Continuation of Construction Sample Clauses

The Continuation of Construction clause ensures that construction work proceeds without interruption, even if certain disputes or issues arise during the project. Typically, this clause requires contractors to continue performing their obligations while disagreements are resolved through designated processes, such as negotiation or arbitration. Its core practical function is to prevent costly delays and maintain project momentum, thereby minimizing disruptions and financial risks for all parties involved.
POPULAR SAMPLE Copied 4 times
Continuation of Construction. BNPPLC may perform or cause to be performed any work to complete or continue the construction of the Construction Project. In this regard, so long as work ordered or undertaken by BNPPLC is not substantially inconsistent (to the extent practicable under Applicable Laws) with the general description of the Construction Project set forth in Exhibit B and the permitted use of the Property set forth in the Lease, BNPPLC will have complete discretion to: (a) proceed with construction according to such plans and specifications as BNPPLC may from time to time approve; (b) establish and extend construction deadlines as BNPPLC from time to time deems appropriate, without obligation to adhere to any deadlines for construction by NAI set forth in this Agreement; (c) hire, fire and replace architects, engineers, contractors, construction managers and other consultants as BNPPLC from time to time deems appropriate, without obligation to use, consider or compensate architects, engineers, contractors, construction managers or other consultants previously selected or engaged by NAI; (d) determine the compensation that any architect, engineer, contractor, construction manager or other consultant engaged by BNPPLC will be paid, and the terms and conditions that will govern the payment of such compensation (including whether payment will be due in advance, over the course of construction or on some other basis and including whether contracts will be let on a fixed price basis, a cost plus a fee basis or some other basis), as BNPPLC from time to time reasonably deems appropriate; (e) pay, settle or compromise existing or future bills and claims which are or may be liens against the Property or as BNPPLC reasonably considers necessary or desirable for the completion of the Construction Project or the removal of any clouds on title to the Property; (f) prosecute and defend all actions or proceedings in connection with the construction of the Construction Project; (g) select and change interior and exterior finishes for the Improvements and landscaping as BNPPLC from time to time deems appropriate; and (h) generally do anything that NAI itself might have done if NAI had satisfied or obtained BNPPLC’s waiver of the conditions specified therein.
View SourceView Similar (14)
Continuation of Construction. Borrower shall not cease construction of any Home for more than thirty (30) days without the consent of Lender for any cause not a Force Majeure Event (or for any period up to, in the aggregate, ninety (90) consecutive days as a result of one or more Force Majeure Events).
View SourceView Similar (2)
Continuation of Construction. The Tenant declares that it agrees that the Landlord, at its exclusive discretion, may continue to construct the building in which the Leased Premises and its systems are located, and that the Tenant may not object to such construction so long as the construction does not cause a change in the structure of the Leased Premises.
View Source
Continuation of Construction. After the occurrence of a Construction Termination Event (without regard to whether Lessor has notified Lessee that Lessor is terminating the Facility 2 Lease Agreement or whether Lessee has elected to exercise the Marketing Option as provided in clause (ii) above), Lessee shall continue diligently to construct the New Improvements in accordance with this Agreement until the Completion thereof; provided, however, that:
View SourceView Similar (2)
Continuation of Construction. BNPLC may perform or cause to be performed any work to complete or continue the construction of the Construction Project. In this regard, so long as work ordered or undertaken by BNPLC is substantially consistent (to the extent practicable under Applicable Laws) with the general description of the Construction Project set forth in Exhibit B to the Construction Management Agreement and the permitted use of the Property set forth in subparagraph 3.(a), BNPLC shall have complete discretion to: a) proceed with construction according to such plans and specifications as BNPLC may from time to time approve; b) establish and extend construction deadlines as BNPLC from time to time deems appropriate, without obligation to adhere to the deadlines for Construction Milestones set forth in the Construction Management Agreement; c) hire, fire and replace architects, engineers, contractors, construction managers
View SourceView Similar (2)
Continuation of Construction. Seller shall, from and after the ---------------------------- Effective Date of this Agreement to the date of Closing, (i) continue to prosecute the construction and development of the Project in accordance with the Plans and Specifications and the Permitted Exceptions with diligence and without interruption, unless such interruption is due to an event or occurrence beyond Seller's reasonable control (it being agreed, however, that lack of funds and contractor defaults are not events or occurrences beyond Seller's reasonable control), (ii) except for change orders which would not require Purchaser's prior consent if effectuated after Closing as provided in Paragraph 16(d) hereof, not modify, amend, or terminate the Architect's Agreement or the Construction Agreements without the prior written consent of Purchaser, which consent shall not be unreasonably withheld or delayed, (iii) not waive any rights of Seller under the Architect's Agreement or Construction Contracts, and (iv) perform and discharge all of the duties and obligations and comply with every covenant and agreement of the Seller or the "Owner" under the Architect's Agreement and Construction Agreements, in the manner and within the time limits required thereunder. Furthermore, Seller shall, for the same period of time, use diligent and good faith efforts to cause the Architect and the Contractors to perform all of their respective duties and obligations and otherwise comply with each and every one of their respective covenants and agreements under the Architect's Agreement and Construction Agreements.
View Source
Continuation of Construction. BNPLC may perform or cause to be performed any work to complete or continue the construction of the
View Source
Continuation of Construction. Sellers shall diligently continue construction at each applicable Project in substantial accordance with the plans and specifications therefor and comply in all material respects with all ordinances, regulations and governmental requirements in connection therewith.
View Source
Continuation of Construction. BNPPLC may perform or cause to be performed any work to complete or continue the construction of the Construction Project. In this regard, so long as work ordered or undertaken by BNPPLC is substantially consistent (to the extent practicable under Applicable Laws) with the general description of the Construction Project set forth in Exhibit B to the Construction Management Agreement and the permitted use of the Property set forth in subparagraph, BNPPLC shall have complete discretion to:
View Source

