Delivery and Acceptance. 8.1 The Goods shall be delivered to and the Services shall be performed at the Company's place of business or if some other place of delivery is agreed by the Company in writing by delivery of the Goods or provision of the Services at that place during the Company's normal office hours. The Supplier shall off-load the Goods at its own risk as directed by the Company. 8.2 The Goods shall be delivered and/or the Services shall be performed on the date or within the period specified in the Order or if no such period is specified then within 28 days of the Order, unless the Company notifies the Supplier of a change in the required delivery date (giving the Supplier as much notice of the revised delivery date as practicable) in which case the Supplier shall deliver the Goods and/or perform the Services on or by the revised delivery date. Time for delivery of the Goods or performance of the Services shall be of the essence of the Agreement. 8.3 The Supplier shall ensure that each delivery of Goods is accompanied by a delivery note which is prominently displayed and which shows, inter alia, the order number, date of order, number of packages and contents and, in the case of part delivery, the outstanding balance remaining to be delivered. For the avoidance of doubt, the Supplier shall only be permitted to deliver in part where the Company has confirmed in writing or on the Order Form that it is willing to accept delivery in part. 8.4 If the Goods are not delivered or the Services are not performed on the due date then, without prejudice to any other rights which it may have, the Company reserves the right to: 8.4.1 terminate the Agreement in whole or in part without being liable to compensate the Supplier for any losses arising as a result of such cancellation or to make any payment to the Supplier other than in respect of Goods actually delivered or Services actually rendered to the Company prior to the date of such termination; 8.4.2 refuse to accept any subsequent delivery of the Goods or provision of the Services which the Supplier attempts to make; 8.4.3 recover from the Supplier any expenditure reasonably incurred by the Company in obtaining the Goods or Services in substitution from another supplier; and 8.4.4 claim damages for any reasonable additional costs, loss or expenses incurred by the Company which are in any way attributable to the Supplier's failure to deliver the Goods or provide the Services on the due date. 8.5 Any signature on behalf of the Company on the delivery note is not evidence that the correct number or type of Goods has been delivered or that the Goods supplied are in good condition or otherwise meet the requirements of the Agreement or the relevant Order. The Company shall not be deemed to have accepted the Goods or Services until it has had a reasonable time to inspect them following delivery and has not notified the Supplier of its rejection of the Goods or Services within that time. The Company shall also have the right to reject the Goods and/or Services as though they had not been accepted for a reasonable time after any latent defect in the Goods or Services has become apparent. If the Company does not accept the Goods and/or Services as conforming to the Agreement, the relevant Order or any Specification, it may exercise any of the remedies set out in Condition 17. 8.6 No Goods supplied or Services performed under the Agreement earlier than the date for delivery set out in the Order, or in any delivery schedule, will be accepted or paid for unless the Company notifies the Supplier in writing of its intention to accept the same. 8.7 The Supplier shall supply the Company on delivery of the Goods with full and clear operating, storage, handling and safety instructions, warning notices clearly displayed and other information as may be necessary for their proper use, maintenance and repair for the Company to accept delivery of the Goods. 8.8 Unless the Company expressly agrees otherwise in writing, containers and packing must be supplied free but will be returned to the Supplier, if required by written notice from the Supplier to the Company, at the Supplier's risk and expense. 8.9 Where more than one item of Goods is involved in the Order and the Company agrees to accept delivery by instalments, the Agreement shall be construed as a separate contract in respect of each instalment. Nevertheless failure to deliver any instalment shall entitle the Company at its option to treat the Agreement as repudiated. 8.10 If the Goods are delivered to the Company in excess of the quantities ordered the Company shall not be bound to pay for the excess and any excess will be and will remain at the Supplier's risk and will be returnable at the Supplier's expense. 8.11 The Supplier shall, free of charge and within 30 days from the giving of notice as provided below, either repair or replace (as the Company shall elect) such of the Goods as may either be damaged in transit or having been placed in transit, fail to be delivered to the Company provided that: 8.11.1 in the case of damage to such Goods in transit, the Company shall within 30 days of delivery give notice in writing to the Supplier that the Goods have been damaged; 8.11.2 in the case of non-delivery, the Company shall (provided that the Company has been notified of dispatch within 10 days of the notified date of delivery) give notice to the Supplier that the Goods have not been delivered. 8.12 If the Goods require assembly and installation, the Supplier shall: 8.12.1 carry out such work in accordance with Condition 2.4 above; 8.12.2 comply with the Company's requirements relating to access to and use and security of, the Company's premises and shall keep the Company's premises clean and tidy at all time; and 8.12.3 following any such assembly or installation, restore the Company’s premises on which it has been installing the Goods to the condition they were in before it commenced such installation.
Appears in 3 contracts
Sources: Terms & Conditions of Purchase, Terms & Conditions of Purchase of Goods or Services, Terms & Conditions of Purchase of Goods or Services
Delivery and Acceptance. 8.1 The Goods (a) Every endeavour will be made to effect delivery within the date specified but dates and periods for delivery are only estimates and as such do not form an essential part of the Contract. In no circumstances whatsoever shall the Buyer be entitled to recover loss of profits from sub‐sales or any special or consequential loss or damage whatsoever arising from or in connection with delay in delivery or non‐ delivery.
(b) Delivery shall be delivered to and the Services shall be performed at the Company's place of business Seller’s premises unless otherwise stipulated or if some other place of delivery is agreed by the Company Seller.
(c) Any subsequent request for amendment to design, quantity or specification or any suspension of work resulting from the Buyer's instruction, or lack of instruction is subject to acceptance by the Seller in writing by delivery and may result in a revision of the Goods or provision of the Services at that place during the Company's normal office hours. The Supplier shall off-load the Goods at its own risk as directed by the Companypreviously estimated delivery date.
8.2 The Goods (d) Where the Contract provides for the supply for goods by regular deliveries over a period, or by more than one single delivery, each such delivery shall be delivered and/or the Services shall be performed on the date or within the period specified in the Order or if no such period is specified then within 28 days of the Order, unless the Company notifies the Supplier of a change in the required delivery date (giving the Supplier as much notice of the revised delivery date as practicable) in which case the Supplier shall deliver the Goods and/or perform the Services on or by the revised delivery date. Time for delivery of the Goods or performance of the Services shall be of the essence of the Agreement.
8.3 The Supplier shall ensure that each delivery of Goods is accompanied by a delivery note which is prominently displayed and which shows, inter alia, the order number, date of order, number of packages and contents and, in the case of part delivery, the outstanding balance remaining considered to be delivered. For the avoidance of doubt, the Supplier shall only be permitted to deliver in part where the Company has confirmed in writing or on the Order Form that it is willing to accept delivery in part.
8.4 If the Goods are not delivered or the Services are not performed on the due date then, without prejudice to any other rights which it may have, the Company reserves the right to:
8.4.1 terminate the Agreement in whole or in part without being liable to compensate the Supplier for any losses arising as a result of such cancellation or separate contract and failure to make any payment delivery shall not terminate the contract as to the Supplier other than in respect of Goods actually delivered or Services actually rendered to the Company prior to the date of such termination;
8.4.2 refuse to accept any subsequent delivery of the Goods or provision of the Services which the Supplier attempts to make;
8.4.3 recover from the Supplier any expenditure reasonably incurred by the Company in obtaining the Goods or Services in substitution from another supplier; and
8.4.4 claim damages for any reasonable additional costs, loss or expenses incurred by the Company which are in any way attributable to the Supplier's failure to deliver the Goods or provide the Services on the due date.
8.5 Any signature on behalf of the Company on the delivery note is not evidence that the correct number or type of Goods has been delivered or that the Goods supplied are in good condition or otherwise meet the requirements of the Agreement or the relevant Orderdeliveries thereunder. The Company shall not be deemed to have accepted the Goods or Services until it has had a reasonable time to inspect them following delivery and has not notified the Supplier of its rejection of the Goods or Services within that time. The Company shall also have the right to reject the Goods and/or Services as though they had not been accepted for a reasonable time after any latent defect in the Goods or Services has become apparent. If the Company does not accept the Goods and/or Services as conforming to the Agreement, the relevant Order or any Specification, it may exercise any of the remedies set out in Condition 17.
8.6 No Goods supplied or Services performed under the Agreement earlier than the date for delivery set out in the Order, or in any delivery schedule, will be accepted or paid for unless the Company notifies the Supplier in writing of its intention to accept the same.
8.7 The Supplier shall supply the Company on delivery of the Goods with full and clear operating, storage, handling and safety instructions, warning notices clearly displayed and other information as may be necessary for their proper use, maintenance and repair for the Company to accept delivery of the Goods.
8.8 Unless the Company expressly agrees otherwise in writing, containers and packing must be supplied free but will be returned to the Supplier, if required by written notice from the Supplier to the Company, at the Supplier's risk and expense.
8.9 Where more than one item of Goods is involved in the Order and the Company agrees to accept delivery by instalments, the Agreement shall be construed as a separate contract in respect of each instalment. Nevertheless failure to deliver any instalment shall entitle the Company at its option to treat the Agreement as repudiated.
8.10 If the Goods are delivered to the Company in excess of the quantities ordered the Company Seller shall not be bound to pay deliver in any month more than the quantity specified, or if no monthly quantity is specified more than the pro rata amount of the total Contract quantity.
