Damage or Destruction of Project Clause Samples

The "Damage or Destruction of Project" clause outlines the procedures and responsibilities if the project or its works are damaged or destroyed during construction. Typically, it specifies who bears the risk, how repairs or reconstruction will be handled, and whether insurance coverage applies to such events. For example, the clause may require the contractor to promptly repair damage at their own cost or allow for contract adjustments if the destruction is extensive. Its core function is to allocate risk and provide a clear process for addressing unexpected physical loss, ensuring that both parties understand their obligations and remedies in the event of damage.
Damage or Destruction of Project. Subject in all events to any obligation on the part of the Company to make any Equalization Payments which may be due on any Removed Component:
View SourceView Similar (3)
Damage or Destruction of Project. In the event that the Project is damaged or destroyed by any cause whatsoever, the Tenant shall promptly repair such damage subject to the following provisions: (a) if, in the reasonable opinion of the Tenant the Project cannot be rebuilt or made fit for the purposes of the Tenant within Eighteen (18) Months of the damage or destruction, the Tenant may, at its option, terminate this Sublease by giving the HRRA Six (6) Months' notice of termination and the Tenant shall deliver up possession of the Subleased Premises to the HRRA in the condition required under the terms of this Sublease on or before the expiry of such Six (6) Months; and (b) if, in the reasonable opinion of the Tenant, no less than Fifty (50%) Percent of the Project in rendered unusable and requires reconstruction, the Tenant may, at its option, terminate this Sublease by giving the HRRA Six (6) Months' notice of termination and the Tenant shall deliver up possession of the Subleased Premises to the HRRA in the condition required under the terms of this Sublease on or before the expiry of such Six (6) Months.
View SourceView Similar (2)
Damage or Destruction of Project. 10 Section 3.8 Condemnation 11 Section 3.9 Maintenance of Existence 11
View Source
Damage or Destruction of Project. In the event that the Other Loans and the City Loans have been paid in full, and if the Project or any part of it is to be repaired or reconstructed, after damage or destruction of the Project or its condemnation, all proceeds collected under any and all policies of insurance referred to in Article V above covering such damage or destruction, or all compensation received by Lessee for such taking by the exercise of the power of eminent domain, shall be paid into a special fund to be created and held by the Lessee and to be designated as the construction fund, during such repairing or reconstructing. Any surplus of such insurance or condemnation proceeds remaining after the completion of all payments for such repairing or reconstructing shall be held or applied by the Lessee in a manner consistent with the applicable provision of Article V or this Article.
View Source
Damage or Destruction of Project. In the event of the damage or destruction of all or a part of the Project and the receipt of Net Proceeds equaling or exceeding $500,000, the Issuer shall either (a) repair and restore the Project or portion thereof to substantially its condition or condition of at least equivalent value, immediately prior to such event, in which instance the Net Proceeds shall be paid to the Issuer for the purpose of such repair and restoration, or (b) direct that a redemption of a portion of the Bonds shall occur in accordance with the provisions of Section 3.04 hereof, in which instance the Net Proceeds shall be paid into the Bond Fund. If the Net Proceeds are less than $500,000, the Net Proceeds shall be used as provided in clause (a) of the preceding sentence, provided, however, that repair and restoration shall not be required in the event that after such casualty the Issuer remains in compliance with the requirements of Section 4.07 hereof.
View Source
Damage or Destruction of Project. If all of the Units on the Property are demolished and Developer elects not to rebuild the Project, the concessions and waivers granted to Developer under Density Bonus Law shall terminate and the terms of this Agreement shall terminate and be of no further force and effect.
View Source
Damage or Destruction of Project. In the event of the destruction of the Project or Material Damage to the Project, then in any such case, the Borrower shall, within thirty (30) days following occurrence of such event, make a prepayment of the Construction Loan(s), plus all accrued and unpaid interest thereon; provided, however, that if (i) the Borrower desires that the Project be repaired or replaced, and (ii) each of the Power Purchase Agreement and Sublease Agreements permits sufficient time for such repair or replacement without termination, then the Borrower may repair or replace the Project and no prepayment shall be required under this Section 2.4(a) in respect of such destruction or Material Damage; provided, further, that the Lender shall be entitled to retain all insurance proceeds received in respect of such destruction or Material Damage and release the same to the Borrower for application to Project costs on the same terms and conditions as apply to the making of Construction Loans in respect of the Project, as applicable; and provided, further, that all such Construction Loans shall remain subject to prepayment in respect of any other events or circumstances that would otherwise require prepayment hereunder.
View Source
Damage or Destruction of Project 
View SourceView Similar (23)

