Commissioning Date Sample Clauses

POPULAR SAMPLE Copied 3 times
Commissioning Date. [insert] 1. Location and Description of Connection Points Location Description
View Source
Commissioning Date. If the Recipient believes that the Commissioning Date will not be met by the Commissioning Sunset Date, the Recipient must provide a notice to ARENA promptly after forming such a belief which sets out the reasons for the Recipient’s belief and the Recipient’s proposed actions to prevent or minimise any delay to the Commissioning Date being met. On receipt of a Notice from the Recipient under clause 3.3above, ARENA may extend either or both of the Commissioning Sunset Date and the End Date (and ARENA will agree to extend the Commissioning Sunset Date if the Financiers have consented to an equivalent extension under the Finance Documents).
View Source
Commissioning Date. The First Commissioning Date shall be the date notified to the Buyer as the target date for the start of commissioning of the first unit.
View SourceView Similar (3)
Commissioning Date. Owner shall diligently cause the Commissioning Date to occur as shown in Schedule B (Project Schedule), but in any event, no later than one year from the Effective Date, and use its best efforts to acquire, preserve and protect all of the rights, interest and properties necessary for the Project. Owner shall install the Equipment, or cause the Equipment to be installed, in a manner consistent with any installation manual prepared by the manufacturer or supplier of the Equipment. Owner shall notify CI immediately of the occurrence of any event or contemplated action (including the threat and/or commencement of any legal proceedings) which could have a material adverse effect on the Project (including a material deviation from the specifications set forth in Schedule A), Contract No. PHOTOVOLTAIC Project together with a recommended course of action.
View Source

Related to Commissioning Date

  • Commissioning Commissioning tests of the Interconnection Customer’s installed equipment shall be performed pursuant to applicable codes and standards. The ISO and Connecting Transmission Owner must be given at least five Business Days written notice, or as otherwise mutually agreed to by the Parties, of the tests and may be present to witness the commissioning tests.

  • Synchronization, Commissioning and Commercial Operation 5.1.1 The SPG shall give PGVCL at least thirty (30) days’ advanced preliminary written notice and at least fifteen (15) days’ advanced final written notice, of the date on which it intends to synchronize the Solar Power Project to the Grid System. 5.1.2 Subject to Article 5.1.1, the Power Project may be synchronized by the SPG to the Grid System when it meets all the connection conditions prescribed in applicable Grid Code then in effect and otherwise meets all other Indian legal requirements for synchronization to the Grid System. 5.1.3 The synchronization equipment and all necessary arrangements / equipment including RTU for scheduling of power generated from the Project and transmission of data to the concerned authority as per applicable regulation shall be installed by the SPG at its generation facility of the Power Project at its own cost. The SPG shall synchronize its system with the Grid System only after the approval of synchronization scheme is granted by the head of the concerned substation/ and checking/verification is made by the concerned authorities of the PGVCL. 5.1.4 The SPG shall immediately after each synchronization/tripping of generator, inform the sub-station of the Grid System to which the Power Project is electrically connected in accordance with applicable Grid Code. In addition, the SPG will inject in-firm power to grid from time to time to carry out operational/ functional test prior to commercial operation. For avoidance of doubt, it is clarified that Synchronization / Connectivity of the Project with the grid shall not to be considered as Commissioning of the Project. 5.1.5 The SPG shall commission the Project within nine (9) Months from the Date of execution of this PPA. Declaration of COD shall be certified by the commissioning committee. 5.1.6 The Parties agree that for the purpose of commencement of the supply of electricity by SPG to PGVCL, liquidated damages for delay etc., the Scheduled Commissioning Date as defined in this Agreement shall be the relevant date.

  • Project Completion Date It is agreed between the Parties that the Project Completion Date is <END DATE, YEAR>. If the Project is not completed by such date then, subject to an amendment agreed to between the Parties, Alberta Innovates may elect to terminate this Investment Agreement. In such event, Alberta Innovates will notify the Applicant of its decision to terminate as soon as reasonably practical and shall advise the Applicant of the effective date of termination. Alberta Innovates will have no liability or obligation to reimburse the Applicant for any Project Costs incurred after the effective date of termination and may require the Applicant to return any portions of the Investment which were spent on Ineligible Expenses. Additionally, any portion of the Investment not used and accounted for in accordance with this Agreement as of the Project Completion Date or earlier termination is repayable by the Applicant to AI at AI’s request.

  • Project Completion The Contractor agrees to schedule a final job walk with the County. If required, the County will prepare a list of incomplete items, the “Punch List”. The Contractor agrees to complete the “Punch List” corrections and schedule a final project completion job walk. The County will sign the “Punch List” as completed when determined, the project is finished. The Contractor agrees to submit the following along with its final payment request:

  • Contract Closure Contracting Officer shall give appropriate written notice to Purchaser when Purchaser has complied with the terms of this contract. Purchaser shall be paid refunds due from Timber Sale Account un- der B4.24 and excess cooperative deposits under B4.218.