(e) If the Buyer fails to take a delivery or collect at the time specified in the contract or notified by the Seller, or the buyer has not provided appropriate instructions, documents, licenses or authorisations the goods shall be deemed delivered and the Seller (without prejudice to its other rights) shall be entitled to invoice the value thereof to the Buyer for settlement in accordance with Condition 4 hereof.
(f) The Seller may store the goods until delivery, whereupon the Buyer shall be liable for all related costs and expenses including storage and insurance.
(f) Where the Buyer has given no specific delivery instructions, the Seller shall not be bound to deliver until such instructions have been received, and if at the expiry of seven days after advising the Buyer that the goods are ready for delivery such instructions have not been received, the Seller shall be entitled to invoice the goods as at that date, and if the Buyer has not issued delivery instructions within one calendar month of the date of such invoice the Seller shall be entitled to charge the Buyer for the excess and any excess will be and will remain at the Supplier's risk and will be returnable at the Supplier's expensestorage of such goods.
8.11 The Supplier shall(g) Goods delivered shall be examined carefully by the Buyer and, free of charge if damaged or short‐delivered, the Seller must be notified in writing within 3 days, and within 30 days from in default no claim may be made by the giving of notice as provided belowBuyer for damage or short‐delivery.
(h) When the Seller undertakes delivery to the Buyer's address, either repair or replace (as the Company shall elect) such no claim for non‐delivery of the Goods as may either goods shall be damaged in transit or having been placed in transit, fail to be delivered to made against the Company provided that:
8.11.1 in the case of damage to such Goods in transit, the Company shall within 30 days of delivery give Seller unless notice in writing of non‐delivery is given to the Supplier that the Goods have been damaged;
8.11.2 in the case of non-delivery, the Company shall (provided that the Company has been notified of dispatch Seller within 10 days of the notified date of delivery) give notice invoice or of the advice of despatch, whichever is the earlier, and any claim on consequence of such non‐delivery must be made to the Supplier that Seller within 21 days of the Goods have not been delivereddate of invoice or of the date of advice of despatch (whichever is the earlier).
8.12 If the Goods require assembly and installation, the Supplier shall:
8.12.1 carry out such work in accordance with Condition 2.4 above;
8.12.2 comply with the Company's requirements relating to access to and use and security of, the Company's premises and shall keep the Company's premises clean and tidy at all time; and
8.12.3 following any such assembly or installation, restore the Company’s premises on which it has been installing the Goods to the condition they were in before it commenced such installation.
Appears in 2 contracts
Sources: Terms and Conditions, Terms and Conditions
Delivery and Acceptance. 8.1 5.1 The Services shall be performed at and the Goods shall be delivered to and the Services shall be performed at the Company's place of business business, or if some other place of delivery is agreed as notified by the Company in writing by delivery of the Goods or provision of the Services at that place writing, during the Company's normal office hours. The Supplier shall off-load the Goods at its own risk as directed by the Company.
8.2 5.2 The Services shall be performed or the Goods shall be delivered and/or the Services shall be performed on the date or within the period specified in the Order or if no such period is specified then within 28 days of the Order, unless the Company notifies the Contractor or Supplier of a change in the required delivery date (giving the Contractor or Supplier as much notice of the revised delivery date as practicable) in which case the Contractor shall perform the Services or the Supplier shall deliver the Goods and/or perform the Services on or by the revised delivery date. Time for the performance of the Services or the delivery of the Goods or performance of the Services shall be of the essence of the Agreement.
8.3 The Supplier shall ensure that each delivery of Goods is accompanied by a delivery note which is prominently displayed and which shows, inter alia, 5.3 If the order number, date of order, number of packages and contents and, in the case of part delivery, the outstanding balance remaining to be delivered. For the avoidance of doubt, the Supplier shall only be permitted to deliver in part where the Company has confirmed in writing Services are not performed or on the Order Form that it is willing to accept delivery in part.
8.4 If the Goods are not delivered or the Services are not performed on the due date then, without prejudice to any other rights which it may have, the Company reserves the right to:
8.4.1 5.3.1 terminate the Agreement in whole or in part without being liable to compensate the Contractor or Supplier for any losses arising as a result of such cancellation or to make any payment to the Contractor other than in respect of Services actually rendered or to the Supplier other than in respect of Goods actually delivered or Services actually rendered to the Company prior to the date of such termination;
8.4.2 5.3.2 refuse to accept any subsequent provision of the Services which the Contractor attempts to make or delivery of the Goods or provision of the Services which the Supplier attempts to make;
8.4.3 5.3.3 recover from the Contractor or Supplier repayment of any Charges paid in advance in respect of the Services or Goods or any expenditure reasonably incurred by the Company in obtaining the Services or Goods or Services in substitution from another contractor or supplier; and
8.4.4 5.3.4 claim damages for any reasonable additional costs, loss or expenses incurred by the Company which are in any way attributable to the Contractors failure to provide the Services or the Supplier's failure to deliver the Goods or provide the Services on the due date.
8.5 Any signature on behalf of the Company on the delivery note is not evidence that the correct number or type of Goods has been delivered or that the Goods supplied are in good condition or otherwise meet the requirements of the Agreement or the relevant Order. The Company shall not be deemed to have accepted the Goods or Services until it has had a reasonable time to inspect them following delivery and has not notified the Supplier of its rejection of the Goods or Services within that time. The Company shall also have the right to reject the Goods and/or Services as though they had not been accepted for a reasonable time after any latent defect in the Goods or Services has become apparent. If the Company does not accept the Goods and/or Services as conforming to the Agreement, the relevant Order or any Specification, it may exercise any of the remedies set out in Condition 17.
8.6 No Goods supplied or Services performed under the Agreement earlier than the date for delivery set out in the Order, or in any delivery schedule, will be accepted or paid for unless the Company notifies the Supplier in writing of its intention to accept the same.
8.7 The Supplier shall supply the Company on delivery of the Goods with full and clear operating, storage, handling and safety instructions, warning notices clearly displayed and other information as may be necessary for their proper use, maintenance and repair for the Company to accept delivery of the Goods.
8.8 Unless the Company expressly agrees otherwise in writing, containers and packing must be supplied free but will be returned to the Supplier, if required by written notice from the Supplier to the Company, at the Supplier's risk and expense.
8.9 Where more than one item of Goods is involved in the Order and the Company agrees to accept delivery by instalments, the Agreement shall be construed as a separate contract in respect of each instalment. Nevertheless failure to deliver any instalment shall entitle the Company at its option to treat the Agreement as repudiated.
8.10 If the Goods are delivered to the Company in excess of the quantities ordered the Company shall not be bound to pay for the excess and any excess will be and will remain at the Supplier's risk and will be returnable at the Supplier's expense.
8.11 The Supplier shall, free of charge and within 30 days from the giving of notice as provided below, either repair or replace (as the Company shall elect) such of the Goods as may either be damaged in transit or having been placed in transit, fail to be delivered to the Company provided that:
8.11.1 in the case of damage to such Goods in transit, the Company shall within 30 days of delivery give notice in writing to the Supplier that the Goods have been damaged;
8.11.2 in the case of non-delivery, the Company shall (provided that the Company has been notified of dispatch within 10 days of the notified date of delivery) give notice to the Supplier that the Goods have not been delivered.
8.12 If the Goods require assembly and installation, the Supplier shall:
8.12.1 carry out such work in accordance with Condition 2.4 above;
8.12.2 comply with the Company's requirements relating to access to and use and security of, the Company's premises and shall keep the Company's premises clean and tidy at all time; and
8.12.3 following any such assembly or installation, restore the Company’s premises on which it has been installing the Goods to the condition they were in before it commenced such installation.
Appears in 2 contracts
Sources: Terms & Conditions of Purchase, Terms & Conditions of Purchase of Goods or Services
Delivery and Acceptance. 8.1 The Goods If a delivery deadline has not been determined upon conclusion of a transaction, the goods shall be deemed as having to be delivered to promptly, i.e. fulfilment may be demanded after the expiry of a reasonable period of time necessary for manufacturing the yarn and the Services shall may be performed rendered at the Company's place of business or if some other place of any time. If a delivery is determined to take place in instalments within a specified period, unless agreed by otherwise, the Company delivery and acceptance must take place for approximately the same quantities each month. If delivery was agreed to take place in writing by delivery of the Goods or provision of the Services at that place during the Company's normal office hours. The Supplier shall off-load the Goods at its own risk as directed by the Company.
8.2 The Goods shall be delivered and/or the Services shall be performed on the date or within the period specified in the Order or if no such period is specified then within 28 days of the Orderinstalments without stating a final date, unless the Company notifies parties have agreed otherwise, delivery and acceptance shall take place with approximately equal quantities each month within six months from the Supplier of a change in date on which the required delivery date (giving agreement was concluded. This shall also apply to purchases on call. With the Supplier as much notice of the revised delivery date as practicable) in which case the Supplier shall deliver the Goods and/or perform the Services on or by the revised delivery date. Time for delivery of yarns, technically unavoidable differences in quantity (which may at most fall within the Goods or performance of the Services following tolerances) shall be of the essence of the Agreement.