Related to Damage or Destruction of Project

  • DAMAGE OR DESTRUCTION OF PREMISES a. In the event the Premises are damaged by fire or other perils or casualty covered by fire and extended coverage insurance, Landlord may, in its sole and absolute discretion, repair or rebuild the same within a reasonable time after the event causing such damage. This Lease shall remain in full force and effect, except that Tenant shall be entitled to a proportionate reduction of the rent from the date of damage and while such repairs are being made, such proportionate reduction to be based upon the extent to which the damage and making of such repairs shall reasonably interfere with the business carried on by Tenant in the Premises as determined by Landlord. If the damage is due to the fault or neglect of Tenant or its employees, as determined by Landlord in its sole discretion, there shall be no reduction of rent. Landlord may authorize or direct construction of an alternative structure or may elect to retain any insurance proceeds received by it if Landlord deems reconstruction or construction of an alternative structure to be impractical or unreasonable in its sole discretion. b. In the event the Premises are damaged to any extent as a result of any cause other than the perils covered by fire and extended coverage insurance, Landlord shall in its sole discretion have the option to: (1.) to repair, reconstruct or restore the Premises within a reasonable time of the event causing the damage, in which case this Lease shall continue in full force and effect, but the rent shall be proportionately reduced as provided above in 11a. during the period of such repair, reconstruction or restoration, or (2.) to give notice to Tenant at any time within sixty (60) days after such damage occurs, terminating this Lease as of the date specified in such notice, which date shall be no more than thirty (30) days after the giving of such notice. In the event of giving to Tenant such notice of termination, this Lease shall terminate and all interests of Tenant in the Premises shall cease on the date so specified in such notice and Tenant shall pay the rent, as proportionately reduced, based upon the extent, if any, to which such damage interfered with the business carried on by Tenant in the Premises, up to the date of such termination. c. With regard to Landlord’s duty or option to repair, reconstruct or restore the Premises within a reasonable time of the event causing the damage as provided in 11a. and b. above, Landlord shall act promptly and with due diligence, but Landlord shall not be responsible for delays caused by factors beyond Landlord’s control, including but not limited to delays because of strikes, work slowdowns or stoppages, accidents, acts of God, failure of any governmental or other authority to act in a timely manner, or delays caused by contractors. If such delays occur, Tenant agrees that Landlord shall not be responsible for damages, nor shall Landlord be deemed to be in default under this Lease. d. Landlord shall not be required to repair any damage by fire or other casualty, or to make any repair or replacements of any leasehold improvements, fixtures, or other personal property of Tenant.

  • Damage or Destruction (a) If the Premises shall be damaged by fire or other casualty, the Landlord shall collect the proceeds of such insurance and immediately and with all due diligence commence to repair such damage at its expense. From the date the damage occurs to the date the repairs are complete, the rent due hereunder shall be reduced by the same percentage as the percentage of the Premises which, in the Tenant's reasonable judgment, cannot be safely, economically or practically used for the operation of the Tenant's business. Anything herein to the contrary notwithstanding, if in the Tenant's reasonable judgment, any damage or destruction to the Premises from any cause whatsoever cannot be repaired within one hundred eighty (180) days following the date such damage occurs, the Tenant may terminate this Lease by written notice to the Landlord given within ninety (90) days following the occurrence of such damage. In addition, if any damage or destruction to the Premises from any cause whatsoever cannot be repaired, in the Landlord's reasonable judgment, within one hundred eighty (180) days following the date such damage occurs and the Landlord elects not to repair such damage, the Landlord shall have the right to terminate this Lease by written notice to the Tenant given within ninety (90) days after the date such damage occurred provided that no more than three (3) calendar years remain in the term hereof. Notwithstanding the foregoing, if at the time the Landlord gives such termination notice any of the renewal options provided for in the Lease have not yet been exercised and the Tenant exercises a renewal option within thirty (30) days after receipt of the Landlord's termination notice, then this Lease shall not be terminated and the Landlord shall promptly commence restoration of the Premises. (b) In the event of a termination of the Lease pursuant to this paragraph, all insurance proceeds payable by reason of damage under policies required to be carried hereunder (excluding any insurance proceeds attributable to damage to the Tenant's inventory, trade fixtures, business or leasehold improvements paid for by the Tenant) shall be paid to the Landlord.

