CLAIMS BASED ON DOM’S ACTIONS OR OMISSIONS Clause Samples

The "Claims Based on DOM’s Actions or Omissions" clause defines the circumstances under which claims may be brought against a party (referred to as DOM) due to their actions or failures to act. This clause typically outlines the types of conduct by DOM that could give rise to liability, such as negligence, breach of contract, or failure to fulfill specific obligations. For example, if DOM fails to deliver services as agreed or acts in a way that causes harm, the clause would specify how and when claims can be made. Its core function is to clarify the scope of responsibility and potential liability for DOM, thereby allocating risk and providing a clear process for addressing grievances related to DOM’s conduct.
CLAIMS BASED ON DOM’S ACTIONS OR OMISSIONS. A. NOTICE OF CLAIM. If any action or omission on the part of DOM requiring performance changes within the scope of the Agreement constitutes the basis for a claim by Contractor for additional compensation, damages, or an extension of time for completion, Contractor shall continue with performance of the contract in compliance with the directions or orders of such officials, but by so doing, Contractor shall not be deemed to have prejudiced any claim for additional compensation, damages, or an extension of time for completion; provided: 1. Contractor shall have given written notice to DOM: a. Prior to the commencement of the work involved, if at that time Contractor knows of the occurrence of such action or omission; b. Within thirty (30) days after Contractor knows of the occurrence of such action or omission, if Contractor did not have such knowledge prior to the commencement of the work; or, c. Within such further time as may be allowed by DOM in writing. This notice shall state that Contractor regards the act or omission as a reason which may entitle Contractor to additional compensation, damages, or an extension of time. DOM, upon receipt of such notice, may rescind such action, remedy such omission, or take such other steps as may be deemed advisable in the discretion of DOM; 2. The notice required by subparagraph (a) of this paragraph describes, as clearly as practicable at the time, the reasons why Contractor believes that additional compensation, damages, or an extension of time may be remedies to which Contractor is entitled; and, 3. Contractor maintains and, upon request, makes available to DOM within a reasonable time, detailed records to the extent practicable, of the claimed additional costs or basis for an extension of time in connection with such changes.
View SourceView Similar (4)
CLAIMS BASED ON DOM’S ACTIONS OR OMISSIONS. 1. Notice of Claim. If any action or omission on the part of the Office of Community Based Services requiring performance changes within the scope of the Agreement constitutes the basis for a claim by Contractor for additional compensation, damages, or an extension of time for completion, Contractor shall continue with performance of the contract in compliance with the directions or orders of such officials, but by so doing, Contractor shall not be deemed to have prejudiced any claim for additional compensation, damages, or an extension of time for completion; provided: a. Contractor shall have given written notice to the Office of Community Based Services: i. prior to the commencement of the work involved, if at that time Contractor knows of the occurrence of such action or omission; ii. within thirty (30) days after Contractor knows of the occurrence of such action or omission, if Contractor did not have such knowledge prior to the commencement of the work; or, iii. within such further time as may be allowed by the Office of Community Based Services in writing. This notice shall state that Contractor regards the act or omission as a reason which may entitle Contractor to additional compensation, damages, or an extension of time. The Office of Community Based Services, upon receipt of such notice, may rescind such action, remedy such omission, or take such other steps as may be deemed advisable in the discretion of the Office of Community Based Services; b. the notice required by subparagraph (a) of this paragraph describes, as clearly as practicable at the time, the reasons why Contractor believes that additional compensation, damages, or an extension of time may be remedies to which Contractor is entitled; and, c. Contractor maintains and, upon request, makes available to the Office of Community Based Services within a reasonable time, detailed records to the extent practicable, of the claimed additional costs or basis for an extension of time in connection with such changes.
View Source

Related to CLAIMS BASED ON DOM’S ACTIONS OR OMISSIONS

  • Delays or Omissions No delay or omission to exercise any right, power or remedy accruing to any party under this Agreement, upon any breach or default of any other party under this Agreement, shall impair any such right, power or remedy of such non-breaching or non-defaulting party nor shall it be construed to be a waiver of any such breach or default, or an acquiescence therein, or of or in any similar breach or default thereafter occurring; nor shall any waiver of any single breach or default be deemed a waiver of any other breach or default theretofore or thereafter occurring. Any waiver, permit, consent or approval of any kind or character on the part of any party of any breach or default under this Agreement, or any waiver on the part of any party of any provisions or conditions of this Agreement, must be in writing and shall be effective only to the extent specifically set forth in such writing. All remedies, either under this Agreement or by law or otherwise afforded to any party, shall be cumulative and not alternative.

