Construction Completion Report Sample Clauses

Construction Completion Report. Within forty-five (45) days of the completion of the capital project, the AGENCY shall summarize its efforts by providing the following information: 1. A brief narrative summary of the successful completion of the capital project. 2. An evaluation of the economic impact the capital project has initially had on the County. 3. A financial statement listing all of the revenues received and expenses paid in the course of the development and completion of the capital project that clearly defines how and where the funds were used. 4. Photographs or video of the capital project and any related events, including time lapses of the construction.
View Source
Construction Completion Report. The Owner/Operator or Respondent shall prepare a Construction Completion Report which documents how the completed project is consistent with the Final Plans and Specifications. A Construction Completion Report shall be submitted to the Department when the construction and any operational tests have been completed. The Construction Completion Report shall, at a minimum, include the following elements: 1. Purpose; 2. Synopsis of the corrective measure, design criteria, and certification that the corrective measure was constructed in accordance with the Final Plans and Specifications; 3. Explanation and description of any modifications to the Final Plans and Specifications and why these were necessary for the project; 4. Results of any operational testing and/or monitoring, indicating how initial operation of the corrective measure compares to the design criteria; 5. Summary of significant activities that occurred during construction. Include a discussion of problems encountered and how they were addressed; 6. Summary of any inspection findings (include copies of key inspection documents in appendices); 7. As built drawings; and 8. A schedule indicating when any treatment systems will begin full scale operations.
View Source
Construction Completion Report. (a) If the Contractor is satisfied that the whole of the Works have been substantially completed, the Contractor shall issue the finalised Construction Completion Report to the Project Manager (copied simultaneously to the Lead Authority and the Independent Certifier) and stating that the Contractor has demonstrated to the Project Manager that the whole of the Works have been substantially completed. (b) If the Project Manager is not satisfied that the Works or part thereof is substantially complete, it may comment in the Construction Completion Report accordingly, stating in what way the Works or part thereof is not in accordance with this Contract. Such comments shall be copied simultaneously to the Lead Authority and the Independent Certifier. The Contractor shall then complete the Works or part thereof as necessary and repeat the procedures contained in this Sub-clause 32.2 until the Project Manager is satisfied that the whole of the Works have been substantially completed.
View Source
Construction Completion Report. CONSULTANT agrees to perform the tasks listed above and described in Exhibit A for a fee amount of not to exceed $92,000.00 (Ninety-Two Thousand Dollars and No Cents), unless otherwise modified by CITY'S Public Works Director in a signed subsequent Task Order. Performance of the services shall be subject to the terms and conditions contained in AGREEMENT. Dated this 22nd Day of May 2024 City of Stanwood , Principal Engineer BY: ▇▇▇▇ ▇▇▇▇▇▇ and ▇▇▇▇▇▇ BY: ▇▇▇▇▇▇ & ▇▇▇▇▇▇, (MFA), and City of Stanwood (Client). Between Maul Inc. Signing of this authorization by MFA and Client authorizes MFA to complete the work as described below (Work) under the terms and conditions of the Master Agreement for Professional Services with an effective date of: February 1, 2021 and the attached Schedule of Charges. The Master Agreement for Professional Services is fully incorporated herein by this reference. MFA project number: Project name: ▇▇▇▇▇▇▇ Property: Construction Oversight Support Project location: ▇▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇ ▇▇▇, ▇▇▇▇▇▇▇▇, ▇▇▇▇▇▇▇▇▇▇ ▇▇▇▇▇ (the Property) Scope of work: MFA will perform the Work indicated below. MFA prepared a design to remediate the Property’s soil and groundwater that contain contaminants of concern (COCs), specifically heavy oils and polycyclic aromatic hydrocarbons (PAHs), that exceed Ecology’s surface water criteria protective of marine aquatic life and/or Ecology’s Sediment Cleanup User’s Manual II Sediment Management Standards. The COCs are related to the operation of former fuel storage tanks on the Property. At Client’s request, MFA has prepared this scope of work to provide permitting support and construction oversight support for the implementation of the previously prepared design. Permit Identification Support Task 1 – MFA will support Client and coordinate with Snohomish County to determine what permits are required for the construction effort, if any, and determine the applicability of land use permits (shoreline permit and State Environmental Policy Act [SEPA] review), development permits (grading) from Snohomish County.
View Source
Construction Completion Report. The Respondent shall prepare a Construction Completion (CC) Report which documents how the completed project is consistent with the Final Plans and Specifications. A CC Report shall be submitted to the Department when the construction and all operational tests have been completed. The CC Report shall, at a minimum, include the following elements:
View Source

Related to Construction Completion Report

  • Project Completion Report At the completion of construction and once a Project is placed in service, the Subrecipient must submit a Project Completion Report that includes the total number of units built and leased, affordable units built and leased, DR-MHP units built and leased, an accomplishment narrative, and the tenants names, demographics and income for each DR-MHP unit.

  • Construction Completion The related Construction shall have been completed substantially in accordance with the related Plans and Specifications, the related Deed and all Applicable Laws, and such Leased Property shall be ready for occupancy and operation. All fixtures, equipment and other property contemplated under the Plans and Specifications to be incorporated into or installed in such Leased Property shall have been substantially incorporated or installed, free and clear of all Liens except for Permitted Liens.

  • Construction Reports Each Constructing Entity shall issue reports to each other Construction Party on a monthly basis, and at such other times as reasonably requested, regarding the status of the construction and installation of the Interconnection Facilities. Each Construction Party shall promptly identify, and shall notify each other Construction Party of, any event that the Construction Party reasonably expects may delay completion, or may significantly increase the cost, of the Interconnection Facilities. Should a Construction Party report such an event, Transmission Provider shall, within fifteen days of such notification, convene a technical meeting of the Construction Parties to evaluate schedule alternatives.

  • Project Completion The Contractor agrees to schedule a final job walk with the County. If required, the County will prepare a list of incomplete items, the “Punch List”. The Contractor agrees to complete the “Punch List” corrections and schedule a final project completion job walk. The County will sign the “Punch List” as completed when determined, the project is finished. The Contractor agrees to submit the following along with its final payment request:

  • Project Completion Date It is agreed between the Parties that the Project Completion Date is <END DATE, YEAR>. If the Project is not completed by such date then, subject to an amendment agreed to between the Parties, Alberta Innovates may elect to terminate this Investment Agreement. In such event, Alberta Innovates will notify the Applicant of its decision to terminate as soon as reasonably practical and shall advise the Applicant of the effective date of termination. Alberta Innovates will have no liability or obligation to reimburse the Applicant for any Project Costs incurred after the effective date of termination and may require the Applicant to return any portions of the Investment which were spent on Ineligible Expenses. Additionally, any portion of the Investment not used and accounted for in accordance with this Agreement as of the Project Completion Date or earlier termination is repayable by the Applicant to AI at AI’s request.