Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
Provisions Applicable to FMR Fiioc and FSC 1. For the services and facilities to be furnished hereunder, the Adviser shall receive a monthly management fee, payable monthly by each class of the Fund as soon as practicable after the last day of each month, composed of a Basic Fee and a Performance Adjustment. Except as otherwise provided in sub-paragraph (e) of this paragraph 1, the Performance Adjustment is added to or subtracted from the Basic Fee depending on whether the Fund experienced better or worse performance than an appropriate index (the “Index”). The Performance Adjustment is not cumulative. An increased fee will result even though the performance of the Fund over some period of time shorter than the performance period has been behind that of the Index, and, conversely, a reduction in the fee will be made for a month even though the performance of the Fund over some period of time shorter than the performance period has been ahead of that of the Index. The Basic Fee for a class and the Performance Adjustment will be computed as follows:
Changes to Specifications All Specifications and any changes thereto agreed to by the parties from time to time shall be in writing, dated and signed by the parties. Any change to the Process shall be deemed a Specification change. No change in the Specifications shall be implemented by Catalent, whether requested by Client or requested or required by any Regulatory Authority, until the parties have agreed in writing to such change, the implementation date of such change, and any increase or decrease in costs, expenses or fees associated with such change (including any change to Unit Pricing). Catalent shall respond promptly to any request made by Client for a change in the Specifications, and both parties shall use commercially reasonable, good faith efforts to agree to the terms of such change in a timely manner. As soon as possible after a request is made for any change in Specifications, Catalent shall notify Client of the costs associated with such change and shall provide such supporting documentation as Client may reasonably require. Client shall pay all costs associated with such agreed upon changes. If there is a conflict between the terms of this Agreement and the terms of the Specifications, this Agreement shall control. Catalent reserves the right to postpone effecting changes to the Specifications until such time as the parties agree to and execute the required written amendment.
Minimum Shipping Requirements for TIPS Sales Vendor shall ship, deliver, or provide ordered goods and services within a commercially reasonable time after acceptance of the order. If a delay in delivery is anticipated, Vendor shall notify the TIPS Member as to why delivery is delayed and provide an updated estimated time for completion. The TIPS Member may cancel the order if the delay is not commercially acceptable or not consistent with the Supplemental Agreement applicable to the order.