8.3 The Supplier shall ensure that each delivery of Goods is accompanied by a delivery note which is prominently displayed admissible and which shows, inter alia, the order number, date of order, number of packages and contents and, in may not be protested: In the case of part deliverywoolen yarn, semi-worsted and corresponding open- end yarns: up to ± 5% with an order quantity of 1000 kg and above up to ± 10% with an order quantity of below 1000 kg. In the outstanding balance remaining case of tufting yarns the number of reels can deviate by up to + 1.5% from the prescribed number of reels. Excess numbers of reels can be jointly supplied as cones to replace finished cones. Regarding the reel run length for tufting yarns, a tolerance of ± 3% is permitted. In the case of other yarns: up to + 5% with natural yarns, up to + 10% for bleached, dyed and special yarns based on the quantity to be delivered. For The seller's delivery obligation shall be fulfilled when the avoidance seller makes the yarn available to the buyer by the last day of doubtthe delivery period ‘ex spinning works' and/or 'ex-stock'. If two or more contracts exist, the Supplier seller shall only be permitted to deliver in part where the Company has confirmed in writing or on the Order Form that it is willing to accept delivery in part.
8.4 If the Goods are not delivered or the Services are not performed on the due date then, without prejudice to any other rights which it may have, the Company reserves the right to:
8.4.1 terminate the Agreement in whole or in part without being liable to compensate the Supplier for any losses arising as a result of such cancellation or to make any payment to the Supplier other than in respect of Goods actually delivered or Services actually rendered to the Company prior to the date of such termination;
8.4.2 refuse to accept any subsequent delivery of the Goods or provision of the Services which the Supplier attempts to make;
8.4.3 recover from the Supplier any expenditure reasonably incurred by the Company in obtaining the Goods or Services in substitution from another supplier; and
8.4.4 claim damages for any reasonable additional costs, loss or expenses incurred by the Company which are in any way attributable to the Supplier's failure to deliver the Goods or provide the Services on the due date.
8.5 Any signature on behalf of the Company on the delivery note is not evidence that the correct number or type of Goods has been delivered or that the Goods supplied are in good condition or otherwise meet the requirements of the Agreement or the relevant Order. The Company shall not be deemed to have accepted the Goods or Services until it has had a reasonable time to inspect them following delivery and has not notified the Supplier of its rejection of the Goods or Services within that time. The Company shall also have the right to reject deliver the Goods and/or Services as though they had not been accepted for a reasonable time after any latent defect oldest one first in the Goods or Services has become apparentfull. If the Company does seller has not accept fulfilled its obligation to deliver or the Goods and/or Services as conforming to the Agreement, the relevant Order or any Specification, it may exercise any of the remedies set out in Condition 17.
8.6 No Goods supplied or Services performed under the Agreement earlier than the date for delivery set out in the Order, or in any delivery schedule, will be accepted or paid for unless the Company notifies the Supplier in writing of buyer has not fulfilled its intention obligation to accept the same.
8.7 The Supplier goods, a grace period of 4 weeks shall supply first be granted. After the Company on delivery unsuccessful expiry of the Goods with full and clear operating, storage, handling and safety instructions, warning notices clearly displayed and other information as may be necessary for their proper use, maintenance and repair for the Company to accept delivery of the Goods.
8.8 Unless the Company expressly agrees otherwise in writing, containers and packing must be supplied free but will be returned to the Supplier, if required by written notice from the Supplier to the Company, at the Supplier's risk and expense.
8.9 Where more than one item of Goods is involved in the Order and the Company agrees to accept delivery by instalmentsthis period, the Agreement provisions of civil and commercial law shall be construed as a separate contract in respect of each instalment. Nevertheless failure to deliver any instalment shall entitle the Company at its option to treat the Agreement as repudiatedapply.
8.10 If the Goods are delivered to the Company in excess of the quantities ordered the Company shall not be bound to pay for the excess and any excess will be and will remain at the Supplier's risk and will be returnable at the Supplier's expense.
8.11 The Supplier shall, free of charge and within 30 days from the giving of notice as provided below, either repair or replace (as the Company shall elect) such of the Goods as may either be damaged in transit or having been placed in transit, fail to be delivered to the Company provided that:
8.11.1 in the case of damage to such Goods in transit, the Company shall within 30 days of delivery give notice in writing to the Supplier that the Goods have been damaged;
8.11.2 in the case of non-delivery, the Company shall (provided that the Company has been notified of dispatch within 10 days of the notified date of delivery) give notice to the Supplier that the Goods have not been delivered.
8.12 If the Goods require assembly and installation, the Supplier shall:
8.12.1 carry out such work in accordance with Condition 2.4 above;
8.12.2 comply with the Company's requirements relating to access to and use and security of, the Company's premises and shall keep the Company's premises clean and tidy at all time; and
8.12.3 following any such assembly or installation, restore the Company’s premises on which it has been installing the Goods to the condition they were in before it commenced such installation.
Appears in 2 contracts
Sources: German Yarn Contract, German Yarn Contract
Delivery and Acceptance. 8.1 6.1 The Goods shall be delivered to to, and the Services shall be performed at at, the Company's place of business or if some other place of delivery is agreed by the Company in writing by delivery of the Goods or provision of the Services at that place during the Company's normal office hours. The Supplier shall off-load the Goods at its own risk as directed by the Company.
8.2 The Goods shall be delivered and/or the Services shall be performed Delivery Address on the date or within the period specified stated in the Order or if no such period is specified then within 28 days of the Order, unless in either case during the Company notifies Buyer’s usual business hours or as otherwise agreed between the Supplier Parties in writing.
6.2 The time of a change in the required delivery date (giving the Supplier as much notice of the revised delivery date as practicable) in which case the Supplier shall deliver the Goods and/or perform the Services on or by the revised delivery date. Time for delivery of the Goods or and of performance of the Services shall be is of the essence of the AgreementContract.
8.3 The Supplier shall ensure that 6.3 A packing list/delivery advice note quoting the Buyer’s valid Order number and containing such other details as the Buyer may require must accompany each delivery or consignment of the Goods is accompanied by a delivery note and must be displayed prominently. An accurate signed timesheet or jobsheet or other documentary evidence or confirmation of completion of the Services, detailing the nature of the Services and the times and locations at which is prominently displayed the Services were performed, quoting the Buyer’s valid Order number and which shows, inter alia, containing such other details as the order number, date Buyer may require must be supplied to the Buyer upon or immediately after completion of order, number of packages and contents and, in the case of part delivery, the outstanding balance remaining to be delivered. For the avoidance of doubt, the Supplier shall only be permitted to deliver in part where the Company has confirmed in writing or on the Order Form that it is willing to accept delivery in partServices.
8.4 6.4 If the Goods are not delivered to be delivered, or the Services are to be performed, by instalments, the Contract will be treated as a single contract and not severable.
6.5 The Buyer may reject any Goods delivered or Services performed which are not in accordance with the Contract, and shall not be deemed to have accepted any Goods or Services until the Buyer has had a reasonable time to inspect and/or test them following delivery or performance thereof and the Buyer has confirmed its acceptance in writing (such acceptance not to be unreasonably withheld or delayed).
6.6 The Supplier shall supply the Buyer in good time with any instructions or other information required to enable the Buyer to accept delivery of the Goods and performance of the Services.
6.7 The Buyer shall not be obliged to return to the Supplier any packaging or packing materials for the Goods, whether or not any Goods are accepted by the Buyer.
6.8 The Buyer will not accept any deliveries of Goods or performance of Services in excess of the amount ordered unless previously agreed in writing by the Buyer.
6.9 If the Supplier fails to deliver the Goods or perform the Services on the due date in accordance with the Contract then, without prejudice to limiting any other rights which it may haveremedy and without any liability, the Company reserves the right Buyer shall be entitled to:
8.4.1 6.9.1 terminate the Agreement Contract and cancel any Order in whole or in part without being liable pursuant to compensate section 9.2.1 and require the Supplier for any losses arising as a result of such cancellation or to make any payment refund to the Supplier other than Buyer on demand any payments previously made by the Buyer in respect of any cancelled Order and (where applicable) collect from the Buyer at the Supplier’s cost any Goods actually delivered or Services actually rendered already received by the Buyer pursuant to the Company prior to the date of such terminationOrder;
8.4.2 6.9.2 refuse to accept any subsequent delivery of the Goods or provision performance of the Services which the Supplier attempts to make;
8.4.3 6.9.3 recover from the Supplier any expenditure reasonably incurred by the Company Buyer in remedying the Supplier’s failure including, if applicable, obtaining the Goods or Services in substitution from another supplier; and;
8.4.4 6.9.4 claim damages for any reasonable additional costs, loss losses or expenses incurred by the Company Buyer which are in any way attributable to the Supplier's ’s failure;
6.9.5 require the Supplier, without charge to the Buyer, to carry out such additional work and take such steps as is necessary to correct the Supplier’s failure and ensure future compliance by the Supplier; and
6.9.6 deduct from the Price or (if the Buyer has paid the Price) to claim from the Supplier by way of liquidated damages payable on demand for delay 5 per cent of the Price for every consecutive period of 7 days’ delay, up to a maximum of 25 per cent or such greater amount as fully compensates the Buyer for any losses, damages, costs and claims it may suffer as a result of the Supplier’s failure to deliver the Goods or provide perform the Services on the due date.
