Contractor’s Entitlement to Suspend Work Clause Samples

The Contractor’s Entitlement to Suspend Work clause grants the contractor the right to temporarily halt work on a project under certain specified circumstances, such as non-payment or breaches by the client. In practice, this clause typically outlines the conditions that must be met before suspension is allowed, the notice requirements the contractor must follow, and the contractor’s obligations during the suspension period. Its core function is to provide the contractor with a formal mechanism to protect their interests and encourage compliance from the client, particularly in situations where continuing work would be unfair or financially risky for the contractor.
POPULAR SAMPLE Copied 2 times
Contractor’s Entitlement to Suspend Work. Delete the words “21 days” in line 4 of paragraph 1 and replace by “28 days”.
View Source
Contractor’s Entitlement to Suspend Work. Notwithstanding the other provisions of this Sub-Clause, if the Bank has suspended disbursements under the loan or credit from which payments to the Contractor are being made, in whole or in part, for the execution of the Works, and no alternative funds are available as provided for in Sub-Clause 2.4 [Employer’s Financial Arrangements], the Contractor may by notice suspend work or reduce the rate of work at any time, but not less than 7 days after the Contractor was informed of the Borrower and the Employer having received the suspension notification from the Bank. The Contractor’s action shall not prejudice his entitlements to financing charges under Sub- Clause 14.8 [Delayed Payment] and to termination under Sub-Clause 16.2 [Termination by Contractor]. If the Contractor subsequently receives such Payment Certificate, evidence or payment (as described in the relevant Sub-Clause and in the above notice) before giving a notice of termination, the Contractor shall resume normal working as soon as is reasonably practicable. If the Contractor suffers delay and/or incurs Cost as a result of suspending work (or reducing the rate of work) in accordance with this Sub-Clause, the Contractor shall give notice to the Engineer and shall be entitled subject to Sub-Clause 20.1 [Contractor’s Claims] to:
View SourceView Similar (6)
Contractor’s Entitlement to Suspend Work. 16.1 Sub Clause 16.1 is amended to read as under: If the Engineer fails to certify in accordance with Sub-Clause 14.6 [ Issue of Interim Payment Certificates ] or Sub-Clause 14.7 [ Payment ], the Contractor may, after giving not less than 21 days’ notice to the Employer, suspend work (or reduce the rate of work) unless and until Item Sub- Clause Data the Contractor has received the Payment Certificate, reasonable evidence or payment, as the case may be and as described in the notice. The Contractor’s action shall not prejudice his entitlements to financing charges under Sub-Clause 14.8 [ Delayed Payment ] and to termination under Sub-Clause 16.2 [ Termination by Contractor ]. If the Contractor subsequently receives such Payment Certificate, evidence or payment (as described in the relevant Sub-Clause and in the above notice) before giving a notice of termination, the Contractor shall resume normal working as soon as is reasonably practicable. If the Contractor suffers delay and/or incurs Cost as a result of suspending work (or reducing the rate of work) in accordance with this Sub-Clause, the Contractor shall give notice to the Engineer and shall be entitled subject to Sub-Clause 20.1 [ Contractor’s Claims ] to: (a) an extension of time for any such delay, if completion is or will be delayed under Sub-Clause 8.4 [ Extension of Time for Completion and (b) payment of any such Cost plus profit, which shall be included in the Contract Price. After receiving this notice, the Engineer shall proceed in accordance with Sub-Clause 3.5 [Determinations] to agree or determine these matters.
View SourceView Similar (4)
