Change of Contract Time Sample Clauses

Change of Contract Time. 16.1 The "Contract Time" may only be changed by a Change Order. Any claim for an extension of the "Contract Time" shall be based on written notice delivered by the party making the claim to the CITY ENGINEER and the City’s Project Manager within 7 calendar days of the beginning of the occurrence of the event giving rise to the claim and stating the general nature of the claim. Notice of the extent of the claim with supporting data shall be delivered within 15 days after the end of such occurrence (unless the CITY allows an additional period of time to ascertain more accurate data in support of the claim) and shall be accompanied by the claimant's written statement that the adjustment claimed is the entire adjustment to which the claimant has reason to believe it is entitled as a result of the occurrence of said event. All claims for adjustment in the "Contract Time" shall be determined by the CITY ENGINEER in accordance with paragraph 16.2, if CITY and CONTRACTOR cannot otherwise agree. No claim for an adjustment in the "Contract Time" will be valid if not submitted in accordance with the requirements of this paragraph. 16.2 The CITY ENGINEER and/or City’s Project Manager must submit the request of an extension of the “Contract Time” with the written information provided by the CONTRACTOR and with a written explanation as to why the extension shall be allowed to the City Manager for approval. If the City Manager approves the request, the "Contract Time" will be extended in an amount equal to time lost due to delays beyond the control of and through no fault or negligence of the CONTRACTOR. Such delays shall include, but not limited to, acts or neglect by CITY or the CITY ENGINEER, or by any employee of either, or any separate contractor employed by the CITY, fires, floods, labor disputes, epidemics, abnormal weather conditions or acts of God.

Change of Contract Time. A. The Contract Time may only be changed by a Change Order. B. No extension of the Contract Time will be allowed for Extra Work or for claimed delay unless the Extra Work contemplated or claimed delay is shown to be on the critical path of the Project Schedule or Contractor can show by Critical Path Method analysis how the Extra Work or claimed delay adversely affects the critical path.

Change of Contract Time. All time limits stated in this Contract are of the essence. Contract Time will be changed only by a Change Order. Any extension in Contract Time will be based on written notice delivered to the City within 15 days of the occurrence of the event precipitating the request. The Design-Builder shall deliver a work progress schedule analysis or summary justifying the time extension within 30 days of such occurrence. Failure to deliver any documentation to the City within the time limits specified above will completely foreclose consideration of an extension of Contract Time and all rights and remedies arising therefrom.

Change of Contract Time. 11.1 The Contract Time may only be changed by a Change Order. Any claim for an extension in the Contract Time shall be based on written notice delivered to OWNER and PROJECT MANAGER within fifteen days of the occurrence of the event-giving rise to the claim. Notice of the extent of the claim with supporting data shall be delivered within forty-five (45) days of such occurrence unless PROJECT MANAGER allows an additional period to ascertain additional accurate data. PROJECT MANAGER shall determine all claims for adjustment in the Contract Time if OWNER and CONTRACTOR cannot otherwise agree. Any change in the Contract Time resulting from any such claim shall be incorporated in a Change Order. 11.2 The Contract Time will be extended in an amount equal to time lost due to delays beyond the control of CONTRACTOR if a claim is made therefore as provided in Article 11.1. Such delays shall include, but not be limited to, acts or neglect by OWNER or others performing additional Work as contemplated by Article 6, or to fires, floods, labor disputes, epidemics, abnormal weather conditions, or acts of God. The CONTRACTOR shall be granted time extensions to the Contract for a period longer than the number of days indicated by month in the table below if rainfall on a given day (measured at a rain gauge site as determined by the Project Manager) is in excess of 1.0 inch and/or site conditions will not permit work on day(s) following a rain in excess of 1.0 inch. Inclement weather and flooding shall not be counted for delays unless Work is scheduled in advance as verified by the PROJECT MANAGER and a legitimate effort is made by the CONTRACTOR to perform that Work. January 2 July 3 February 2 August 4 March 2 September 4 April 4 October 4 May 5 November 4 June 4 December 2 The CONTRACTOR shall furnish all data and analysis to the PROJECT MANAGER to substantiate a claim for Contract time extension on a month-to-month basis with the CONTRACTORS monthly progress payment request. The CONTRACTOR shall not be entitled to any additional monetary consideration for granted time extensions or reimbursement for damages or hindrances because of heavy rainfall or flooding. 11.3 All time limits stated in the Contract Documents are of the essence of the Agreement.

