DELAY NOTICES Clause Samples

The DELAY NOTICES clause requires a party to promptly inform the other party if they anticipate or experience any delays in fulfilling their contractual obligations. Typically, this involves providing written notice within a specified timeframe, detailing the cause and expected duration of the delay. By ensuring timely communication about delays, this clause helps manage expectations, allows for mitigation measures, and reduces the risk of disputes arising from unforeseen setbacks.
POPULAR SAMPLE Copied 1 times
DELAY NOTICES. 2.1 The Builder shall give written notice to the Buyer of a cause of delay pursuant to Clause 1.3 as soon as practicable and no later than five (5) days after the date on which the Builder first has knowledge of such cause of delay and in such notice the Builder shall describe the cause of the delay, the date of commencement (or first occurrence) of the cause, its expected duration and its expected effect on the Builder’s ability to carry on with the building work. 2.2 The Builder will provide the Buyer with regular written status reports (at such reasonable intervals as the Buyer may request) with respect to any delay in respect of which the Builder has given notice pursuant to Clause 2.1 and as to the steps being taken (and planned) by the Builder to minimise and overcome any actual delay in delivery of the Ship. 2.3 Within five (5) days after any cause of delay set forth in Clause 1.3 has ceased to exist, the Builder shall notify the Buyer of such cessation and give the Buyer a written statement of the actual or estimated delay in the completion of the building work resulting from such cause together with such detailed documentation as is then available to it justifying such extension, and any such detailed documentation thereafter becoming available to the Builder shall be promptly be given to the Buyer. 2.4 On the basis of the notices, reports, statements and information given to the Buyer by the Builder relating to any actual or estimated delay in delivery (and such further information and documentation as the Buyer may reasonably request), the Buyer and the Builder shall confer and attempt to agree upon the number of days by which the Delivery Date shall be extended provided that if the Buyer and the Builder cannot so agree within thirty (30) days after the completion of any such conference, the extension of the Delivery Date (if any) shall be determined as a Dispute pursuant to the provisions of Article 13. 2.5 The extension of the Delivery Date provided for in this Article shall be the only remedy for delay to which the Builder shall be entitled and, by way of illustration but not limitation, the Builder shall not be entitled to damages or any adjustment in the Contract Price.
View SourceView Similar (16)
DELAY NOTICES. 24 Article 6: Tests and Liquidated Damages.................................. 25 1. Tests........................................................... 25 2.
View SourceView Similar (2)
DELAY NOTICES. If upon receipt of a request for a Demand Registration or any NT Registration or while a Demand Registration or any NT Registration is pending, the Company determines in its good faith judgment after consultation with its securities counsel that (i) the filing of a registration statement or any amendment thereto would require disclosure of material information which the Company has a bona fide business purpose for preserving as confidential and (ii) a delay as contemplated herein would be likely to reduce the detrimental effect of or would obviate the need for such disclosure, then if the Company provides the Requesting Holder or the Names' Trustee, as the case may be, with written notice (an "Information Delay Notice"; an Information Delay Notice or a Transaction Delay Notice, each, a "Delay Notice") thereof promptly after the Company makes such determination, which shall be made promptly after the receipt of any request, the Company shall not be required to comply with its obligations under Section 2(a) (in case of a Demand Registration) or Section 2(c)(ii) or 2(c)(iii) (in case of any NT Registration thereunder) until the earlier of (A) the date upon which such material information is disclosed to the public or ceases to be material or (B) 90 days after the Company's receipt of such registration request.
View Source

Related to DELAY NOTICES

  • A5 Notices Except as otherwise expressly provided within the Contract, no notice or other communication from one Party to the other shall have any validity under the Contract unless made in writing by or on behalf of the Party concerned.