  • Damage or Destruction Condemnation (a) The risk of loss, damage or destruction to the Property by fire or other casualty or the taking of all or part of the Property by condemnation or eminent domain or by an agreement in lieu thereof until the Closing is assumed by Seller, except to the extent otherwise provided in paragraph 6(d) of this Contract. (b) In the event that the Property shall have been damaged or destroyed, the cost of repair or restoration of which would, in Buyer's and Seller's reasonable determination, exceed the sum of One Hundred Thousand and 00/100 Dollars ($100,000.00) (the "Casualty Amount"), then at Buyer's election, Seller shall, unless Seller has previously repaired or restored the Property to its former condition, either (i) pay over or assign to Buyer, on delivery of the Deeds all amounts recovered or recoverable on account of any insurance, together with amounts equal to any deductibles thereunder, less any amounts reasonably expended by Seller for partial restoration, or (ii) direct Escrow Agent to return the Deposit to Buyer in which case all other obligations of the parties hereto shall cease and this Contract shall be void and without recourse to the parties hereto, except such liabilities and obligations as expressly survive termination of this Contract. If the Property, or any part thereof, suffers any damage, the cost of repair or restoration of which would, in Buyer's and Seller's reasonable estimation, be less than the Casualty Amount, then Buyer shall consummate the Closing, without reduction in the Purchase Price, and accept the assignment of all amounts recovered or recoverable on account of any insurance, together with the amount of any deductibles thereunder, less any amounts reasonably expended by Seller for partial restoration. (c) If all or any portion of the Property is taken by condemnation, eminent domain or by agreement in lieu thereof, or any proceeding to acquire, take or condemn all or part of the Property is threatened or commenced, Buyer may either terminate this Contract (in which event Buyer shall be entitled to a return of the Deposit) or purchase the Property in accordance with the terms hereof, without reduction in the Purchase Price, together with an assignment of Seller's right to any award paid or payable by or on behalf of the condemning authority. If Seller has received payments from the condemning authority and if Buyer elects to purchase the Property, Seller shall credit the amount of said payments against the Purchase Price at the Closing. (d) Seller shall immediately notify Buyer of any damage or destruction to the Property or any notice received by it or information or awareness acquired by it regarding the threatening of or commencement of condemnation or similar proceedings.

  • Damage, Destruction or Condemnation (a) In the event of damage to or destruction of any portion of the Project resulting from fire or other casualty during the Term, or in the event any portion of the District is condemned or taken for any public or quasi-public use or title thereto is found to be deficient during the Term, the net proceeds of any insurance relating to such damage or destruction, the net proceeds of such condemnation or taking or the net proceeds of any realization on title insurance shall be paid into, and used in accordance with a construction escrow agreement reasonably satisfactory to the City and Developer ("Casualty Escrow"). (b) If, at any time during the Term, the Project or any part thereof shall be damaged or destroyed by a casualty (the "Damaged Facilities"), Developer, at its sole cost and expense, shall commence and thereafter proceed as promptly as possible to repair, restore and replace the Damaged Facilities as nearly as possible to their condition immediately prior to the casualty and shall be entitled to draw upon the Casualty Escrow for payment of said costs. (c) If at any time during the Term, title to the whole or substantially all of the Project which has previously been conveyed to Developer shall be taken in condemnation proceedings or by right of eminent domain, Developer, at its sole discretion, may terminate this Agreement as of the date of such taking. For purposes of this Section 6.07(c), "substantially all of the District" shall be deemed to have been taken if the City and Developer, each acting reasonably and in good faith, determine that the untaken portion of the District, including the parking improvements, cannot be practically and economically used by Developer for the purposes and at the times contemplated by this Agreement. (d) In the event of condemnation of less than the whole or substantially all of the District which has previously been conveyed to Developer during the Term, Developer, at its sole cost and expense, shall commence and thereafter proceed as promptly as possible to repair, restore and replace the remaining part of the Project, as nearly as possible, to its former condition, and shall be entitled to draw upon the Casualty Escrow for payment of said costs. (e) Nothing in this section will require the Developer to expend funds in excess of the Casualty Escrow for the repair, restoration and/or replacement of the Damaged Facilities.

  • Damage, Destruction and Condemnation (a) Seller will bear the risk of loss for any damage, destruction, or condemnation that may occur prior to Closing. If any portion of the Property is damaged or destroyed prior to Closing, Purchaser may elect to terminate this Agreement, unless prior to Closing all that damage has been repaired and the Improvements restored or replaced to their condition prior to the damage. If any material portion of the Property is condemned or taken prior to Closing, Purchaser may elect to terminate this Agreement. (b) Purchaser's election under this Section with respect to any condemnation or taking will be exercised by written notice to Seller within twenty (20) days after written notice from Seller of the condemnation or taking. Purchaser's election under this Section with respect to any damage or destruction not repaired prior to Closing will be exercised by written notice to seller within twenty (20) days of the later to occur of: (i) written notice from Seller of the damage or destruction and Seller's inability to repair and restore prior to Closing; or (ii) written notice from Seller's insurance carrier regarding the estimated cost of repair, replacement, or reconstruction and the portion of the repair, replacement, or reconstruction for which insurance proceeds will be made available. The Closing Date will be extended as necessary to give Purchaser time to make the election. (c) If Purchaser elects to terminate this Agreement under this Section, neither party will have any further rights, duties, or obligations. If Purchaser does not elect to terminate this Agreement, this Agreement will remain in full force and the purchase contemplated in this Agreement, less any interest taken by condemnation, will be effected, and at the Closing, Seller will pay the Purchaser the amount of any deductible under Seller's insurance policy and will assign, transfer, and set over to Purchaser all of Seller's right, title, and interest to any condemnation awards or insurance proceeds that have been or that may later be made for the taking or destruction.