Complete the Work Clause Samples

The 'Complete the Work' clause requires a party, typically the contractor or service provider, to finish all tasks or deliverables specified in the agreement. In practice, this means the responsible party must perform the work according to the agreed-upon standards, timelines, and specifications, ensuring that nothing is left incomplete or substandard. This clause ensures that the project or service is fully delivered as promised, protecting the interests of the party receiving the work and providing a clear standard for fulfillment.
Complete the Work. Will initiate and complete the work within the applicable time frame after receipt of approval from Worksystems.
View SourceView Similar (5)
Complete the Work. Contractor - The individual or entity with which Owner has contracted for performance of the Work.
View SourceView Similar (4)
Complete the Work. Will initiate and complete the work within the applicable time frame after receipt of approval from WWP.
View SourceView Similar (3)
Complete the Work. Fit products together to integrate with other work.
View Source

Related to Complete the Work

  • Completion of the Work The Contractor must obtain Material Completion as defined in Section 6.1.2 below prior to any occupancy of the Project.

  • Complete Taking If at any time during the Fee Term title to or temporary use of the entire Project should become vested in a public or quasi-public authority by virtue of the exercise of a taking by condemnation, inverse condemnation or the right of eminent domain, or by voluntary transfer under threat of such taking, or in the event that title to a portion of the Project shall be taken rendering continued occupancy of the Project commercially infeasible in the judgment of the Sponsor, the Sponsor shall have the option to terminate this Fee Agreement as of the time of vesting of title by sending written notice to the County within a reasonable period of time following such vesting.

  • Project Completion The Contractor agrees to schedule a final job walk with the County. If required, the County will prepare a list of incomplete items, the “Punch List”. The Contractor agrees to complete the “Punch List” corrections and schedule a final project completion job walk. The County will sign the “Punch List” as completed when determined, the project is finished. The Contractor agrees to submit the following along with its final payment request:

  • Project Work PURCHASER shall complete the following projects in accordance with the specifications provided in Exhibits B, C, D, E, and F and written instructions from STATE. Project locations are shown on Exhibit A unless otherwise described. PURCHASER shall furnish all material unless otherwise specified.

  • Incomplete Works In the event the Contractor fails to complete the Works in accordance with the Project Completion Schedule, including any Time Extension granted under this Agreement, the Contractor shall endeavour to complete the balance work expeditiously and shall pay Damages to the Authority in accordance with the provisions of Clause 10.3 (ii) for delay of each day until the Works are completed in accordance with the provisions of this Agreement. Recovery of Damages under this Clause shall be without prejudice to the rights of the Authority under this Agreement including the right to termination under Clause 23.1.