Cost to Students Sample Clauses

Cost to Students. 3.1 Internet access through the Department’s network is provided at no cost. 3.2 Access to school resources such as shared drives, printers and associated costs will be covered by Computer Access Fee. 3.3 Access to Technical Support Officer to assist with connection of devices to wireless and installation of DEC provided software and ongoing support will be covered by ▇▇▇▇ ▇▇▇▇ and contribution from School Funds.
View SourceView Similar (4)
Cost to Students. 4.1 Internet access through the Department’s network will be provided at no cost to students enrolled in NSW Public Schools at DEC sites. 4.2 Access to school resources such as shared drives, printers and associated costs will be provided.
View SourceView Similar (2)
Cost to Students 
View Source

Related to Cost to Students

  • Payments to Subcontractors Develop and implement a procedure for the review, processing and payment of applications by subcontractors for progress and final payments.

  • Payment to Subcontractors (If applicable) As required by Minnesota Statute § 16A.1245, the prime Contractor must pay all subContractors, less any retainage, within 10 calendar days of the prime Contractor’s receipt of payment from the State for undisputed services provided by the subContractor(s) and must pay interest at the rate of one and one-half percent per month or any part of a month to the subContractor(s) on any undisputed amount not paid on time to the subContractor(s).

  • Prompt Payment to Subcontractors (a) Within 7 days of receipt by the Contractor of each payment from the City under this contract, the Contractor shall pay all Subcontractors (which term includes subconsultants and suppliers) based on work completed or service provided under the subcontract. Should any payment to the Subcontractor be delayed by more than 7 days after receipt of payment by the Contractor from the City under this contract, the Contractor shall pay the Subcontractor interest, beginning on the 8th day, at the rate of 1% per month or fraction thereof on such unpaid balance as may be due. By appropriate litigation, Subcontractors shall have the right to enforce this subsection (a) directly against the Contractor, but not against the City of Durham. (b) If the individual assigned to administer this contract for the City (in this section, titled “Prompt Payment to Subcontractors,” he or she will be referred to as the “Project Manager”) determines that it is appropriate to enforce subsection (a) in this manner, the City may withhold from progress or final payments to the Contractor the sums estimated by the Project Manager to be (i) the amount of interest due to the Subcontractor under subsection (a), and/or (ii) the amounts past-due under subsection (a) to the Subcontractor but not exceeding 5% of the payment(s) due from the City to the Contractor. This subsection (b) does not limit any other rights to withhold payments that the City may have. (c) Nothing in this section (titled “Prompt Payment to Subcontractors”) shall prevent the Contractor at the time of invoicing, application, and certification to the City from withholding invoicing, application, and certification to the City for payment to the Subcontractor for unsatisfactory job progress; defective goods, services, or construction not remedied; disputed work; third-party claims filed or reasonable evidence that such a claim will be filed; failure of the subcontractor to make timely payments for labor, equipment, and materials; damage to the Contractor or another subcontractor; reasonable evidence that the subcontract cannot be completed for the unpaid balance of the subcontract sum; or a reasonable amount for retainage not to exceed 10%. (d) The Project Manager may require, as a prerequisite to making progress or final payments, that the Contractor provide statements from any Subcontractors designated by the Project Manager regarding the status of their accounts with the Contractor. The statements shall be in such format as the Project Manager reasonably requires, including notarization if so specified.

  • APPLICABILITY TO SUBCONTRACTORS Respondent agrees that all contracts it awards pursuant to the contract awarded as a result of this Agreement will be bound by the foregoing terms and conditions.

  • Owner’s Right to Stop Work The Owner reserves the right, for itself and for any designated Construction Inspector retained by Owner, upon observation of apparent nonconforming Work, to immediately stop the affected Work. If the Work is later determined by the Design Professional to be in fact conforming Work, then Contractor shall be entitled upon timely claim to a Change Order for payment by Owner of any reasonable Actual Costs actually incurred by Contractor in connection with the stop Work order and resumption of the Work, as well as an extension in the time for performance of the Work to the extent Contractor is delayed by Owner's stop Work order. The Design Professional shall determine the time, which shall be binding upon both Owner and Contractor, as set forth in Section 3, Part 3.