8.5 Any signature on behalf of the Company on the delivery note is not evidence that the correct number or type of Goods has been delivered or that the Goods supplied are in good condition or otherwise meet the requirements of the Agreement or the relevant Order. The Company shall not be deemed to have accepted the Goods or Services until it has had a reasonable time to inspect them following delivery and has not notified the Supplier of its rejection of the Goods or Services within that time. The Company shall also have the right to reject the Goods and/or Services as though they had not been accepted for a reasonable time after any latent defect in the Goods or Services has become apparent. If the Company does not accept the Goods and/or Services as conforming to the Agreement, the relevant Order or any Specification, it may exercise any of the remedies set out in Condition 17.
8.6 No Goods supplied or Services performed under the Agreement earlier than the date for delivery set out in the Order, or in any delivery schedule, will be accepted or paid for unless the Company notifies the Supplier in writing of its intention to accept the same.
8.7 The Supplier shall supply the Company on delivery of the Goods with full and clear operating, storage, handling and safety instructions, warning notices clearly displayed and other information as may be necessary for their proper use, maintenance and repair for the Company to accept delivery of the Goods.
8.8 Unless the Company expressly agrees otherwise in writing, containers and packing must be supplied free but will be returned to the Supplier, if required by written notice from the Supplier to the Company, at the Supplier's risk and expense.
8.9 Where more than one item of Goods is involved in the Order and the Company agrees to accept delivery by instalments, the Agreement shall be construed as a separate contract in respect of each instalment. Nevertheless failure to deliver any instalment shall entitle the Company at its option to treat the Agreement as repudiated.
8.10 If the Goods are delivered to the Company in excess of the quantities ordered the Company shall not be bound to pay for the excess and any excess will be and will remain at the Supplier's risk and will be returnable at the Supplier's expense.
8.11 The Supplier shall, free of charge and within 30 days from the giving of notice as provided below, either repair or replace (as the Company shall elect) such of the Goods as may either be damaged in transit or having been placed in transit, fail to be delivered to the Company provided that:
8.11.1 in the case of damage to such Goods in transit, the Company shall within 30 days of delivery give notice in writing to the Supplier that the Goods have been damaged;
8.11.2 in the case of non-delivery, the Company shall (provided that the Company has been notified of dispatch within 10 days of the notified date of delivery) give notice to the Supplier that the Goods have not been delivered.
8.12 If the Goods require assembly and installation, the Supplier shall:
8.12.1 carry out such work in accordance with Condition 2.4 above;
8.12.2 comply with the Company's requirements relating to access to Contract and use the Parties agree that such amount represents a genuine and security reasonable pre-estimate of, and is not out of proportion to the Company's premises and shall keep the Company's premises clean and tidy at all time; and
8.12.3 following Buyer’s legitimate interests for, any such assembly or installationlosses, restore damages, costs and claims which may be suffered by the Company’s premises on which it has been installing the Goods to the condition they were in before it commenced such installationBuyer.
Appears in 2 contracts
Sources: Standard Terms and Conditions, Standard Terms and Conditions for Purchase and Hire of Goods/Services
Delivery and Acceptance. 8.1 The Goods shall be delivered to and the Services shall be performed at the Company's place of business or if some other place of delivery is 3.1 Unless otherwise agreed by the Company in writing by ▇▇▇▇▇▇▇▇▇, the dates and times of delivery or performance in the Contract are binding on the seller and must be strictly observed. The time or time of delivery or execution is an essential condition of the Contract. The seller is liable for any delay in the delivery or execution, except for a delay caused by force majeure (as defined in point 11), and the seller shall give BontexGeo appropriate instructions in connection with the delivery and execution of the goods or services.
3.2 Unless otherwise agreed in writing by BontexGeo, the goods are delivered DDP (Delivered Duty Paid, Incoterms 2010) at the destination stated in the Contract.
3.3 Partial delivery of goods or partial performance of services is only permitted if this is accepted in writing by BontexGeo.
3.4 If the Goods seller cannot comply with a delivery or provision execution date, the seller must immediately notify BontexGeo of the Services at that place during the Company's normal office hours. The Supplier shall off-load the Goods at its own risk as directed by the Company.
8.2 The Goods shall be delivered and/or the Services shall be performed on the date earliest possible delivery or within the period specified in the Order or if no such period is specified then within 28 days of the Order, unless the Company notifies the Supplier of a change in the required delivery date (giving the Supplier as much notice of the revised delivery date as practicable) in which case the Supplier shall deliver the Goods and/or perform the Services on or by the revised delivery execution date. Time Unless BontexGeo accepts a modified delivery and execution date for delivery of the Goods or performance of the Services shall be of the essence of the Agreement.
8.3 The Supplier shall ensure that each delivery of Goods is accompanied by a delivery note which is prominently displayed goods and which shows, inter aliaservices in writing, the order number, date of order, number of packages and contents and, in the case of part delivery, the outstanding balance remaining to be delivered. For the avoidance of doubt, the Supplier shall only be permitted to deliver in part where the Company has confirmed in writing or on the Order Form that it is willing to accept delivery in part.
8.4 If the Goods are not delivered or the Services are not performed on the due date then, without prejudice to any other rights which it may have, the Company reserves the right to:
8.4.1 terminate the Agreement in whole or in part without being liable to compensate the Supplier for any losses arising as a result of such cancellation or to make any payment to the Supplier other than in respect of Goods actually delivered or Services actually rendered to the Company prior to the date of such termination;
8.4.2 refuse to accept any subsequent delivery of the Goods or provision of the Services which the Supplier attempts to make;
8.4.3 recover from the Supplier any expenditure reasonably incurred by the Company in obtaining the Goods or Services in substitution from another supplier; and
8.4.4 claim damages for any reasonable additional costs, loss or expenses incurred by the Company which are in any way attributable to the Supplierseller's failure to deliver the Goods goods or provide the Services on the due date.
8.5 Any signature on behalf of the Company services on the delivery note is not evidence and execution date timely gives BontexGeo the right to (1) deduct from the prize (if BontexGeo has paid the price) or to claim from the seller compensation for delay, one (1) percent of the total Contract Price for each commenced calendar week, up to a maximum of fifteen (15) percent of the total Contract Price, and/or (2) to unilaterally terminate the Contract, after which the seller will repay any part of the Contract Price that the correct number or type of Goods has been paid in respect of these goods or services, and where BontexGeo has the right to return, at the expense of the seller, all goods have already been delivered under the Contract; and/or (3) to unilaterally terminate the Contract and (at the choice of BontexGeo) to purchase replacement goods or that services elsewhere; and (4) claim compensation from each of items (1), (2) and (i3) from the Goods supplied are seller for all direct, foreseeable indirect and/or consequential damages, costs and claims of any kind whatsoever, including in good condition the case of points (2) and (3) without limitation, the cost of replacing or otherwise meet returning the goods or services.
3.5 Upon delivery of the goods and/or the completion of the services, the seller will invite ▇▇▇▇▇▇▇▇▇ to inspect and check whether the goods and/or services have been performed in accordance with the requirements of the Agreement Contract and/or have visible defects. Provided that such invitation to inspect and control has been received, BontexGeo will inform the seller of any non-conformities and/or visible defects that have come to light within a period of thirty (30) days of receipt thereof. through the usual and reasonable control and inspection methods of BontexGeo. If BontexGeo establishes a non-conformity and / or visible defect, no acceptance of the relevant Ordergoods and / or services will take place. The Company signing of a proof of delivery, proof of completion, signing a performance sheet, the payment of a final invoice, the transfer of ownership or user right over the goods and/or the use of the services shall not be deemed to have accepted the Goods or Services until it has had a reasonable time to inspect them following delivery and has not notified the Supplier of its rejection considered as acceptance of the Goods or Services within that time. The Company shall also have the right to reject the Goods delivered goods and/or Services as though they had not been accepted for a reasonable time after any latent defect in the Goods or Services has become apparent. If the Company does not accept the Goods and/or Services as conforming to the Agreement, the relevant Order or any Specification, it may exercise any of the remedies set out in Condition 17services.
8.6 No Goods supplied or Services performed under the Agreement earlier than the date for delivery set out in the Order, or in any delivery schedule, will be accepted or paid for unless the Company notifies the Supplier in writing of its intention to accept the same.
8.7 The Supplier shall supply the Company on delivery of the Goods with full and clear operating, storage, handling and safety instructions, warning notices clearly displayed and other information as may be necessary for their proper use, maintenance and repair for the Company to accept delivery of the Goods.
8.8 Unless the Company expressly agrees otherwise in writing, containers and packing must be supplied free but will be returned to the Supplier, if required by written notice from the Supplier to the Company, at the Supplier's risk and expense.
8.9 Where more than one item of Goods is involved in the Order and the Company agrees to accept delivery by instalments, the Agreement shall be construed as a separate contract in respect of each instalment. Nevertheless failure to deliver any instalment shall entitle the Company at its option to treat the Agreement as repudiated.
8.10 If the Goods are delivered to the Company in excess of the quantities ordered the Company shall not be bound to pay for the excess and any excess will be and will remain at the Supplier's risk and will be returnable at the Supplier's expense.