  • Delays or Omissions; Waivers No failure on the part of either Party to exercise any power, right, privilege or remedy under this Agreement, and no delay on the part of either Party in exercising any power, right, privilege or remedy under this Agreement, shall operate as a waiver of such power, right, privilege or remedy; and no single or partial exercise or waiver of any such power, right, privilege or remedy shall preclude any other or further exercise thereof or of any other power, right, privilege or remedy. No Party shall be deemed to have waived any claim arising out of this Agreement, or any power, right, privilege or remedy under this Agreement, unless the waiver of such claim, power, right, privilege or remedy is expressly set forth in a written instrument duly executed and delivered on behalf of such Party; and any such waiver shall not be applicable or have any effect except in the specific instance in which it is given.

  • Breach of Contract Claims To the extent that Chapter 2260, Texas Government Code, is applicable to this Agreement and is not preempted by other applicable law, the dispute resolution process provided for in Chapter 2260 and the related rules adopted by the Texas Attorney General pursuant to Chapter 2260, will be used by University and Contractor to attempt to resolve any claim for breach of contract made by Contractor that cannot be resolved in the ordinary course of business. The chief business officer of University will examine Contractor's claim and any counterclaim and negotiate with Contractor in an effort to resolve the claims. The parties specifically agree (i) neither execution of this Agreement by University nor any other conduct, action or inaction of any representative of University relating to this Agreement constitutes or is intended to constitute a waiver of University’s or the state's sovereign immunity to suit; and (ii) University has not waived its right to seek redress in the courts.

  • Liability for Acts or Omissions of Third Parties Neither BellSouth nor Mpower shall be liable for any act or omission of another telecommunications company providing a portion of the services provided under this Agreement.

  • Indemnification Against Third-Party Claims Each Party (the Indemnifying Party) agrees to indemnify, defend, and hold harmless the other Party (the Indemnified Party) and the other Party’s Subsidiaries, predecessors, successors, Affiliates, and assigns, and all current and former officers, directors, members, shareholders, agents, contractors and employees of all such persons and entities (collectively, with Indemnified Party, the “Indemnitee Group”), from any and all Claims (as hereinafter defined). 22.1.1 For purposes of this Section 22, Claim means any action, cause of action, suit, proceeding, claim, or demand of any third party (and all resulting judgments, bona fide settlements, penalties, damages, losses, liabilities, costs, and expenses including, but not limited to, reasonable costs and attorneys’ fees), (a) based on allegations that, if true, would establish (i) the Indemnifying Party’s breach of this Agreement; (ii) the Indemnifying Party’s misrepresentation, fraud or other misconduct; (iii) the Indemnifying Party’s negligent or willful misconduct or omissions; (iv) infringement by the Indemnifying Party or by any Indemnifying Party product or service of any patent, copyright, trademark, service mark, trade name, right of publicity or privacy, trade secret, or any other proprietary right of any third party; (v) the Indemnifying Party’s liability in relation to any wrongful disclosure of private or personal matters or material which is defamatory; or (vi) the Indemnifying Party’s wrongful use or unauthorized disclosure of data; or (b) that arises out of: (i) any act or omission of the Indemnifying Party or its subcontractors or agents relating to the Indemnifying Party’s performance or obligations under this Agreement or the Indemnifying Party’s use of any services or facilities obtained from or provided by the other Party under this Agreement; (ii) any act or omission of the Indemnifying Party’s customer(s) or End User(s) pertaining to the services or facilities provided under this Agreement; (iii) the bodily injury or death of any person, or the loss or disappearance of or damage to the tangible property of any person, relating to the Indemnifying Party’s performance or obligations under this Agreement; (iv) the Indemnifying Party’s design, testing, manufacturing, marketing, promotion, advertisement, distribution, lease or sale of services and/or products to its customers, or such customers’ use, possession, or operation of those services and/or products; or (v) personal injury to or any unemployment compensation claim by one or more of the Indemnifying Party’s employees, notwithstanding any protections the Indemnifying Party might otherwise have under applicable workers’ compensation or unemployment insurance law, which protections the Indemnifying Party waives, as to the Indemnified Party and other persons and entities to be indemnified under this Section (other than applicable employee claimant(s)). 22.1.2 For purposes of this Section, Reasonable costs and attorneys’ fees, as used in this Section, includes without limitation fees and costs incurred to interpret or enforce this Section. 22.1.3 The Indemnified Party will provide the Indemnifying Party with reasonably prompt written notice of any Claim. At the Indemnifying Party’s expense, the Indemnified Party will provide reasonable cooperation to the Indemnifying Party in connection with the defense or settlement of any Claim. The Indemnified Party may, at its expense, employ separate counsel to monitor and participate in the defense of any Claim.