Cooperation with Financing (a) Prior to the Closing, each of the Seller Parties shall use reasonable best efforts to provide, and shall cause the other Target Companies to use reasonable best efforts to provide, and shall use reasonable best efforts to cause its and their respective Representatives to provide, in each case at US Buyer’s sole cost and expense, such cooperation as may reasonably be requested by US Buyer that is customary and necessary in connection with arranging and obtaining the Financing contemplated by the Commitment Letter, including (in each case to the extent that the same is reasonably requested or is otherwise expressly required by the Commitment Letter):
(i) assisting in preparation for and participation in marketing efforts (including a reasonable number of meetings with prospective lenders on reasonable advance notice and during normal business hours, due diligence and drafting sessions, and not more than one presentation and session with rating agencies);
(ii) providing the Required Financial Information to US Buyer;
(iii) if the Closing has not occurred, on or prior to February 14, 2017, furnishing US Buyer and the Financing Sources on or before February 15, 2017, with the unaudited consolidated balance sheet, consolidated income statement and consolidated cash flow statement of the Business for the 12 months ended December 31, 2016;
(iv) furnishing US Buyer and the Financing Sources with all other financial and other pertinent information regarding the Business as is required by the Commitment Letter and reasonably requested by US Buyer; provided, that no such preparation of materials or information (including in relation to clause (a)(i) above) shall require the preparation by any Seller Party, Target Company or the Business of pro forma financial or other pro forma information not currently available as of the date of this Agreement;
(v) facilitating delivery at the Closing of customary evidence of property and liability insurance, including endorsements in favor of the Financing Sources;
(vi) executing and delivering such documents, instruments, certificates or information, as may be reasonably requested in connection with the Financing (including all documentation and other information required by bank regulatory authorities under applicable “know-your-customer” and anti-money laundering rules and regulations, including the Patriot Act) so long as any such documents, instruments certificates or information are requested by US Buyer at least ten Business Days prior to the Closing Date;
(vii) delivering such officer’s certificates as are customary in financings of such type (including a certificate of the chief financial officer of US Seller with respect to solvency matters in the form attached to the Commitment Letter) and as are, in the good faith determination of the Person(s) executing such certificates, accurate in all material respects, and agreeing to pledge, grant security interests in, and otherwise grant Liens on, the Assets pursuant to such agreements, documents, instruments and certificates as may be reasonably requested (including such agreements, documents or certificates that facilitate the creation, perfection or enforcement of Liens securing the Financing (including original copies of all certificated securities (with transfer powers executed in blank)) as may be reasonably requested by US Buyer, and executing and delivering any pledge and security documents and otherwise facilitating the pledging of collateral); provided that no obligation of the Seller Parties, the Target Companies or any of their Subsidiaries under any such agreement or other financing document shall be effective until the Closing;
(viii) taking all corporate actions reasonably necessary to permit the consummation of the Financing; and
(ix) executing and delivering definitive agreements (the “Definitive Financing Agreements”) with respect to the Financing, subject to the occurrence of the Closing. Notwithstanding the foregoing: (1) US Buyer shall ensure that such requested cooperation does not unreasonably interfere with the Business (it being understood and agreed that neither any Seller nor any Target Company shall be required to take any action that unreasonably interferes with the Business); (2) neither any Seller nor any Target Company nor any of their respective Representatives, shall, in connection with the Financing: (A) be required to take any action that would result in a violation of applicable Law or breach of any Contract or subject it to actual or potential Liability; (B) have any Liability under any Definitive Financing Agreement or any related document or other agreement or document related to the Financing, other than any such Liability of any Target Company following the Closing; (C) be required to incur any other Liability in connection with the Financing, other than any other Liability incurred by any Target Company following the Closing; (D) be required to disclose or provide any information the disclosure of which, in the reasonable judgment of any Seller or any Target Company supported by outside legal counsel, is restricted by Contract, applicable Law or Order, is subject to attorney-client privilege, or would result in the disclosure of any trade secrets of third parties or violate any obligation of any Seller or any Target Company with respect to confidentiality; (E) be required to enter into or perform under any agreement with respect to the Financing that is not contingent upon the Closing or that would be effective prior to or simultaneous with the Closing, or (F) be required to waive or amend any terms of this Agreement or agree to pay any fees or reimburse any expenses prior to the Closing for which it has not received prior reimbursement or is not otherwise indemnified by or on behalf of any Buyer.
(b) US Buyer shall, promptly upon request by the Sellers’ Representative, reimburse Sellers and the Target Companies and/or their respective Representatives for all reasonable and documented out-of-pocket fees, costs and expenses, including all reasonable and documented out-of-pocket fees and expenses of outside counsel and other advisors, incurred by any Seller, any Target Company or such Representative in connection with the cooperation contemplated by Section 7.18(a). US Buyer shall indemnify and hold harmless Sellers, the Target Companies and their respective Representatives (collectively, the “Financing Indemnitees”) against any and all Losses (including advancing attorneys’ fees and expenses in advance of the final disposition of any Proceeding) directly or indirectly suffered or incurred by the Financing Indemnitees in connection with the Financing, including any information provided in connection therewith or the cooperation by any Seller or any Target Company with respect thereto, in each case, other than to the extent arising out of any Seller’s, any Target Company’s or any of their respective Representative’s gross negligence, bad faith or willful misconduct. This Section 7.18(b) shall survive the consummation of the transactions contemplated by this Agreement and the Closing and any termination of this Agreement, and is intended to benefit, and may be enforced by, the Financing Indemnitees and their respective heirs, executors, estates, personal representatives, successors and assigns, and shall be binding on all successors and permitted assigns of Buyers.