8.11 The Supplier shall, free of charge and within 30 days from the giving of notice as provided below, either repair or replace (as the Company shall elect) such of the Goods as may either be damaged in transit or having been placed in transit, fail to be delivered to the Company provided that:
8.11.1 in the case of damage to such Goods in transit, the Company shall within 30 days of delivery give notice in writing to the Supplier that the Goods have been damaged;
8.11.2 in the case of non-delivery, the Company shall (provided that the Company has been notified of dispatch within 10 days of the notified date of delivery) give notice to the Supplier that the Goods have not been delivered.
8.12 If the Goods require assembly and installation, the Supplier shall:
8.12.1 carry out such work in accordance with Condition 2.4 above;
8.12.2 comply with the Company's requirements relating to access to and use and security of, the Company's premises and shall keep the Company's premises clean and tidy at all time; and
8.12.3 following any such assembly or installation, restore the Company’s premises on which it has been installing the Goods to the condition they were in before it commenced such installation.
Appears in 1 contract
Sources: General Purchase Conditions
Delivery and Acceptance. 8.1 5.1 The Goods shall be delivered to and the Services shall be performed at the Company's place of business or if some other place of delivery is agreed by the Company in writing by delivery of the Goods or provision performance of the Services shall take place at that place during the Company's normal office hours. The Supplier shall off-load the Goods at its own risk as directed address by the Company.
8.2 The Goods shall be delivered and/or the Services shall be performed on the date or within the period specified stated in the Order PO or if no such period is specified then within 28 days subsequent written notice, in either case during the Company’s usual business hours.
5.2 The time of the Order, unless the Company notifies the Supplier of a change in the required delivery date (giving the Supplier as much notice of the revised delivery date as practicable) in which case the Supplier shall deliver the Goods and/or perform the Services on or by the revised delivery date. Time for delivery of the Goods or and of performance of the Services shall be is of the essence of this Agreement. The stipulated time for delivery/performance shall be strictly adhered to. Without prejudice to the AgreementSeller’s obligation to deliver/perform on time, the Seller shall give the Company notice in writing immediately if any delay is foreseen.
8.3 The Supplier shall ensure that each delivery of Goods is accompanied by a delivery note which is prominently displayed and which shows, inter alia, the order number, date of order, number of packages and contents and, in the case of part delivery, the outstanding balance remaining to be delivered. For the avoidance of doubt, the Supplier shall only be permitted to deliver in part where the Company has confirmed in writing or on the Order Form that it is willing to accept delivery in part.
8.4 5.3 If the Goods are not delivered to be delivered, or the Services are to be performed by installments, this Agreement will be treated as a single contract and not performed on severable.
5.4 The Seller shall bear all taxes, duties, and charges including packaging, transportation and insurance, and all costs and expenses involved in the due date thenimportation of the Goods. The Seller shall arrange and bear the responsibility for and the cost of prompt unloading, without prejudice stacking, packing, crating and storing of the Goods.
5.5 The Goods shall be marked in accordance with the Company’s instructions and any applicable regulations or requirements of the carrier, and properly packed and secured so as to any other rights which it may have, the reach their destination in an undamaged condition.
5.6 The Company reserves shall have the right to:
8.4.1 terminate to reject any Goods and/or Services which are not in accordance with this Agreement, in which event the Agreement in whole or in part without being liable to compensate the Supplier for any losses arising as a result of such cancellation or to make any payment to the Supplier other than in respect of Goods actually delivered or Services actually rendered to the Company prior to the date of such termination;
8.4.2 refuse to accept any subsequent delivery liabilities under Clause 8 shall apply. Any return of the Goods or provision of and/or Services to the Services which the Supplier attempts to make;
8.4.3 recover from the Supplier any expenditure reasonably incurred Seller shall be arranged by the Company in obtaining Seller and at the Goods or Services in substitution from another supplier; and
8.4.4 claim damages for any reasonable additional costs, loss or expenses incurred by the Company which are in any way attributable to the Supplier's failure to deliver the Goods or provide the Services on the due dateSeller’s expense.
8.5 Any signature on behalf of the Company on the delivery note is not evidence that the correct number or type of Goods has been delivered or that the Goods supplied are in good condition or otherwise meet the requirements of the Agreement or the relevant Order. 5.7 The Company shall not be deemed to have accepted the Goods or and/or Services until it the Company has had a reasonable time to inspect them following delivery and has not notified the Supplier of its rejection of the Goods or Services or, if later, within that time. The Company shall also have the right to reject the Goods and/or Services as though they had not been accepted for a reasonable time after any latent defect in the Goods or Services has become apparent. If the Company does not accept the Goods and/or Services as conforming to the Agreement, the relevant Order or any Specification, it may exercise any of the remedies set out in Condition 17.
8.6 No Goods supplied or Services performed under the Agreement earlier than the date for delivery set out in the Order, or in any delivery schedule, will be accepted or paid for unless the Company notifies the Supplier in writing of its intention to accept the same.
8.7 5.8 The Supplier shall supply the Company on delivery of the Goods with full and clear operating, storage, handling and safety instructions, warning notices clearly displayed and other information as may be necessary for their proper use, maintenance and repair for the Company to accept delivery of the Goods.
8.8 Unless the Company expressly agrees otherwise in writing, containers and packing must be supplied free but will be returned to the Supplier, if required by written notice from the Supplier to the Company, at the Supplier's risk and expense.
8.9 Where more than one item of Goods is involved in the Order and the Company agrees to accept delivery by instalments, the Agreement shall be construed as a separate contract in respect of each instalment. Nevertheless failure to deliver any instalment shall entitle the Company at its option to treat the Agreement as repudiated.
8.10 If the Goods are delivered to the Company in excess of the quantities ordered the Company shall not be bound obliged to pay return to the Seller any packaging or packing material for the excess and Goods, whether or not any excess will be and will remain at the Supplier's risk and will be returnable at the Supplier's expense.
8.11 The Supplier shall, free of charge and within 30 days from the giving of notice as provided below, either repair or replace (as the Company shall elect) such of the Goods as may either be damaged in transit or having been placed in transit, fail to be delivered to the Company provided that:
8.11.1 in the case of damage to such Goods in transit, the Company shall within 30 days of delivery give notice in writing to the Supplier that the Goods have been damaged;
8.11.2 in the case of non-delivery, the Company shall (provided that the Company has been notified of dispatch within 10 days of the notified date of delivery) give notice to the Supplier that the Goods have not been delivered.
8.12 If the Goods require assembly and installation, the Supplier shall:
8.12.1 carry out such work in accordance with Condition 2.4 above;
8.12.2 comply with are accepted by the Company's requirements relating to access to and use and security of, the Company's premises and shall keep the Company's premises clean and tidy at all time; and
8.12.3 following any such assembly or installation, restore the Company’s premises on which it has been installing the Goods to the condition they were in before it commenced such installation.
Appears in 1 contract
Sources: Standard Terms and Conditions
Delivery and Acceptance. 8.1 5.1 The Goods shall be delivered to and the Services shall be performed at the Company's place of business or if some other place of delivery is agreed by the Company in writing by delivery of and the Goods supplied to or provision of installed at the Services at that place during the Company's normal office hours. The Supplier shall off-load the Goods at its own risk as directed by the Company.
8.2 The Goods shall be delivered and/or the Services shall be performed Delivery Address on the date or within and at the period time specified in the Order or if no such period is specified then within 28 days of the Purchase Order, unless the Company notifies the Supplier of a change in the required delivery date (giving the Supplier as much notice of the revised delivery date as practicable) in which case the Supplier shall deliver the Goods and/or perform the Services on or by the revised delivery date. Time The time for delivery of the Goods or performance and Services is of the Services shall be of the essence of the Agreementessence.
8.3 The Supplier shall ensure that each delivery of 5.2 All invoices relating to the Goods is accompanied by a delivery note which is and Services must be prominently displayed and which shows, inter alia, marked with the order Purchase Order number, date of order, number of packages quantity and contents and, in the case of part delivery, the outstanding balance remaining description. Failure to be delivered. For the avoidance of doubt, the Supplier shall only be permitted to deliver in part where the Company has confirmed in writing or provide such accompanying information specified on the Purchase Order Form that it will result in non- acceptance of delivery or non-payment of invoice until such information is willing to accept delivery in partprovided.
8.4 If the 5.3 Wincanton shall be entitled to reject any Goods and/or Services delivered which are not delivered in accordance with this Agreement, or the Services are not performed on the due date then, without prejudice to any other rights which it may have, the Company reserves the right to:
8.4.1 terminate the Agreement in whole or in part without being liable to compensate the Supplier for any losses arising as a result of such cancellation or to make any payment to the Supplier other than in respect of Goods actually delivered or Services actually rendered to the Company prior to the date of such termination;
8.4.2 refuse to accept any subsequent delivery of the Goods or provision of the Services which the Supplier attempts to make;
8.4.3 recover from the Supplier any expenditure reasonably incurred by the Company in obtaining the Goods or Services in substitution from another supplier; and
8.4.4 claim damages for any reasonable additional costs, loss or expenses incurred by the Company which are in any way attributable to the Supplier's failure to deliver the Goods or provide the Services on the due date.
