Delay Suspension or Interruption Clause Samples

The "Delay, Suspension, or Interruption" clause defines the rights and procedures when a project or contractual obligations are postponed, temporarily halted, or disrupted. Typically, this clause outlines the circumstances under which work may be delayed or suspended, such as unforeseen events, regulatory requirements, or instructions from one party, and may specify notice requirements, time extensions, or compensation for affected parties. Its core function is to provide a clear framework for managing and resolving disruptions, thereby minimizing disputes and ensuring that both parties understand their rights and responsibilities during periods of non-performance.
Delay Suspension or Interruption 
View SourceView Similar (5)

Related to Delay Suspension or Interruption

  • TERMINATION OR SUSPENSION § 9.1 If the Owner fails to make payments to the Architect in accordance with this Agreement, such failure shall be considered substantial nonperformance and cause for termination or, at the Architect’s option, cause for suspension of performance of services under this Agreement. If the Architect elects to suspend services, the Architect shall give seven days’ written notice to the Owner before suspending services. In the event of a suspension of services, the Architect shall have no liability to the Owner for delay or damage caused the Owner because of such suspension of services. Before resuming services, the Owner shall pay the Architect all sums due prior to suspension and any expenses incurred in the interruption and resumption of the Architect’s services. The Architect’s fees for the remaining services and the time schedules shall be equitably adjusted. § 9.2 If the Owner suspends the Project, the Architect shall be compensated for services performed prior to notice of such suspension. When the Project is resumed, the Architect shall be compensated for expenses incurred in the interruption and resumption of the Architect’s services. The Architect’s fees for the remaining services and the time schedules shall be equitably adjusted. § 9.3 If the Owner suspends the Project for more than 90 cumulative days for reasons other than the fault of the Architect, the Architect may terminate this Agreement by giving not less than seven days’ written notice. § 9.4 Either party may terminate this Agreement upon not less than seven days’ written notice should the other party fail substantially to perform in accordance with the terms of this Agreement through no fault of the party initiating the termination. § 9.5 The Owner may terminate this Agreement upon not less than seven days’ written notice to the Architect for the Owner’s convenience and without cause. § 9.6 If the Owner terminates this Agreement for its convenience pursuant to Section 9.5, or the Architect terminates this Agreement pursuant to Section 9.3, the Owner shall compensate the Architect for services performed prior to termination, Reimbursable Expenses incurred, and costs attributable to termination, including the costs attributable to the Architect’s termination of consultant agreements. § 9.7 In addition to any amounts paid under Section 9.6, if the Owner terminates this Agreement for its convenience pursuant to Section 9.5, or the Architect terminates this Agreement pursuant to Section 9.3, the Owner shall pay to the Architect the following fees:

  • TEN TERMINATION OR SUSPENSION CONTRACTOR shall be considered in material default of this Agreement and such default will be considered cause for OWNER to terminate this Agreement, in whole or in part, as further set forth in this section, for any of the following reasons: (a) failure to begin work under the Agreement within the times specified under the Notice(s) to Proceed, or (b) failure to properly and timely perform the services to be provided hereunder or as directed by OWNER, or (c) the bankruptcy or insolvency or a general assignment for the benefit of creditors by CONTRACTOR or by any of CONTRACTOR's principals, officers or directors, or (d) failure to obey laws, ordinances, regulations or other codes of conduct, or (e) failure to perform or abide by the terms or spirit of this Agreement, or (f) for any other just cause. The OWNER may so terminate this Agreement, in whole or in part, by giving the CONTRACTOR seven (7) calendar day’s written notice.

  • Suspension of Access Ricoh reserves the right to suspend or terminate authorizations, or to suspend or block access to all or any part of the Site or Services as provided in paragraph 10 hereof.

  • DISCHARGE OR SUSPENSION The Employer shall not discharge nor suspend any employee with- out just cause, but in respect to discharge or suspension shall give at least one (1) warning notice of a complaint against such employ- ee to the employee, in writing, and a copy of the same to the Union, except that no warning notice need be given to an employee before he/she is discharged if the cause of such discharge is dishonesty, drinking alcoholic beverages or being under the influence of drugs or in illegal possession of drugs during the workday (including meal period) or drunkenness, recklessness resulting in serious acci- dent while on duty, or the carrying of unauthorized passengers while on the job or offenses of equal seriousness. Except for seri- ous accidents, a driver will not be removed from the payroll during an investigation of an accident. The driver can be assigned to non-driving work during this period. Before disciplinary action is taken, a meeting shall be held with the employee and the employee shall have the right to choose a ▇▇▇▇▇▇▇ who is readily available and on the premises. In the case of discharge for any offense other than the above mentioned, including suspension, the disciplinary action will be held in abeyance for two (2) weeks to give the Local Union the opportunity to intervene prior to the action being taken. The warning notice, suspension or discharge as herein provided shall not remain in effect for a period of more than nine (9) months from the date of said warning notice, suspension or discharge. Any disciplinary action will list the violation(s) and be by proper written notice to the employee and the Union affected. Disci- plinary letters must be issued by the Company within ten (10) working days after the incident. Any employee may request an in- vestigation as to his/her discharge or suspension. Should such in- vestigation prove that an injustice has been done an employee, he/ she shall be reinstated. The C.P.A.P.G.C. or the impartial arbitrator shall have the authority to order full, partial or no compensation for time lost. Appeal from discharge or suspension must be taken with- in ten (10) days by written notice and a decision reached within thirty (30) days from the date of suspension or discharge. An em- ployee shall be given a copy of any Company form or document signed by the employee if requested. The Company will not use absenteeism or accidents in conjunction with any other disciplinary action.

  • Permanent Suspension or Prohibition If the Employee is removed and/or permanently prohibited from participating in the conduct of the Bank's affairs by an order issued under Section 8(e)(4) or (g)(1) of the FDIA, 12 U.S.C. ss. 1818(e)(4) and (g)(1), all obligations of the Bank under this Agreement shall terminate as of the effective date of the order, but vested rights of the contracting parties shall not be affected.