from time to time, but no Project Budget or revision thereof shall be effective unless and until the same is approved in writing by Project Monitor. The funds granted under this Grant Contract cannot be used to supplant (replace) other existing funds.

  • Development Schedule The Project shall substantially comply with the specific timetables and triggers for action set forth in Article 5 of this Agreement. The parties acknowledge that, as provided in G.S. 160A-400.25(b), the failure to meet a commencement or completion date shall not, in and of itself, constitute a material breach of this Agreement pursuant to G.S. 160A-400.27 but must be judged based upon the totality of the circumstances.

  • Construction Budget The total amount of funds indicated by the District for the entire Project plus all other costs, including design, construction, administration, and financing.

  • Work Schedule (A) Where an employee has an established schedule, a change in workdays or shifts will be posted no less than 14 calendar days in advance and will reflect at least a two workweek schedule; however, the state will make a good faith effort to reflect a one month schedule. (B) In the event of a declared emergency the notice requirement of this Section may be void. (C) The state will continue to observe the scheduling structures currently in place at each agency and agrees to bargain any change in the overall practice of how schedules are established.