Construction; Validity Sample Clauses

The 'Construction; Validity' clause defines how the terms of a contract are to be interpreted and affirms the enforceability of the agreement even if certain provisions are found invalid. Typically, this clause clarifies that the contract should be read as a whole, and if any part is deemed unenforceable or illegal, the remainder of the contract remains effective. For example, if a specific term is struck down by a court, the rest of the agreement continues to bind the parties. This clause ensures that minor legal issues do not invalidate the entire contract, thereby preserving the parties' overall intentions and maintaining contractual stability.
POPULAR SAMPLE Copied 4 times
Construction; Validity. Wherever possible, this Agreement shall be construed in a manner that is consistent with the Managed Account provisions in the Service Agreement. An adjudication or other determination that a provision of this Agreement is invalid or unenforceable shall not affect the validity or enforceability of any remaining provision of this Agreement.
View SourceView Similar (5)
Construction; Validity. Because each of the parties to this Agreement has contributed to the preparation and drafting hereof, has read it, and has had the option and sufficient time to reviewed it with each’s respective counsel and understands its terms and contents, the terms and provisions of this Agreement shall be interpreted and construed without any presumption or inference based upon the party drafting this Agreement. This Agreement is entered into without force or duress, in the free will of the parties, and in consideration of the receipt of substantial consideration. All parties acknowledge that they have not entered into this Agreement in reliance upon any inducement or promise not otherwise contained herein. The parties have had the opportunity and sufficient time to consult extensively with counsel regarding the terms of this Agreement and have resolved any questions they may have had as to the meaning, effect or interpretation of this Agreement. The decision of the parties to enter into this Agreement is a fully-informed decision, and the parties are aware of all legal and other ramifications of such decision. 
View Source

Related to Construction; Validity

  • Contract Construction 6.27.1 The parties acknowledge that each party and its counsel have reviewed this CONTRACT and that the normal rule of construction to the effect that any ambiguities are to be resolved against the drafting party shall not be employed in the interpretation of this CONTRACT or any amendment or exhibits hereto.

  • Project Construction The Contractor agrees to provide continuous on-site supervision on each Job Order, while progress on the project is being accomplished. The Contractor’s Project Manager will ensure: 1. Coordination and providing supervision to all Subcontractor and workers; 2. Posting of the prevailing wage scale; 3. Maintaining a copy of the Contractors safety program manual made available to all construction personnel; 4. Conducting weekly on-site safety meetings; 5. Completing the daily labor and construction progress log on a daily basis and submit copies to the County on a daily basis. Copies of the previous day’s reports must be submitted by 9:00AM of the following day. a. Daily labor log is to include a listing of Subcontractor(s) and a count of workers by trade providing services for the day. b. Construction progress log is to include a narrative of the Work provided by trade(s). Narrative agrees to include the various areas of the jobsite where Work was performed and any problems or conditions that were encountered. c. In the event the Contractor fails to provide a daily log and/or construction progress log, the County may impose damages against the Contractor in the amount of fifty dollars ($50.00) for each log and deduct from the Contractor’s payment request, for each day the Contractor does not provide the documentation. 6. County may suspend Contractor operations if no Contractor Superintendent is observed. All delays caused by the suspension will be the responsibility of the Contractor. No time extension or claims for cost(s) associated with the suspension will be granted by the County.

  • Law; Construction This Agreement and any claim, counterclaim or dispute of any kind or nature whatsoever arising out of or in any way relating to this Agreement (“Claim”), directly or indirectly, shall be governed by, and construed in accordance with, the internal laws of the State of New York.

  • Strict Construction The parties to this Agreement have participated jointly in the negotiation and drafting of this Agreement. In the event an ambiguity or question of intent or interpretation arises, this Agreement will be construed as if drafted jointly by the parties, and no presumption or burden of proof will arise favoring or disfavoring any party by virtue of the authorship of any of the provisions of this Agreement.

  • FAIR CONSTRUCTION & INTERPRETATION The provisions of this Contract shall be construed as a whole according to their common meaning and not strictly for or against any party and consistent with the provisions contained herein in order to achieve the objectives and purposes of this Contract. Each party hereto and its counsel has reviewed and revised this Contract and agrees that the normal rules of construction to the effect that any ambiguities are to be resolved against the drafting party shall not be construed in the interpretation of this Contract. Each term and provision of this Contract to be performed by either party shall be construed to be both a covenant and a condition.