Contractor’s Entitlement to Suspend Work. 承包商暂停工作的权利 If the Employer fails to comply with Sub-Clause 2.4 [Employer’s Financial Arrangements] or Sub-Clause 14.7 [Timing of Payments], the Contractor may, after giving not less than 21 days’ notice to the Employer, suspend work (or reduce the rate of work) unless and until the Contractor has received the reasonable evidence or payment, as the case may be and as described in the notice. 如果雇主未能遵守第 2.4 款[雇主的资金安排]或第 14.7 款[付款的时间安排]的规定，承包商可在不少于 21 天前通知雇主，暂停工作（或放慢工作速度），除非并直到承包商根据情况和通知中所述，收到付款证书、合理的证明或付款为止。 The Contractor’s action shall not prejudice his entitlements to financing charges under Sub-Clause
View Source
Contractor’s Entitlement to Suspend Work. (a) If the Employer fails to comply with Clause 14.7 ( Timing of Payments), the Contractor may, after giving not less than thirty (30) days’ notice to the Employer, suspend work (or reduce t he r ate of work) u nless a nd u ntil the C ontractor has received t he pa yment, a s described in the notice. (b) The C ontractor’s action s hall not pr ejudice i ts e ntitlement t o financing c ▇▇▇▇▇▇ und er Clause 14.8 ( Delayed Payment) and t o t ermination under C ▇▇▇▇▇ 16 .2 ( Termination by Contractor). (c) If the Contractor subsequently receives such payment (as described in the relevant Clause and in the above notice) before giving a notice of termination, the Contractor shall resume normal working as soon as is reasonably practicable. (d) If the C ontractor su ffers d elay and /or i ncurs C ost a s a r esult of suspending w ork ( or reducing the rate of work) in accordance with this Clause, the Contractor shall give notice to the Employer and shall be entitled subject to Clause 20.1 (Contractor’s Claims) to: (i) an extension of time for any such delay, if completion is or will be delayed, under Clause 8.4 (Extension of Time for Completion), and (ii) payment of a ny s uch C ost pl us r easonable p rofit, w hich s hall be a dded to t he Contract Price. (e) After r eceiving th is notice, the E mployer sh all p roceed in accordance w ith C ▇▇▇▇▇ 3 .5 (Determinations) to agree or determine these matters.
View Source
Contractor’s Entitlement to Suspend Work. If the Engineer fails to certify in accordance with Sub-Clause 14.6 [
View Source
Contractor’s Entitlement to Suspend Work. If the Engineer fails to certify in accordance with Sub-Clause 14.6 [Issue of Interim Payment Certificates] or the Employer fails to comply with Sub-Clause 2.4 [Employer’s Financial Arrangements] or Sub-Clause 14.7 [Payment], the Contractor may, after giving not less than 21 days’ notice to the Employer, suspend work (or reduce the rate of work) unless and until the Contractor has received the Payment Certificate, reasonable evidence or payment, as the case may be and as described in the notice. Notwithstanding the above, if the Bank has suspended disbursements under the financing from which payments to the Contractor are being made, in whole or in part, for the execution of the Works, and no alternative funds are available as provided for in Sub-Clause 2.4 [Employer’s Financial Arrangements], the Contractor may by notice suspend work or reduce the rate of work at any time, but not less than 7 days after the Beneficiary having received the suspension notification from the Bank. The Contractor’s action shall not prejudice his entitlements to financing charges under Sub-Clause 14.8 [Delayed Payment] and to termination under Sub-Clause
View Source
Contractor’s Entitlement to Suspend Work. In Sub-clause 16.1, delete “Sub-Clause 2.4 or” in the first paragraph.
View Source
Contractor’s Entitlement to Suspend Work. Delete the first paragraph of Sub-clause 16.1 and replace with following: If the Employer fails to certify in accordance with Sub-clause 14.6, or the Employer does not comply with the time for the Contractor's due payments in accordance with Sub-clause 14.7, the Contractor may, after giving not less than 21 days notice to the Employer, suspend work (or reduce the rate of work) unless and until the Contractor has received the Payment Certificate, or the due payment, as the case may be and as described in such notice. Add the following paragraph at the end of this Sub-clause: The Contractor shall, within 3 days after the date of submission of the Statement for Interim Payment, notify the Employer with the date of submission of such statement.
View Source