(c) Each Seller Party hereby consents, and agrees to cause the other Target Companies to consent to, to the use of its and their logos solely in connection with the Financing upon prior notice to the Sellers’ Representative; provided, however, that such logos shall be used solely in a manner that is not intended or reasonably likely to harm, disparage or otherwise adversely affect any Seller Party or any other Target Company.
(d) Each Buyer acknowledges and agrees that, other than the obligations to cooperate expressly set forth in this Section 7.18, no Seller or any Target Company has any responsibility or liability in relation to any financing that any Buyer may seek or obtain in connection with the transactions contemplated by this Agreement.
Construction of the Project Highway (i) The Contractor shall construct the Project Highway as specified in Schedule- B and Schedule-C, and in conformity with the Specifications and Standards set forth in Schedule-D. The Contractor shall be responsible for the correct positioning of all parts of the Works, and shall rectify any error in the positions, levels, dimensions or alignment of the Works. The [650th (six hundred and fiftieth) day] from the Appointed Date shall be the scheduled completion date (the “Scheduled Completion Date”) and the Contractor agrees and undertakes that the construction shall be completed on or before the Scheduled Completion Date, including any extension thereof.
(ii) The Contractor shall construct the Project Highway in accordance with the Project Completion Schedule set forth in Schedule-J. In the event that the Contractor fails to achieve any Project Milestone or the Scheduled Completion Date within a period of 30 (thirty) days from the date set forth in Schedule-J, unless such failure has occurred due to Force Majeure or for reasons solely attributable to the Authority, it shall pay Damages to the Authority of a sum calculated at the rate of 0.05% (zero point zero five percent) of the Contract Price for delay of each day reckoned from the date specified in Schedule –J and until such Project Milestone is achieved or the Project Highway is completed; provided that if the period for any or all Project Milestones or the Scheduled Completion Date is extended in accordance with the provisions of this Agreement, the dates set forth in Schedule-J shall be deemed to be modified accordingly and the provisions of this Agreement shall apply as if Schedule-J has been amended as above; provided further that in the event the Project Highway is completed within or before the Scheduled Completion Date including any Time Extension, applicable for that work or section, the Damages paid under this Clause 10.3 (ii) shall be refunded by the Authority to the Contractor, but without any interest thereon. The Parties agree that for determining achievement or delays in completion of the Project Milestones or the Project on the due date, the works affected due to delay in providing the site for which time extension has been granted beyond the Scheduled Completion Date will be excluded. For example on the due date to achieve the Project Milestone-I (i.e., Stage Payments of 10% (ten percent) of Contract Price on 180th (one hundred and eighty) day from the Appointed Date), if 5% (five percent) of the project length corresponding to the Project Milestone-I is not handed over or lately handed over resulting in the extension of completion of this 5% (five percent) length beyond Scheduled Completion Date, Stage Payment of 10% X 0.95 = 9.5% only is to be achieved by 180th (one hundred and eighty) day. For the avoidance of doubt, it is agreed that recovery of Damages under this Clause 10.3 (ii) shall be without prejudice to the rights of the Authority under this Agreement including the right of Termination thereof. The Parties further agree that Time Extension hereunder shall only be reckoned for and in respect of the affected Works as specified in Clause 10.5 (ii).
(iii) The Authority shall notify the Contractor of its decision to impose Damages in pursuance with the provisions of this Clause 10.3. Provided that no deduction on account of Damages shall be effected by the Authority without notifying the Contractor of its decision to impose the Damages, and taking into consideration the representation, if any, made by the Contractor within 20 (twenty) days of such notice. The Parties expressly agree that the total amount of Damages under Clause 10.3 (ii) shall not exceed 10% (ten percent) of the Contract Price. If the damages exceed 10% (ten percent) of the Contract Price, the Contractor shall be deemed to be in default of this agreement having no cure and the Authority shall be entitled to terminate this Agreement by issuing a Termination Notice in accordance with the provisions of Clause 23.1 (ii).
(iv) In the event that the Contractor fails to achieve the Project Completion within a period of 90 (ninety) days from the Schedule Completion Date set forth in Schedule-J, unless such failure has occurred due to Force Majeure or for reasons solely attributable to the Authority, the contractor shall be deemed to be ineligible for bidding any future projects of the Authority, both as the sole party or as one of the parties of Joint Venture/ Consortium during the period from Scheduled Completion Date to issuance of Completion Certificate. This restriction is applicable if the contract value of the delayed project is not less than Rs. 300 Crore.