Performance Orders A Performance Order: (a) is an order made under clause 13.3.3(b), relating to a Relevant Dispute, whether by way of interim or final relief; and (b) may be applied for by Network Rail or the Train Operator in the circumstances set out in clause 8.1, subject to the qualifications in clause 17.8, and an application for a Performance Order shall be without prejudice to any other remedy available to the claimant under this contract (whether final or interim and whether by way of appeal under the Network Code or otherwise).
Purchase Order Duration Purchase orders issued pursuant to this State Term Contract must be received by the Contractor no later than close of business on the last day of the Contract’s term to be considered timely. The Contractor is obliged to fill those orders in accordance with the Contract’s terms and conditions. Purchase orders received by the Contractor after close of business on the last day of the State Term Contract’s term shall be considered void. Purchase orders for a one-time performance of contractual services shall be valid through the performance by the Contractor, and all terms and conditions of the State Term Contract shall apply to the single delivery/performance, and shall survive the termination of the Contract. Contractors are required to accept purchase orders specifying delivery schedules exceeding the contracted schedule even when such extended delivery will occur after expiration of the State Term Contract. For example, if a state term contract calls for delivery 30 days after receipt of order (ARO), and an order specifies delivery will occur both in excess of 30 days ARO and after expiration of the state term contract, the Contractor will accept the order. However, if the Contractor expressly and in writing notifies the ordering office within ten (10) calendar days of receipt of the purchase order that Contractor will not accept the extended delivery terms beyond the expiration of the state term contract, then the purchase order will either be amended in writing by the ordering entity within ten (10) calendar days of receipt of the contractor’s notice to reflect the state term contract delivery schedule, or it shall be considered withdrawn. The duration of purchase orders for recurring deliveries of commodities or performance of services shall not exceed the expiration of the State Term Contract by more than twelve months. However, if an extended pricing plan offered in the State Term Contract is selected by the Customer, the Contract terms on pricing plans shall govern the maximum duration of purchase orders reflecting such pricing plans. Timely purchase orders shall be valid through their specified term and performance by the Contractor, and all terms and conditions of the State Term Contract shall apply to the recurring delivery/performance as provided herein, and shall survive the termination of the Contract. Ordering offices shall not renew a purchase order issued pursuant to a State Term Contract if the underlying contract expires prior to the effective date of the renewal.
Project Delivery Order Procedures The TIPS Member having approved and signed an interlocal agreement, or other TIPS Membership document, may make a request of the awarded vendor under this Agreement when the TIPS Member has services that need to be undertaken. Notification may occur via phone, the web, email, fax, or in person. Upon notification of a pending request, the awarded vendor shall make contact with the TIPS Member as soon as possible, but must make contact with the TIPS Member within two working days. Scheduling of projects (if applicable) may be accomplished when the TIPS Member issues a Purchase Order and/or an Agreement or Contract that will serve as “the notice to proceed” as agreed by the Vendor and the TIPS Member. The period for the delivery order will include the mobilization, materials purchase, installation and delivery, design, weather, and site cleanup and inspection. No additional claims may be made for delays as a result of these items. When the tasks have been completed the awarded vendor shall notify the client and have the TIPS Member or a designated representative of the TIPS Member inspect the work for acceptance under the scope and terms in the Purchase Order and/or Agreement or Contract. The TIPS Member will issue in writing any corrective actions that are required. Upon completion of these items, the TIPS Member will issue a completion notice and final payment will be issued per the contractual requirements of the project with the TIPS Member. Any Construction contract prepared by the TIPS Member’s Legal Counsel may alter the terms of this subsection, “Scheduling of Projects”.
Order Rejections 53.11.1 CenturyLink shall reject and return to CLEC any order that CenturyLink cannot provision, due to technical reasons, missing information, or jeopardy conditions resulting from CLEC ordering service at less than the standard order interval. 53.11.2 When an order is rejected, CenturyLink will, in its reject notification, describe the existing reasons for which the order was rejected.
Unforeseen and Emergency Scheduled RDO work where Notice not Provided (a) If notice is not provided by the Employer in accordance with clause 38.8(c) and 38.8(d) then the affected Employees, in addition to accrued entitlements, will be paid as if they were undertaking Public Holiday Work in accordance with clause 39.9 of this Agreement.