Related to Continuation of Construction

  • Completion of Construction Within 60 days of the completion of construction of the Project, Project Owner shall deliver to DoD copies of the FAA form 7460-2 for each ASN, including the final coordinates for each turbine erected.

  • Commencement of Construction Construction of the Project will start within thirty (30) days after notification to the Developer by the Owner, or as soon thereafter as weather and ground conditions permit.

  • ICIF Construction The ICIF shall be designed and constructed in accordance with Good Utility Practice. Within one hundred twenty (120) Calendar Days after the Commercial Operation Date, unless the Parties agree on another mutually acceptable deadline, Interconnection Customer shall deliver to Transmission Provider and Transmission Owner “as-built” drawings, information and documents for the ICIF, such as: a one-line diagram, a site plan showing the Generating Facility and the ICIF, plan and elevation drawings showing the layout of the ICIF, a relay functional diagram, relaying AC and DC schematic wiring diagrams and relay settings for all facilities associated with the Interconnection Customer’s step-up transformers, the facilities connecting the Generating Facility to the step-up transformers and the ICIF, and the impedances (determined by factory tests) for the associated step-up transformers and the Generating Facility. Interconnection Customer shall provide Transmission Provider and Transmission Owner with Interconnection Customer’s specifications for the excitation system, automatic voltage regulator, Generating Facility control and protection settings, transformer tap settings, and communications, if applicable.

  • DAF Construction The DAF shall be designed and constructed in accordance with Good Utility Practice. Within one hundred twenty (120) Calendar Days after the Commercial Operation Date, unless the Developer and Connecting Transmission Owner agree on another mutually acceptable deadline, the Developer shall deliver to the Connecting Transmission Owner and NYISO “as- built” drawings, information and documents for the DAF, such as: a one-line diagram, a site plan showing the Large Generating Facility and the DAF, plan and elevation drawings showing the layout of the DAF, a relay functional diagram, relaying AC and DC schematic wiring diagrams and relay settings for all facilities associated with the Developer’s step-up transformers, the facilities connecting the Large Generating Facility to the step-up transformers and the DAF, and the impedances (determined by factory tests) for the associated step-up transformers and the Large Generating Facility. The Developer shall provide to, and coordinate with, Connecting Transmission Owner and NYISO with respect to proposed specifications for the excitation system, automatic voltage regulator, Large Generating Facility control and protection settings, transformer tap settings, and communications, if applicable.

  • Manner of Construction Landlord may impose, as a condition of its consent to any and all Alterations or repairs of the Premises or about the Premises that required the consent of Landlord, such requirements as Landlord in its reasonable discretion may deem desirable, including, but not limited to, the requirement that Tenant utilize for such purposes only contractors, subcontractors, materials, mechanics and materialmen approved in advance by Landlord (which approval shall not be unreasonably withheld, conditioned or delayed), or the requirement that Tenant shall, at Tenant's expense, remove such Alterations upon the expiration or any early termination of the Lease Term. Tenant shall construct such Alterations and perform such repairs in a good and workmanlike manner, in conformance with any and all applicable federal, state, county or municipal laws, rules and regulations and, if applicable, pursuant to a valid building permit, issued by the city in which the Building is located (or other applicable governmental authority), all in conformance with Landlord's reasonable construction rules and regulations; provided, however, that prior to commencing to construct any Alteration, Tenant shall meet with Landlord to discuss Landlord's design parameters and code compliance issues. In the event Tenant performs any Alterations in the Premises which require or give rise to governmentally required changes to the "Base Building," as that term is defined below, then Landlord shall, at Tenant's expense, make such changes to the Base Building. The "Base Building" shall include the structural portions of the Building, including the roof, foundation and exterior walls and windows), and the exit stairwells and the systems and equipment located in the internal core of the Building. In performing the work of any such Alterations, Tenant shall have the work performed in such manner so as not to materially obstruct access to the Project or any portion thereof, by any other tenant of the Project, and so as not to materially obstruct the business of Landlord or other tenants in the Project. Tenant shall not use (and upon notice from Landlord shall cease using) contractors, services, workmen, labor, materials or equipment that, in Landlord's reasonable judgment, would disturb labor harmony with the workforce or trades engaged in performing other work, labor or services in or about the Building or the Common Areas. Upon completion of any Alterations (or repairs), Tenant shall deliver to Landlord final lien waivers from all contractors, subcontractors and materialmen who performed such work. In addition to Tenant's obligations under Article 9 of this Lease, upon completion of any Alterations, Tenant shall deliver to the Project construction manager a reproducible copy of the "as built" drawings of the Alterations, if any, as well as copies of any permits, approvals and other documents issued by any governmental agency in connection with the Alterations.