8.5 Any signature on behalf of the Company on the delivery note is not evidence that the correct number or type of Goods has been delivered or that the Goods supplied are in good condition or otherwise meet the requirements of the Purchase Order issued under this Agreement or the relevant Order. The Company any Specification supplied in relation to this Agreement, and shall not be deemed to have accepted the relevant Goods or and/or Services (notwithstanding any prior payment thereto) until it has Wincanton has, as the context requires, either had a reasonable time to inspect them the Goods following delivery and has not notified the Supplier of its rejection of the Goods or Services or, if later, within that time. The Company shall also have the right to reject the Goods and/or Services as though they had not been accepted for a reasonable time after any latent defect in the Goods or Services has become apparent. If apparent or had a reasonable time to review the Company does results of the Services.
5.4 Without prejudice to any other remedy, if any Goods and/or Services are not accept supplied in accordance with the Agreement, or as specified in any Purchase Order and/or Specification issued under the Agreement, Wincanton shall be entitled: -
(a) to reject the Goods and/or Services in whole or in part;
(b) to require the Supplier to, as conforming to the Agreementcontext requires, replace, repair, or otherwise remedy the relevant Order Goods; and/or re-perform the relevant Services; and/or
(c) at Wincanton’s option and without prejudice to any other right or any Specificationremedy to which Wincanton is entitled, it may exercise any of the remedies set out in Condition 17.
8.6 No Goods supplied or Services performed under the Agreement earlier than the date for delivery set out in the Order, or in any delivery schedule, will be accepted or paid for unless the Company notifies the Supplier in writing of its intention to accept the same.
8.7 The Supplier shall supply the Company on delivery of the Goods with full and clear operating, storage, handling and safety instructions, warning notices clearly displayed and other information as may be necessary for their proper use, maintenance and repair for the Company to accept delivery of the Goods.
8.8 Unless the Company expressly agrees otherwise in writing, containers and packing must be supplied free but will be returned to the Supplier, if required by written notice from the Supplier to the Company, at the Supplier's risk and expense.
8.9 Where more than one item of Goods is involved in the Order and the Company agrees to accept delivery by instalments, the Agreement shall be construed as a separate contract in respect of each instalment. Nevertheless failure to deliver any instalment shall entitle the Company at its option to treat the Agreement as repudiated.
8.10 If discharged by the Goods are delivered to Supplier’s breach and require the Company in excess repayment of any part of the quantities ordered the Company shall not be bound Price which has been paid by Wincanton in relation to pay for the excess and any excess will be and will remain at the Supplier's risk and will be returnable at the Supplier's expense.
8.11 The Supplier shall, free of charge and within 30 days from the giving of notice as provided below, either repair or replace (as the Company shall elect) such of the Goods as may either be damaged in transit or having been placed in transit, fail to be delivered to the Company provided that:
8.11.1 in the case of damage to such Goods in transit, the Company shall within 30 days of delivery give notice in writing to the Supplier that the Goods have been damaged;
8.11.2 in the case of non-delivery, the Company shall (provided that the Company has been notified of dispatch within 10 days of the notified date of delivery) give notice to the Supplier that the conforming Goods have not been deliveredand/or Services.
8.12 If the Goods require assembly and installation, the Supplier shall:
8.12.1 carry out such work in accordance with Condition 2.4 above;
8.12.2 comply with the Company's requirements relating to access to and use and security of, the Company's premises and shall keep the Company's premises clean and tidy at all time; and
8.12.3 following any such assembly or installation, restore the Company’s premises on which it has been installing the Goods to the condition they were in before it commenced such installation.
Appears in 1 contract
Sources: Standard Conditions of Purchase for Goods and Services
Delivery and Acceptance. 8.1 The Goods shall be delivered to and the Services shall be performed at the Company's place of business or if some other place of delivery is 3.1 Unless otherwise agreed by the Company in writing by BontexGeo, the dates and times of delivery or performance in the Contract are binding on the seller and must be strictly observed. The time or time of delivery or execution is an essential condition of the Contract. The seller is liable for any delay in the delivery or execution, except for a delay caused by force majeure (as defined in point 11), and the seller shall give BontexGeo appropriate instructions in connection with the delivery and execution of the goods or services.
3.2 Unless otherwise agreed in writing by BontexGeo, the goods are delivered DDP (Delivered Duty Paid, Incoterms 2010) at the destination stated in the Contract.
3.3 Partial delivery of goods or partial performance of services is only permitted if this is accepted in writing by BontexGeo.
3.4 If the Goods seller cannot comply with a delivery or provision execution date, the seller must immediately notify BontexGeo of the Services at that place during the Company's normal office hours. The Supplier shall off-load the Goods at its own risk as directed by the Company.
8.2 The Goods shall be delivered and/or the Services shall be performed on the date earliest possible delivery or within the period specified in the Order or if no such period is specified then within 28 days of the Order, unless the Company notifies the Supplier of a change in the required delivery date (giving the Supplier as much notice of the revised delivery date as practicable) in which case the Supplier shall deliver the Goods and/or perform the Services on or by the revised delivery execution date. Time Unless BontexGeo accepts a modified delivery and execution date for delivery of the Goods or performance of the Services shall be of the essence of the Agreement.
8.3 The Supplier shall ensure that each delivery of Goods is accompanied by a delivery note which is prominently displayed goods and which shows, inter aliaservices in writing, the order number, date of order, number of packages and contents and, in the case of part delivery, the outstanding balance remaining to be delivered. For the avoidance of doubt, the Supplier shall only be permitted to deliver in part where the Company has confirmed in writing or on the Order Form that it is willing to accept delivery in part.
8.4 If the Goods are not delivered or the Services are not performed on the due date then, without prejudice to any other rights which it may have, the Company reserves the right to:
8.4.1 terminate the Agreement in whole or in part without being liable to compensate the Supplier for any losses arising as a result of such cancellation or to make any payment to the Supplier other than in respect of Goods actually delivered or Services actually rendered to the Company prior to the date of such termination;
8.4.2 refuse to accept any subsequent delivery of the Goods or provision of the Services which the Supplier attempts to make;
8.4.3 recover from the Supplier any expenditure reasonably incurred by the Company in obtaining the Goods or Services in substitution from another supplier; and
8.4.4 claim damages for any reasonable additional costs, loss or expenses incurred by the Company which are in any way attributable to the Supplierseller's failure to deliver the Goods goods or provide the Services on the due date.
8.5 Any signature on behalf of the Company services on the delivery note is not evidence and execution date timely gives BontexGeo the right to (1) deduct from the prize (if BontexGeo has paid the price) or to claim from the seller compensation for delay, one (1) percent of the total Contract Price for each commenced calendar week, up to a maximum of fifteen (15) percent of the total Contract Price, and/or (2) to unilaterally terminate the Contract, after which the seller will repay any part of the Contract Price that the correct number or type of Goods has been paid in respect of these goods or services, and where BontexGeo has the right to return, at the expense of the seller, all goods have already been delivered under the Contract; and/or (3) to unilaterally terminate the Contract and (at the choice of BontexGeo) to purchase replacement goods or that services elsewhere; and (4) claim compensation from each of items (1), (2) and (i3) from the Goods supplied are seller for all direct, foreseeable indirect and/or consequential damages, costs and claims of any kind whatsoever, including in good condition the case of points (2) and (3) without limitation, the cost of replacing or otherwise meet returning the goods or services.
3.5 Upon delivery of the goods and/or the completion of the services, the seller will invite BontexGeo to inspect and check whether the goods and/or services have been performed in accordance with the requirements of the Agreement Contract and/or have visible defects. Provided that such invitation to inspect and control has been received, BontexGeo will inform the seller of any non-conformities and/or visible defects that have come to light within a period of thirty (30) days of receipt thereof. through the usual and reasonable control and inspection methods of BontexGeo. If BontexGeo establishes a non-conformity and / or visible defect, no acceptance of the relevant Ordergoods and / or services will take place. The Company signing of a proof of delivery, proof of completion, signing a performance sheet, the payment of a final invoice, the transfer of ownership or user right over the goods and/or the use of the services shall not be deemed to have accepted the Goods or Services until it has had a reasonable time to inspect them following delivery and has not notified the Supplier of its rejection considered as acceptance of the Goods or Services within that time. The Company shall also have the right to reject the Goods delivered goods and/or Services as though they had not been accepted for a reasonable time after any latent defect in the Goods or Services has become apparent. If the Company does not accept the Goods and/or Services as conforming to the Agreement, the relevant Order or any Specification, it may exercise any of the remedies set out in Condition 17services.
8.6 No Goods supplied or Services performed under the Agreement earlier than the date for delivery set out in the Order, or in any delivery schedule, will be accepted or paid for unless the Company notifies the Supplier in writing of its intention to accept the same.
8.7 The Supplier shall supply the Company on delivery of the Goods with full and clear operating, storage, handling and safety instructions, warning notices clearly displayed and other information as may be necessary for their proper use, maintenance and repair for the Company to accept delivery of the Goods.
8.8 Unless the Company expressly agrees otherwise in writing, containers and packing must be supplied free but will be returned to the Supplier, if required by written notice from the Supplier to the Company, at the Supplier's risk and expense.
8.9 Where more than one item of Goods is involved in the Order and the Company agrees to accept delivery by instalments, the Agreement shall be construed as a separate contract in respect of each instalment. Nevertheless failure to deliver any instalment shall entitle the Company at its option to treat the Agreement as repudiated.