Related to Contractor’s Entitlement to Suspend Work

  • PAYMENT TO SUB-CONTRACTORS 12.1 Transnet reserves the right, in its sole discretion, to make payment directly to the sub-contractor of the Supplier/Service Provider, subject to the following conditions: a) Receipt of an undisputed invoice from the sub-contractor; and b) Receipt of written confirmation from the Supplier/Service Provider that the amounts claimed by the sub-contractor are correct and that the services for which the sub- contractor has requested payment were rendered to the satisfaction of the Supplier/Service Provider, against the required standards. 12.2 Nothing contained in this clause must be interpreted as bestowing on any sub-contractor a right or legitimate expectation to be paid directly by Transnet. Furthermore, this clause does not bestow any right or legitimate expectation on the Supplier/Service provider to demand that Transnet pay its sub-contractor directly. The decision to pay any sub-contractor directly, remains that of Transnet alone.

  • Prompt Payment to Subcontractors (a) Within 7 days of receipt by the Contractor of each payment from the City under this contract, the Contractor shall pay all Subcontractors (which term includes subconsultants and suppliers) based on work completed or service provided under the subcontract. Should any payment to the Subcontractor be delayed by more than 7 days after receipt of payment by the Contractor from the City under this contract, the Contractor shall pay the Subcontractor interest, beginning on the 8th day, at the rate of 1% per month or fraction thereof on such unpaid balance as may be due. By appropriate litigation, Subcontractors shall have the right to enforce this subsection (a) directly against the Contractor, but not against the City of Durham. (b) If the individual assigned to administer this contract for the City (in this section, titled “Prompt Payment to Subcontractors,” he or she will be referred to as the “Project Manager”) determines that it is appropriate to enforce subsection (a) in this manner, the City may withhold from progress or final payments to the Contractor the sums estimated by the Project Manager to be (i) the amount of interest due to the Subcontractor under subsection (a), and/or (ii) the amounts past-due under subsection (a) to the Subcontractor but not exceeding 5% of the payment(s) due from the City to the Contractor. This subsection (b) does not limit any other rights to withhold payments that the City may have. (c) Nothing in this section (titled “Prompt Payment to Subcontractors”) shall prevent the Contractor at the time of invoicing, application, and certification to the City from withholding invoicing, application, and certification to the City for payment to the Subcontractor for unsatisfactory job progress; defective goods, services, or construction not remedied; disputed work; third-party claims filed or reasonable evidence that such a claim will be filed; failure of the subcontractor to make timely payments for labor, equipment, and materials; damage to the Contractor or another subcontractor; reasonable evidence that the subcontract cannot be completed for the unpaid balance of the subcontract sum; or a reasonable amount for retainage not to exceed 10%. (d) The Project Manager may require, as a prerequisite to making progress or final payments, that the Contractor provide statements from any Subcontractors designated by the Project Manager regarding the status of their accounts with the Contractor. The statements shall be in such format as the Project Manager reasonably requires, including notarization if so specified.

  • Payment to Subcontractors (If applicable) As required by Minnesota Statute § 16A.1245, the prime Contractor must pay all subContractors, less any retainage, within 10 calendar days of the prime Contractor’s receipt of payment from the State for undisputed services provided by the subContractor(s) and must pay interest at the rate of one and one-half percent per month or any part of a month to the subContractor(s) on any undisputed amount not paid on time to the subContractor(s).

  • APPLICABILITY TO SUBCONTRACTORS Respondent agrees that all contracts it awards pursuant to the contract awarded as a result of this Agreement will be bound by the foregoing terms and conditions.

  • Entitlement to Force Majeure relief An Affected Party is entitled to Force Majeure relief if and to the extent that: (a) performance of the Relevant Obligation has been prevented or materially impeded by reason of a Force Majeure Event; (b) it has taken all reasonable steps, taking account of all relevant circumstances (including as to whether the event in question could reasonably have been anticipated): (i) to avoid the occurrence of the Force Majeure Event; and (ii) to minimise, and where practicable avoid, the effects of the Force Majeure Event on its ability to perform the Relevant Obligation; and (c) except in the case of clause 17.1(f), none of the Affected Party, its officers, employees or agents caused the Force Majeure Event.