By Delta Clause Samples

The "By Delta" clause typically defines actions, obligations, or rights that are specifically assigned to the party named Delta in an agreement. In practice, this clause outlines what Delta is responsible for, such as providing certain services, delivering goods, or fulfilling particular contractual duties. By clearly delineating Delta's roles and responsibilities, the clause helps prevent misunderstandings and ensures that each party knows what is expected from Delta, thereby promoting accountability and reducing the risk of disputes.
By Delta. Payment by Delta for Purchased ABS Equipment shall be made net forty-five (45) days from the date of issuance of Aircell’s invoice therefor, which shall not precede shipment of the Purchased ABS Equipment. Payment by Delta for Connectivity Services Certificates and any Services shall be made net forty-five (45) days from the date of issuance of Aircell’s invoice therefor, which date shall be noted thereon. In the event that Delta in good faith disputes any invoiced amount(s), then within forty-five (45) days following issuance of the invoice, Delta will notify Aircell in writing of the disputed amount(s) and submit payment for all undisputed amounts in accordance with this Section 9.7.1, and Delta’s nonpayment of such disputed amounts pending resolution will not constitute a breach by Delta of this Agreement. The unpaid disputed amount(s) will be resolved by mutual negotiations of the parties. Invoices to Delta hereunder shall be sent by Aircell using Delta’s electronic invoicing system. [***].
View SourceView Similar (3)
By Delta. Aircell shall keep full and accurate records in connection with providing the ABS Equipment, Software and Services and shall make each such record available for audit by Delta for a period of [***] years from the date on which the record is created; provided, however, such auditor shall not be entitled to access to any information that Aircell may not disclose pursuant to confidentiality obligations to any third party. The audit, for purposes of certifying Aircell’s compliance with the terms of this Agreement, may be conducted no more than once per year upon reasonable advance written notice and in a manner that minimizes disruption of Aircell’s business, at Delta’s expense by a leading public accounting firm appointed by Delta, and approved by Aircell. Any such auditor shall agree, in a writing satisfactory to Aircell, to maintain the confidentiality of all information disclosed pursuant to such audit.
View SourceView Similar (3)
By Delta. Gogo shall keep full and accurate records in connection with providing the Equipment, Software and Services and any revenue sharing obligations, and shall make each such record available for audit by an auditor selected by Delta in accordance with this Section 9.11.1 for a period of [***] years from the date on which the record is created; provided, however, such auditor shall not be entitled to access any information that Gogo may not disclose pursuant to confidentiality obligations to any third party. Any such audit may be conducted no more than once per year (other than audits of Gogo’s compliance with Section 9.10) upon reasonable advance written notice and in a manner that minimizes disruption of Gogo’s business, at Delta’s expense by a leading public accounting firm appointed by Delta and approved by Gogo, such approval not to be unreasonably delayed or withheld. Any such auditor shall agree, in a writing reasonably satisfactory to Gogo, to maintain the confidentiality of all information disclosed pursuant to such audit. Notwithstanding anything to the contrary contained herein, with respect to Gogo’s compliance with Section 9.10, Delta may cause an audit to be conducted if, once Gogo provides certification affirming Gogo’s compliance with Section 9.10, Delta has reason to doubt the accuracy of such certification (in which case the expenses will be borne by Delta if the audit confirms Gogo’s compliance and by Gogo if Gogo is found not to be in compliance). With respect to any audit of Section 9.10, the auditor shall, subject to appropriate confidentiality agreements, have access to information regarding Gogo’s arrangements with other airlines but the report delivered by such auditor to Delta shall be drafted in a way that preserves the anonymity of other Gogo airline partners.
View SourceView Similar (3)
By Delta. Payment by Delta for Equipment shall be made net forty-five (45) days from the date of issuance of Gogo’s invoice therefor, which issuance shall not precede shipment of the Equipment. Payment by Delta for the Monthly Service Fee, Connectivity Services Certificates, Portal Usage Fee, Usage Fee, Per Diem Rate (if applicable) and any Services shall be made net forty-five (45) days from the date of issuance of Gogo’s invoice therefor. Gogo’s share of Portal Revenue and Sponsorship Revenue collected by Delta will be calculated on a calendar quarter basis and paid to Gogo within forty-five (45) days of the end of the calendar quarter in which Delta collected such revenue. In the event that Delta in good faith disputes any invoiced amount(s), then within forty-five (45) days following issuance of the invoice, Delta will notify Gogo in writing of the disputed amount(s) and submit payment for all undisputed amounts in accordance with this Section 9.8.1, and Delta’s nonpayment of such disputed amounts pending resolution will not constitute a breach by Delta of this Agreement. The unpaid disputed amount(s) will be resolved by mutual negotiations of the parties. Invoices to Delta hereunder shall be sent by Gogo using Delta’s electronic invoicing system. [***].
View SourceView Similar (3)
By Delta. The parties hereto agree that irreparable damage would occur in the event any of the restrictions set forth in Section 6.07(a) were violated by DELTA, its Subsidiaries or any Representative of DELTA or its Subsidiaries. It is accordingly agreed that F&M shall be entitled to an injunction or injunctions to prevent breaches of Section 6.07 and to enforce specifically the terms and provisions thereof in any court of the United States or any state having jurisdiction, this being in addition to any other remedy to which F&M is entitled at law or in equity. In the event attorneys’ fees or other costs are incurred to secure performance of any of the obligations provided for in this Section 6.07, or to establish damages for the breach thereof, or to obtain any other appropriate relief, whether by way of prosecution or defense, F&M shall be entitled to recover reasonable attorneys’ fees and costs incurred therein.
View Source