Change of Contract Time. The Contract Time may only be changed by written Change Order. Any claim for an extension in the Contract Time shall be in writing and include an analysis of the Progress Schedule as further described in the Specifications and shall be delivered to the City Manager or designee within fifteen (15) business days of the occurrence of the event giving rise to the claim. All claims for adjustment in the Contract Time shall be determined by the City Manager or designee. Any change in the Contract Time resulting from any such claim shall be incorporated in a Change Order. The Contract Time may be extended for an amount equal to time lost due to unforeseeable causes beyond the control of the Contractor (and his Subcontractors and Suppliers) if he makes a claim therefrom. Such delays shall include, but not be restricted to, acts or neglect by any separate Contractor employed by the City; fires; floods; labor disputes; epidemics; or acts of God. All time limits stated in the Contract Documents are of the essence to the Contract. The stated time limits are agreed to be adequate to complete the work, including the procurement, manufacture and delivery of all material and equipment required, and account for any and all potential impact, delays, disruptions and costs that may be expected.

Change of Contract Time. 13.1 The Contract Time may only be changed by a Change Order. Any request for an extension in the Contract Time shall be made in writing and delivered to the Professional within seven (7) calendar days of the occurrence first happening and resulting in the claim. Written supporting data will be submitted to the Project Manager within fifteen (15) calendar days after such occurrence unless the Professional allows additional time. All claims submitted by the Contractor for adjustments to the Contract Time must set forth in detail the reasons for and causes of the delay and clearly indicate why the subject delay was beyond the Contractor’s control or fault. Failure to comply constitutes a waiver of Contractor’s right to make a claim. 13.1.1 If the Contractor is delayed at any time in the performance, progress, commencement, or by any separate contractor employed by the City, or by changes ordered in the Work, or by labor disputes, fire, unavoidable casualties, utility conflicts which could not have been identified or foreseen by the completion of the Work by any act or neglect of the City or the Professional, or by an employee of either, the Contractor using reasonable diligence, or any causes beyond the Contractor’s control or fault, then the Contract Time shall be extended by Change Order for such reasonable time as the City may determine. The Contractor shall be entitled to an extension of time for such causes only for the number of days of delay which the City may determine to be due solely to such causes and only to the extent such occurrences actually delay the completion of the Work and then only if the Contractor shall have strictly complied with all the requirements of the Contract Documents. Provided, however, notwithstanding anything in the Contract Documents to the contrary, no interruption, interference, inefficiency, suspension or delay in the performance, progress, commencement or completion of the Work for any cause whatsoever, including those for which the City or the Professional may be responsible in whole or in part, shall relieve Contractor of its duty to perform or give rise to any right to damages or additional compensation from the City. The Contractor’s sole and exclusive remedy against the City for interruption, interference, inefficiency, suspension or delay of any aspect of the Work shall be the right to seek an extension to the Contract Time in accordance with the procedures set forth herein. The Contractor shall not be entitled t...

Change of Contract Time. 12.1 The Contract Time may only be changed by a Change Order or a Written Amendment. Any claim for an extension or shortening of the Contract Time shall be based on written notice delivered by the party making the claim to the other party and to Engineer promptly (but in no event later than thirty (30) days after the occurrence of the event giving rise to the claim and stating the general nature of the claim. Notice of the extent of the claim with supporting data shall be delivered within sixty days after such occurrence (unless Engineer allows an additional period of time to ascertain more accurate data in support of the claim) and shall be accompanied by the claimant’s written statement that the adjustment claimed is the entire adjustment to which the claimant has reason to believe it is entitled as a result of the occurrence of said event. All claims for adjustment in the Contract Time shall be determined by Engineer in accordance with paragraph 9.11 if Town and Contractor cannot otherwise agree. No claim for an adjustment in the Contract Time will be valid if not submitted in accordance with the requirements of this paragraph 12.1.

Change of Contract Time. The Contract Time may only be changed by a Written Amendment. Any claim for an adjustment in the Contract Time shall be made by written notice submitted by the party making the claim to the other party to the Contract and must be approved by both parties.

Change of Contract Time. ALL TIME LIMITS STATED IN THE CONTRACT DOCUMENTS ARE OF THE ESSENCE OF THE AGREEMENT. NO CLAIM FOR DAMAGES OR ANY CLAIM OTHER THAN FOR AN EXTENSION OF TIME SHALL BE MADE OR ASSERTED AGAINST THE CITY BY REASON OF ANY DELAYS. CONTRACTOR shall not be entitled to an increase in the Contract Price or payment or compensation of any kind from CITY for direct, indirect, consequential, impact or other costs, expenses or damages including but not limited to costs of acceleration or inefficiency, arising because of delay, disruption, interference or hindrance from any cause whatsoever, whether such delay, disruption, interference be reasonable or unreasonable, foreseeable or unforeseeable, or avoidable or unavoidable; provided, however, that this provision shall not preclude recovery of damages by CONTRACTOR for hindrances or delays due solely to fraud, bad faith or active interference on the part of CITY or its agents. Otherwise, CONTRACTOR shall be entitled only to extensions of the Contract Time as the sole and exclusive remedy for such resulting delay, in accordance with and to that extent specifically