Common use of Completion of Work Clause in Contracts

Completion of Work. Contractor is accountable for completing the Work within the Contract Time stated in the Contract, or as otherwise amended by Change Order. 9.5.1 If, in the judgment of Owner, the work is behind schedule and the rate of placement of work is inadequate to regain scheduled progress to insure timely completion of the entire work or a separable portion thereof, Contractor, when so informed by Owner, shall immediately take action to increase the rate of work placement by: 9.5.1.1 An increase in working forces. 9.5.1.2 An increase in equipment or tools. 9.5.1.3 An increase in hours of work or number of shifts. 9.5.1.4 Expedite delivery of materials. 9.5.1.5 Other action proposed if acceptable to Owner. 9.5.2 Within ten (10) days after such notice from ODR, Contractor shall notify ODR in writing of the specific measures taken and/or planned to increase the rate of progress. Contactor shall include an estimate as to the date of scheduled progress recovery and an updated Work Progress Schedule illustrating Contractor’s plan for achieving timely completion of the Project. Should ODR deem the plan of action inadequate, Contractor shall take additional steps or make adjustments as necessary to its plan of action until it meets with ▇▇▇’s approval.

Completion of Work. Contractor is accountable for completing the Work within the Contract Time stated in the Contract, or as otherwise amended by Change Order. 9.5.1 If, in the judgment of Owner, the work is behind schedule and the rate of placement of work is inadequate to regain scheduled progress to insure timely completion of the entire work or a separable portion thereof, Contractor, when so informed by Owner, shall immediately take action to increase the rate of work placement by: 9.5.1.1 An increase in working forces. 9.5.1.2 An increase in equipment or tools. 9.5.1.3 An increase in hours of work or number of shifts. 9.5.1.4 Expedite delivery of materials. 9.5.1.5 Other action proposed if acceptable to Owner. 9.5.2 Within ten (10) days after such notice from ODR, Contractor shall notify ODR in writing of the specific measures taken and/or planned to increase the rate of progress. Contactor shall include an estimate as to the date of scheduled progress recovery and an updated Work Progress Schedule illustrating Contractor’s plan for achieving timely completion of the Project. Should ODR deem the plan of action inadequate, Contractor shall take additional steps or make adjustments as necessary to its plan of action until it meets with ▇▇▇ODR’s approval.

Completion of Work. Contractor is accountable for completing the Work within the Contract Time stated in the Contract, or as otherwise amended by Change Order. 9.5.1 8.5.1 If, in the judgment of Owner, the work is behind schedule and the rate of placement of work is inadequate to regain scheduled progress to insure timely completion of the entire work or a separable portion thereof, Contractor, when so informed by Owner, shall immediately take action to increase the rate of work placement by: 9.5.1.1 8.5.1.1 An increase in working forces. 9.5.1.2 8.5.1.2 An increase in equipment or tools. 9.5.1.3 8.5.1.3 An increase in hours of work or number of shifts. 9.5.1.4 8.5.1.4 Expedite delivery of materials. 9.5.1.5 8.5.1.5 Other action proposed if acceptable to Owner. 9.5.2 8.5.2 Within ten (10) days after such notice from ODR, Contractor shall notify ODR in writing of the specific measures taken and/or planned to increase the rate of progress. Contactor shall include an estimate as to the date of scheduled progress recovery and an updated Work Progress Schedule illustrating Contractor’s plan for achieving timely completion of the Project. Should ODR deem the plan of action inadequate, Contractor shall take additional steps or make adjustments as necessary to its plan of action until it meets with ▇▇▇’s approvalODR’sapproval.

Completion of Work. The Contractor is accountable for completing the Work within in the Contract Time time stated in the Contract, or as otherwise amended by Change Order. 9.5.1 If, in the judgment of the Owner, the work is behind schedule and the rate of placement of work is inadequate to regain scheduled progress to insure timely completion of the entire work or a separable portion thereof, the Contractor, when so informed by the Owner, shall immediately take action to increase the rate of work placement by: 9.5.1.1 An increase in working forces. 9.5.1.2 An increase in equipment or tools. 9.5.1.3 An increase in hours of work or number of shifts. 9.5.1.4 Expedite delivery of materials. 9.5.1.5 Other action proposed if acceptable to Owner. 9.5.2 Within ten (10) calendar days after such notice from the ODR, the Contractor shall notify the ODR in writing of the specific measures taken and/or planned to increase the rate of progress. Contactor shall include Include an estimate as to the date of scheduled progress recovery and an updated Work Progress Schedule illustrating the Contractor’s 's plan for achieving timely completion of the Project. Should the ODR deem the plan of action inadequate, Contractor shall take additional steps or make adjustments as necessary to its plan of action until it meets with ▇▇▇the ODR’s approval.

Completion of Work. Contractor is accountable for completing the Work within the Contract Time stated in the Contract, or as otherwise amended by Change Order. 9.5.1 If, in the judgment of Owner/ODR, the work is behind schedule and the rate of placement of work is inadequate to regain scheduled progress to insure timely completion of the entire work or a separable portion thereof, Contractor, when so informed by Owner/ODR, shall immediately take action to increase the rate of work placement by: 9.5.1.1 An increase in working forces. 9.5.1.2 An increase in equipment or tools. 9.5.1.3 An increase in hours of work or number of shifts. 9.5.1.4 Expedite delivery of materials. 9.5.1.5 Other action proposed if acceptable to Owner. 9.5.2 Within ten five (105) days after such notice from ODR, Contractor shall notify ODR in writing of the specific measures taken and/or planned to increase the rate of progress. Contactor shall include an estimate as to the date of scheduled progress recovery and an updated Work Progress Schedule illustrating Contractor’s plan for achieving timely completion of the Project. Should ODR deem the plan of action inadequate, Contractor shall take additional steps or make adjustments as necessary to its plan of action until it meets with ▇▇▇ODR’s approval.