8.10 If the Goods are delivered to the Company in excess of the quantities ordered the Company shall not be bound to pay for the excess and any excess will be and will remain at the Supplier's risk and will be returnable at the Supplier's expense.
8.11 The Supplier shall, free of charge and within 30 days from the giving of notice as provided below, either repair or replace (as the Company shall elect) such of the Goods as may either be damaged in transit or having been placed in transit, fail to be delivered to the Company provided that:
8.11.1 in the case of damage to such Goods in transit, the Company shall within 30 days of delivery give notice in writing to the Supplier that the Goods have been damaged;
8.11.2 in the case of non-delivery, the Company shall (provided that the Company has been notified of dispatch within 10 days of the notified date of delivery) give notice to the Supplier that the Goods have not been delivered.
8.12 If the Goods require assembly and installation, the Supplier shall:
8.12.1 carry out such work in accordance with Condition 2.4 above;
8.12.2 comply with the Company's requirements relating to access to and use and security of, the Company's premises and shall keep the Company's premises clean and tidy at all time; and
8.12.3 following any such assembly or installation, restore the Company’s premises on which it has been installing the Goods to the condition they were in before it commenced such installation.
Appears in 1 contract
Sources: General Purchase Conditions
Delivery and Acceptance. 8.1 4.1 The Goods Delivery Date, as stated on the Order, is binding upon the Supplier unless otherwise agreed to in writing by the Purchaser.
4.2 The Services and/or Materials shall be delivered to and the Services shall be performed at the Company's place of business or if some other place of delivery is agreed Delivery Address by the Company in writing by delivery of the Goods or provision of the Services at that place during the Company's normal office hours. The Supplier shall off-load the Goods at its own risk as directed by the Company.
8.2 The Goods shall be delivered and/or the Services shall be performed on the date or within the period specified in the Order or if no such period is specified then within 28 days of the Order, unless the Company notifies the Supplier of a change in the required delivery date (giving the Supplier as much notice of the revised delivery date as practicable) in which case the Supplier shall deliver the Goods and/or perform the Services on or by the revised relevant Delivery Date during the Purchaser's usual business hours and off- loaded by the Supplier unless the Purchaser requests otherwise.
4.3 No consignment of Materials shall be deemed to have been delivered unless a delivery date. note has been signed by a duly authorised representative of the Purchaser.
4.4 Time for of delivery of the Goods or performance of the Services shall be and/or Materials is of the essence of the this Agreement.
8.3 4.5 The Supplier shall ensure that each supply the Purchaser in good time with any instructions or other information required enabling the Purchaser to accept delivery of Goods is accompanied the Services and/or the Materials.
4.6 If a Delivery Date cannot be met by a delivery note which is prominently displayed and which shows, inter alia, the order number, date of order, number of packages and contents and, in the case of part delivery, the outstanding balance remaining to be delivered. For the avoidance of doubtSupplier, the Supplier shall only be permitted promptly notify the Purchaser of the earliest possible date for delivery. Notwithstanding such notice, and unless a substitute delivery date for the Services and/or Materials has been expressly agreed by the Purchaser in writing, the Supplier's failure to deliver in part where effect delivery of the Company has confirmed in writing or Services and/or Materials on the Order Form that it is willing to accept delivery in part.
8.4 If Delivery Date shall entitle the Goods are not delivered or the Services are not performed on the due date thenPurchaser, without prejudice to any other rights which remedy it may have, the Company reserves the right have to:
8.4.1 terminate 4.6.1 deduct from the Price or (if the Purchaser has paid the Price) to claim from the Supplier by way of liquidated damages for delay 2 per cent of the price for every week's or part week's delay, up to a maximum of 15 per cent of the Price; and/or
4.6.2 cancel the Agreement in whole or in part without being liable to compensate part, whereupon if requested by the Purchaser the Supplier for shall refund any losses arising as a result part of such cancellation or to make any payment to the Supplier other than Price which has been paid in respect of Goods actually delivered or such Services actually rendered to and/or Materials and the Company prior to the date of such termination;
8.4.2 refuse to accept any subsequent delivery Purchaser shall, on receipt of the Goods or provision of the Services which the Supplier attempts to make;
8.4.3 recover from the Supplier any expenditure reasonably incurred by the Company in obtaining the Goods or Services in substitution from another supplier; and
8.4.4 claim damages for any reasonable additional costs, loss or expenses incurred by the Company which are in any way attributable to the Supplier's failure to deliver the Goods or provide the Services on the due date.
8.5 Any signature on behalf of the Company on the delivery note is not evidence that the correct number or type of Goods has been delivered or that the Goods supplied are in good condition or otherwise meet the requirements of the Agreement or the relevant Order. The Company shall not be deemed to have accepted the Goods or Services until it has had a reasonable time to inspect them following delivery and has not notified the Supplier of its rejection of the Goods or Services within that time. The Company shall also have the right to reject the Goods and/or Services as though they had not been accepted for a reasonable time after any latent defect in the Goods or Services has become apparent. If the Company does not accept the Goods and/or Services as conforming to the Agreement, the relevant Order or any Specification, it may exercise any of the remedies set out in Condition 17.
8.6 No Goods supplied or Services performed under the Agreement earlier than the date for delivery set out in the Order, or in any delivery schedule, will be accepted or paid for unless the Company notifies the Supplier in writing of its intention to accept the same.
8.7 The Supplier shall supply the Company on delivery of the Goods with full and clear operating, storage, handling and safety instructions, warning notices clearly displayed and other information as may be necessary for their proper use, maintenance and repair for the Company to accept delivery of the Goods.
8.8 Unless the Company expressly agrees otherwise in writing, containers and packing must be supplied free but will be returned to the Supplier, if required by written notice from the Supplier to the Companyrefund, at the Supplier's risk and expense., return any Materials already supplied under the Agreement; and/or
8.9 Where more than one item of Goods 4.6.3 (where delivery is involved in the Order and the Company agrees to accept delivery by instalments) cancel that instalment and (at the Purchaser's option) purchase substitute Services and/or Materials elsewhere; and in each case in paragraphs 4.6.1, 4.6.2 and 4.6.3 inclusive recover from the Supplier any costs and liabilities incurred by the Purchaser (including, without limitation, the Agreement shall be construed as a separate contract in respect costs of each instalment. Nevertheless failure to deliver any instalment shall entitle the Company at its option to treat the Agreement as repudiatedreplacement Services and/or Materials).
8.10 If the Goods are delivered to the Company in excess of the quantities ordered the Company shall not be bound to pay for the excess and any excess will be and will remain at the Supplier's risk and will be returnable at the Supplier's expense.
8.11 The Supplier shall, free of charge and within 30 days from the giving of notice as provided below, either repair or replace (as the Company shall elect) such of the Goods as may either be damaged in transit or having been placed in transit, fail to be delivered to the Company provided that:
8.11.1 in the case of damage to such Goods in transit, the Company shall within 30 days of delivery give notice in writing to the Supplier that the Goods have been damaged;
8.11.2 in the case of non-delivery, the Company shall (provided that the Company has been notified of dispatch within 10 days of the notified date of delivery) give notice to the Supplier that the Goods have not been delivered.
8.12 If the Goods require assembly and installation, the Supplier shall:
8.12.1 carry out such work in accordance with Condition 2.4 above;
8.12.2 comply with the Company's requirements relating to access to and use and security of, the Company's premises and shall keep the Company's premises clean and tidy at all time; and
8.12.3 following any such assembly or installation, restore the Company’s premises on which it has been installing the Goods to the condition they were in before it commenced such installation.
Appears in 1 contract
Sources: General Terms and Conditions for the Purchase of Sub Threshold Services
Delivery and Acceptance. 8.1 5.1 The Services shall be performed at and the Goods shall be delivered to and the Services shall be performed at the CompanyCharity's place of business business, or if some other place of delivery is agreed as notified by the Company Charity in writing by delivery of the Goods or provision of the Services at that place writing, during the CompanyCharity's normal office hours. The Supplier shall off-load the Goods at its own risk as directed by the Company.
8.2 5.2 The Services shall be performed or the Goods shall be delivered and/or the Services shall be performed on the date or within the period specified in the Order or if no such period is specified then within 28 days of the Order, unless the Company Charity notifies the Contractor or Supplier of a change in the required delivery date (giving the Contractor or Supplier as much notice of the revised delivery date as practicable) in which case the Contractor shall perform the Services or the Supplier shall deliver the Goods and/or perform the Services on or by the revised delivery date. Time for the performance of the Services or the delivery of the Goods or performance of the Services shall be of the essence of the Agreement.
8.3 The Supplier shall ensure that each delivery of Goods is accompanied by a delivery note which is prominently displayed and which shows, inter alia, 5.3 If the order number, date of order, number of packages and contents and, in the case of part delivery, the outstanding balance remaining to be delivered. For the avoidance of doubt, the Supplier shall only be permitted to deliver in part where the Company has confirmed in writing Services are not performed or on the Order Form that it is willing to accept delivery in part.