  • 2Notices All notices, requests and demands to or upon the respective parties hereto to be effective shall be in writing, by facsimile transmission, by telephone confirmed in writing and, unless otherwise expressly provided herein, shall be deemed to have been duly given or made when delivered by hand, or when deposited in the mail, postage prepaid, or, in the case of facsimile transmission, when received, addressed as follows in the case of the Borrowers, the Administrative Agent, or to such address or other address as may be hereafter notified by the respective parties hereto: The Borrowers: The Company: Deere & Company Attention: Treasurer One ▇▇▇▇ Deere Place Moline, Illinois 61265 Telephone: ▇▇▇-▇▇▇-▇▇▇▇ Facsimile: ▇▇▇-▇▇▇-▇▇▇▇ The Capital Corporation: ▇▇▇▇ Deere Capital Corporation Attention: Manager P.O. Box 5328 Madison, WI ▇▇▇▇▇-▇▇▇▇ Telephone: ▇▇▇-▇▇▇-▇▇▇▇ Facsimile: ▇▇▇-▇▇▇-▇▇▇▇ JD Luxembourg: ▇▇▇▇ Deere Bank S.A. ▇▇, ▇▇▇▇▇▇ ▇▇▇▇ ▇. KennedyL-1855 LuxembourgGrand Duchy of Luxembourg Facsimile: + 352 26 29 90 200​ with a copy to: Deere & Company Attention: Treasurer ▇▇▇ ▇▇▇▇ ▇▇▇▇▇ Place Moline, Illinois 61265Telephone: ▇▇▇-▇▇▇-▇▇▇▇ Facsimile: ▇▇▇-▇▇▇-▇▇▇▇ The Administrative Agent: Provided separately by Administrative Agent​ To any other Bank: To it at its address (or facsimile number) set forth in its Administrative Questionnaire​ provided that any notice, request or demand to or upon the Administrative Agent or the Banks pursuant to subsections 2.1, 2.2, 2.5, 2.6, 2.9, 2.11, 2.20 and 9.9 shall not be effective until received (including receipt by telephone if permitted hereby). Notices and other communications to any Borrower, the Banks and the Administrative Agent hereunder may be delivered or furnished by using Approved Borrower Portals (as applicable), in each case, pursuant to procedures approved by the Administrative Agent; provided that the foregoing shall not apply to notices pursuant to Article 2 hereof unless otherwise agreed by the Administrative Agent and the applicable Bank. The Administrative Agent or any Borrower may, in its discretion, agree to accept notices ​ ​ and other communications to it hereunder by electronic communications pursuant to procedures approved by it; provided that approval of such procedures may be limited to particular notices or communications.

  • 5Notices A. 5.1Any notice or other communication which is to be given by either Party to the other shall be issued by the E-Sourcing Messaging Facility. Where, for legal or other reasons, this is not possible, notice shall be given by letter, (sent by hand or post, registered post or recorded delivery), or transmitted by facsimile or e-mail, confirmed in either case by written letter. Such notice or communication shall be deemed to have been given on the day when in the ordinary course of the means of transmission it would first be received by the addressee in normal business hours. A. 6Mistakes in Information

  • 1Notices Any notices, consents or other communications required to be sent or given hereunder by any of the parties hereto shall in every case be in writing and shall be deemed properly served if and when (a) delivered by hand, (b) transmitted by facsimile or other means of electronic delivery, with confirmation of transmission, or (c) delivered by Federal Express or other express overnight delivery service, or registered or certified mail, return receipt requested, to the parties at the addresses as set forth below or at such other addresses as may be furnished in writing: To the Company: Authentic Brands LLC ▇▇▇▇ ▇▇▇▇▇ ▇▇▇ ▇▇▇▇ ​ ▇▇▇▇ ▇▇▇▇ ▇▇▇▇, ▇▇▇▇ ▇▇▇▇▇ Attention: ▇▇▇▇ ▇▇▇▇▇ Telephone: ▇▇▇.▇▇▇.▇▇▇▇ Facsimile: E-mail: ▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ with copies to: New Coffee Holdings, LLC c/o Sterling Partners ▇▇▇ ▇. ▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇, ▇▇▇▇ ▇▇▇▇▇ ▇▇▇▇▇▇▇, ▇▇▇▇▇▇▇▇ ▇▇▇▇▇-▇▇▇▇ Attention: Office of the General Counsel Telephone: ▇▇▇.▇▇▇.▇▇▇▇ E-mail: ▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇ and: ▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇ LLP ▇▇▇ ▇▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇ Suite 3100 Chicago, Illinois 60606 Attention: ▇▇▇▇ ▇▇▇▇▇▇▇ Telephone: ▇▇▇.▇▇▇.▇▇▇▇ E-mail: ▇▇▇▇▇▇▇▇@▇▇▇▇▇▇▇▇.▇▇▇ To Recipient: to the address listed on the signature page. or to such other person or address as any party shall specify by notice in writing to the other party. The date of service of such notice shall be deemed to be: (x) the date such notice is delivered by hand, facsimile or other electronic means, (y) one business day following the delivery by express overnight delivery service, or (z) three business days after the date of mailing if sent by certified or registered mail.

  • Certain Notices Within five Business Days after the occurrence of any Event of Default actually known to a Responsible Officer of the Property Trustee, the Property Trustee shall transmit, in the manner and to the extent provided in Section 10.8, notice of such Event of Default to the Holders and the Administrators, unless such Event of Default shall have been cured or waived. Within five Business Days after the receipt of notice of the Depositor's exercise of its right to defer the payment of interest on the Junior Subordinated Debentures pursuant to the Indenture, the Property Trustee shall transmit, in the manner and to the extent provided in Section 10.8, notice of such exercise to the Holders and the Administrators, unless such exercise shall have been revoked.