Related to By Delta

  • General Conditions Applicable to Option to Build If the Interconnection Customer assumes responsibility for the design, procurement and construction of the Participating TO's Interconnection Facilities and Stand Alone Network Upgrades, (1) the Interconnection Customer shall engineer, procure equipment, and construct the Participating TO's Interconnection Facilities and Stand Alone Network Upgrades (or portions thereof) using Good Utility Practice and using standards and specifications provided in advance by the Participating TO; (2) The Interconnection Customer’s engineering, procurement and construction of the Participating TO's Interconnection Facilities and Stand Alone Network Upgrades shall comply with all requirements of law to which the Participating TO would be subject in the engineering, procurement or construction of the Participating TO's Interconnection Facilities and Stand Alone Network Upgrades; (3) the Participating TO shall review, and the Interconnection Customer shall obtain the Participating TO’s approval of, the engineering design, equipment acceptance tests, and the construction of the Participating TO's Interconnection Facilities and Stand Alone Network Upgrades, which approval shall not be unreasonably withheld, and the CAISO may, at its option, review the engineering design, equipment acceptance tests, and the construction of the Participating TO's Interconnection Facilities and Stand Alone Network Upgrades; (4) prior to commencement of construction, the Interconnection Customer shall provide to the Participating TO, with a copy to the CAISO for informational purposes, a schedule for construction of the Participating TO's Interconnection Facilities and Stand Alone Network Upgrades, and shall promptly respond to requests for information from the Participating TO; (5) at any time during construction, the Participating TO shall have the right to gain unrestricted access to the Participating TO's Interconnection Facilities and Stand Alone Network Upgrades and to conduct inspections of the same; (6) at any time during construction, should any phase of the engineering, equipment procurement, or construction of the Participating TO's Interconnection Facilities and Stand Alone Network Upgrades not meet the standards and specifications provided by the Participating TO, the Interconnection Customer shall be obligated to remedy deficiencies in that portion of the Participating TO's Interconnection Facilities and Stand Alone Network Upgrades; (7) the Interconnection Customer shall indemnify the CAISO and Participating TO for claims arising from the Interconnection Customer's construction of the Participating TO's Interconnection Facilities and Stand Alone Network Upgrades under the terms and procedures applicable to Article 18.1

  • Time of the Essence in This Tenant Work Letter Unless otherwise indicated, all references herein to a “number of days” shall mean and refer to calendar days. If any item requiring approval is timely disapproved by Landlord, the procedure for preparation of the document and approval thereof shall be repeated until the document is approved by Landlord.

  • Company Deliverables The Company shall have delivered the Company Deliverables in accordance with Section 2.2(a).

  • Suspension of unsafe Construction Works (i) Upon recommendation of the Authority’s Engineer to this effect, the Authority may by notice require the Contractor to suspend forthwith the whole or any part of the Works if, in the reasonable opinion of the Authority’s Engineer, such work threatens the safety of the Users and pedestrians. (ii) The Contractor shall, pursuant to the notice under Clause 11.17 (i), suspend the Works or any part thereof for such time and in such manner as may be specified by the Authority and thereupon carry out remedial measures to secure the safety of suspended works, the Users and pedestrians. The Contractor may by notice require the Authority’s Engineer to inspect such remedial measures forthwith and make a report to the Authority recommending whether or not the suspension hereunder may be revoked. Upon receiving the recommendations of the Authority’s Engineer, the Authority shall either revoke such suspension or instruct the Contractor to carry out such other and further remedial measures as may be necessary in the reasonable opinion of the Authority, and the procedure set forth in this Clause 11.17 shall be repeated until the suspension hereunder is revoked. (iii) Subject to the provisions of Clause 21.6, all reasonable costs incurred for maintaining and protecting the Works or part thereof during the period of suspension (the “Preservation Costs”), shall be borne by the Contractor; provided that if the suspension has occurred as a result of any breach of this Agreement by the Authority, the Preservation Costs shall be borne by the Authority. (iv) If suspension of Works is for reasons not attributable to the Contractor, the Authority’s Engineer shall determine any Time Extension to which the Contractor is reasonably entitled.

  • Notice of Completion; Copy of Record Set of Plans Within fifteen (15) days after completion of construction of the Improvements, Tenant shall cause a Notice of Completion to be recorded in the office of the Recorder of the county in which the Building is located in accordance with Section 8182 of the Civil Code of the State of California or any successor statute, and shall furnish a copy thereof to Landlord upon such recordation. If Tenant fails to do so, Landlord may execute and file the same as Tenant’s agent for such purpose, at Tenant’s sole cost and expense. At the conclusion of construction, (i) Tenant shall cause the Architect and Contractor (A) to update the Approved Working Drawings as necessary to reflect all changes made to the Approved Working Drawings during the course of construction, (B) to certify to the best of their knowledge that the “record-set” of as-built drawings are true and correct, which certification shall survive the expiration or termination of this Lease, and (C) to deliver to Landlord two (2) sets of copies of such record set of drawings within ninety (90) days following issuance of a certificate of occupancy for the Premises, and (ii) Tenant shall deliver to Landlord a copy of all warranties, guaranties, and operating manuals and information relating to the improvements, equipment, and systems in the Premises.