DELAYS; PERFORMANCE CREDITS AND CORRECTIVE REPORTING; DEFAULTS; FORCE MAJEURE Sample Clauses

This clause defines the procedures and remedies related to project delays, performance shortfalls, and unforeseen events that may impact contractual obligations. It typically outlines how delays are identified and reported, the process for issuing performance credits to compensate for missed targets, and the requirements for corrective action reporting. Additionally, it addresses what constitutes a default under the agreement and specifies the conditions under which force majeure events—such as natural disasters or other uncontrollable circumstances—excuse performance. The core function of this clause is to allocate responsibility for delays, provide mechanisms for remediation, and clarify the parties’ rights and obligations when performance is disrupted by extraordinary events.
DELAYS; PERFORMANCE CREDITS AND CORRECTIVE REPORTING; DEFAULTS; FORCE MAJEURE. 16.1 Notice of Delays Time is of the essence in Contractor’s performance of its obligations under this Agreement. Contractor shall promptly notify Customer in writing of any anticipated or known delay in Contractor’s performance of an obligation by the date specified therefor, if any, in this Agreement, the reasons for the delay, and the expected duration of the delay. In the event of any failure of Customer or User to perform an obligation which delays or threatens to delay a scheduled performance date of Contractor under this Agreement (“Customer/User Delay”), Contractor shall promptly notify Customer in writing of such delay or threatened delay, and Contractor’s scheduled performance date shall be extended day-for-day for any such actual delay of Customer or User directly affecting such scheduled performance date. If Contractor fails to notify Customer of a Customer/User Delay of which Customer or the applicable User does not otherwise have a prior notice (i.e., pursuant to a Project Plan), Contractor may not use such Customer/User Delay as an excuse for its failure to meet a scheduled performance date. 16.2 [Deleted]
View SourceView Similar (4)
DELAYS; PERFORMANCE CREDITS AND CORRECTIVE REPORTING; DEFAULTS; FORCE MAJEURE 
View SourceView Similar (2)

Related to DELAYS; PERFORMANCE CREDITS AND CORRECTIVE REPORTING; DEFAULTS; FORCE MAJEURE

  • Reporting of Non-Force Majeure Events Each Party (the “Notifying Party”) shall notify the other Parties when the Notifying Party becomes aware of its inability to comply with the provisions of this Agreement for a reason other than a Force Majeure event. The Parties agree to cooperate with each other and provide necessary information regarding such inability to comply, including the date, duration, reason for the inability to comply, and corrective actions taken or planned to be taken with respect to such inability to comply. Notwithstanding the foregoing, notification, cooperation or information provided under this Article shall not entitle the Party receiving such notification to allege a cause for anticipatory breach of this Agreement.

  • Excuse for Nonperformance or Delayed Performance Except with respect to defaults of subcontractors, Contractor/Vendor shall not be in default by reason of any failure in performance of this contract in accordance with its terms (including any failure by Contractor/Vendor to make progress in the prosecution of the work hereunder which endangers such performance) if Contractor/Vendor has notified the Commission or designee within 15 days after the cause of the delay and the failure arises out of causes such as: acts of God; acts of the public enemy; acts of the State and any other governmental entity in its sovereign or contractual capacity; fires; floods; epidemics; quarantine restrictions; strikes or other labor disputes; freight embargoes; or unusually severe weather. If the failure to perform is caused by the failure of a subcontractor to perform or to make progress, and if such failure arises out of causes similar to those set forth above, Contractor/Vendor shall not be deemed to be in default, unless the services to be furnished by the subcontractor were reasonably obtainable from other sources in sufficient time to permit Contractor to meet the contract requirements. Upon request of Contractor, the Commission or designee shall ascertain the facts and extent of such failure, and, if such officer determines that any failure to perform was occasioned by any one or more of the excusable causes, and that, but for the excusable cause, Contractor’s progress and performance would have met the terms of the contract, the delivery schedule shall be revised accordingly, subject to the rights of the State under the clause entitled (in fixed-price contracts, “Termination for Convenience,” in cost-reimbursement contracts, “Termination”). (As used in this Paragraph of this clause, the term “subcontractor” means subcontractor at any tier).

  • Termination Due to Force Majeure Event If the period of Force Majeure continues or is in the reasonable judgment of the Parties likely to continue beyond a period of 120 (one hundred and twenty) Days, the Parties may mutually decide to terminate this Agreement or continue this Agreement on mutually agreed revised terms. If the Parties are unable to reach an agreement in this regard, the Affected Party shall after the expiry of the said period of 120 (one hundred and twenty ) Days be entitled to terminate the Agreement in which event, the provisions of Articles 16 and 17 shall, to the extent expressly made applicable, apply.

  • Termination due to Force Majeure 13.5.1 If the Force Majeure Event or its effects continue to be present beyond the period as specified in Article 4.5.3, either Party shall have the right to cause termination of the Agreement. In such an event, this Agreement shall terminate on the date of such Termination Notice.

  • Performance Deficiencies If the City or the Quality Control Manager determine in their reasonable belief that any of the Infrastructure Improvements are not being constructed in accordance with the Infrastructure Improvement Plans or this Agreement in any material respect, they shall immediately notify RCP and Bliss Sports II in writing stating the alleged deficiency and the City, the Quality Control Manager, the Architect, RCP and Bliss Sports II will meet within seven (7) days of the giving of such notice to discuss whether the Infrastructure Improvements are not being constructed in accordance with the Infrastructure Improvement Plans or this Agreement in any material respect and, if the City, RCP and Architect agree that they are not, then RCP shall cause Bliss Sports II to correct such deficiencies. The failure by the City to provide any notice of any observed deficiency shall not give rise to any liability to the City and shall not be considered a waiver of any right of the City under this Agreement, including, without limitation, the enforcement of the representations and warranties of Bliss Sports II under this Agreement and any warranties that may be made to the City by any Contracting Parties under the Infrastructure Construction Contract Documents with respect to the completion of the Infrastructure Improvements in accordance with the Infrastructure Improvement Plans and the Project Timeline.