8.4 If the Goods are not delivered or the Services are not performed on the due date then, without prejudice to any other rights which it may have, the Company Charity reserves the right to:
8.4.1 5.3.1 terminate the Agreement in whole or in part without being liable to compensate the Contractor or Supplier for any losses arising as a result of such cancellation or to make any payment to the Contractor other than in respect of Services actually rendered or to the Supplier other than in respect of Goods actually delivered or Services actually rendered to the Company Charity prior to the date of such termination;
8.4.2 5.3.2 refuse to accept any subsequent provision of the Services which the Contractor attempts to make or delivery of the Goods or provision of the Services which the Supplier attempts to make;
8.4.3 5.3.3 recover from the Contractor or Supplier repayment of any Charges paid in advance in respect of the Services or Goods or any expenditure reasonably incurred by the Company Charity in obtaining the Services or Goods or Services in substitution from another contractor or supplier; and
8.4.4 5.3.4 claim damages for any reasonable additional costs, loss or expenses incurred by the Company Charity which are in any way attributable to the Contractors failure to provide the Services or the Supplier's failure to deliver the Goods or provide the Services on the due date.
8.5 Any signature on behalf of the Company on the delivery note is not evidence that the correct number or type of Goods has been delivered or that the Goods supplied are in good condition or otherwise meet the requirements of the Agreement or the relevant Order. The Company shall not be deemed to have accepted the Goods or Services until it has had a reasonable time to inspect them following delivery and has not notified the Supplier of its rejection of the Goods or Services within that time. The Company shall also have the right to reject the Goods and/or Services as though they had not been accepted for a reasonable time after any latent defect in the Goods or Services has become apparent. If the Company does not accept the Goods and/or Services as conforming to the Agreement, the relevant Order or any Specification, it may exercise any of the remedies set out in Condition 17.
8.6 No Goods supplied or Services performed under the Agreement earlier than the date for delivery set out in the Order, or in any delivery schedule, will be accepted or paid for unless the Company notifies the Supplier in writing of its intention to accept the same.
8.7 The Supplier shall supply the Company on delivery of the Goods with full and clear operating, storage, handling and safety instructions, warning notices clearly displayed and other information as may be necessary for their proper use, maintenance and repair for the Company to accept delivery of the Goods.
8.8 Unless the Company expressly agrees otherwise in writing, containers and packing must be supplied free but will be returned to the Supplier, if required by written notice from the Supplier to the Company, at the Supplier's risk and expense.
8.9 Where more than one item of Goods is involved in the Order and the Company agrees to accept delivery by instalments, the Agreement shall be construed as a separate contract in respect of each instalment. Nevertheless failure to deliver any instalment shall entitle the Company at its option to treat the Agreement as repudiated.
8.10 If the Goods are delivered to the Company in excess of the quantities ordered the Company shall not be bound to pay for the excess and any excess will be and will remain at the Supplier's risk and will be returnable at the Supplier's expense.
8.11 The Supplier shall, free of charge and within 30 days from the giving of notice as provided below, either repair or replace (as the Company shall elect) such of the Goods as may either be damaged in transit or having been placed in transit, fail to be delivered to the Company provided that:
8.11.1 in the case of damage to such Goods in transit, the Company shall within 30 days of delivery give notice in writing to the Supplier that the Goods have been damaged;
8.11.2 in the case of non-delivery, the Company shall (provided that the Company has been notified of dispatch within 10 days of the notified date of delivery) give notice to the Supplier that the Goods have not been delivered.
8.12 If the Goods require assembly and installation, the Supplier shall:
8.12.1 carry out such work in accordance with Condition 2.4 above;
8.12.2 comply with the Company's requirements relating to access to and use and security of, the Company's premises and shall keep the Company's premises clean and tidy at all time; and
8.12.3 following any such assembly or installation, restore the Company’s premises on which it has been installing the Goods to the condition they were in before it commenced such installation.
Appears in 1 contract
Sources: Terms and Conditions of Purchase
Delivery and Acceptance. 8.1 The Goods 7.1. If following the conclusion of the contract for Services there is a need for delivery, that delivery is carried out (if technically feasible) by courier service under the agreement between the Buyer and the Website Administration, or to the pickup point, or by agreement between the Buyer and the Website Administration by the Trade Partner’s courier service unless otherwise is set forth in the Advertisement. If it is possible to carry out electronic delivery, the information thereon shall be delivered available to the Buyer when placing an Order.
7.2. The procedure for delivery, its price and other terms of carrying out the Services delivery are specified on the Website.
7.3. The delivery is carried out within the period agreed upon with the Buyer.
7.4. The Buyer shall be performed obliged to perform the acceptance of the delivered Service by its quantity, quality, range and completeness in the presence of the courier who delivered it.
7.5. The Buyer shall send all the claims concerned with inadequate quality of the delivered Service, as well as the requests for refund that arose within three (3) calendar days upon acceptance of the delivered Service by the Buyer, to the Trade Partner, with whom the Buyer has concluded the contract for Service, using the contact details that are specified by the respective Trade Partner on his/her page on the Website. In this case, the Website Administration shall assist the Buyers in settlement of their claims to the Trade Partners by providing all the information available to the Website Administration regarding the work procedure, conditions for providing the Services, conditions of return of the funds paid for the Services, location of the respective Trade Partners, as well as any other information relevant for settlement of such claims, which is at the Company's place of business or if some other place of delivery is agreed by the Company in writing by delivery disposal of the Goods Website Administration and is not confidential by virtue of a law or provision of the Services at that place during the Company's normal office hours. The Supplier shall off-load the Goods at its own risk as directed by the Companycontract.
8.2 The Goods 7.6. If the Buyer chooses pickup instead of delivery, the Buyer shall be delivered and/or obliged to pick up what is meant for him/her from the Services shall be performed on the date or pickup point within the period specified in on the Order or if no such Website upon concluding the contract for Services as the period for Buyer’s picking up unless another period is specified then within 28 days of agreed upon with the Order, unless the Company notifies the Supplier of a change in the required delivery date (giving the Supplier as much notice of the revised delivery date as practicable) in which case the Supplier shall deliver the Goods and/or perform the Services on Buyer or set by the revised delivery date. Time for delivery of the Goods or performance of the Services shall be of the essence of the Agreement.
8.3 The Supplier shall ensure that each delivery of Goods is accompanied by a delivery note which is prominently displayed and which shows, inter alia, the order number, date of order, number of packages and contents and, in the case of part delivery, the outstanding balance remaining to be delivered. For the avoidance of doubt, the Supplier shall only be permitted to deliver in part where the Company has confirmed in writing or on the Order Form that it is willing to accept delivery in part.
8.4 If the Goods are not delivered or the Services are not performed on the due date then, without prejudice to any other rights which it may have, the Company reserves the right to:
8.4.1 terminate the Agreement in whole or in part without being liable to compensate the Supplier for any losses arising as a result of such cancellation or to make any payment to the Supplier other than in respect of Goods actually delivered or Services actually rendered to the Company prior to the date of such termination;
8.4.2 refuse to accept any subsequent delivery of the Goods or provision of the Services which the Supplier attempts to make;
8.4.3 recover from the Supplier any expenditure reasonably incurred by the Company in obtaining the Goods or Services in substitution from another supplier; and
8.4.4 claim damages for any reasonable additional costs, loss or expenses incurred by the Company which are in any way attributable to the Supplier's failure to deliver the Goods or provide the Services on the due date.
8.5 Any signature on behalf of the Company on the delivery note is not evidence that the correct number or type of Goods has been delivered or that the Goods supplied are in good condition or otherwise meet the requirements of the Agreement or the relevant Order. The Company shall not be deemed to have accepted the Goods or Services until it has had a reasonable time to inspect them following delivery and has not notified the Supplier of its rejection of the Goods or Services within that time. The Company shall also have the right to reject the Goods and/or Services as though they had not been accepted for a reasonable time after any latent defect in the Goods or Services has become apparentapplicable law. If the Company Buyer does not accept pick up what is meant for him/her from the Goods and/or Services as conforming to pickup point within a period agreed upon with the AgreementBuyer specified in “Delivery” section on the Website, the relevant Order or any Specification, it may exercise any of Service not received by the remedies set out in Condition 17.
8.6 No Goods supplied or Services performed under the Agreement earlier than the date for delivery set out in the Order, or in any delivery schedule, will be accepted or paid for unless the Company notifies the Supplier in writing of its intention to accept the same.
8.7 The Supplier Buyer shall supply the Company on delivery of the Goods with full and clear operating, storage, handling and safety instructions, warning notices clearly displayed and other information as may be necessary for their proper use, maintenance and repair for the Company to accept delivery of the Goods.
8.8 Unless the Company expressly agrees otherwise in writing, containers and packing must be supplied free but will be returned to the SupplierTrade Partner, if required with the Buyer paying for the redelivery (return) of what was not received by written notice him/her from the Supplier pickup point to the CompanyTrade Partner, at unless otherwise is provided by the Supplier's risk and expenseapplicable law.
8.9 Where more than one item of Goods is involved in the Order and the Company agrees to accept delivery by instalments, the Agreement shall be construed as a separate contract in respect of each instalment. Nevertheless failure to deliver any instalment shall entitle the Company at its option to treat the Agreement as repudiated.
8.10 If the Goods are delivered to the Company in excess of the quantities ordered the Company shall not be bound to pay for the excess and any excess will be and will remain at the Supplier's risk and will be returnable at the Supplier's expense.
8.11 The Supplier shall, free of charge and within 30 days from the giving of notice as provided below, either repair or replace (as the Company shall elect) such of the Goods as may either be damaged in transit or having been placed in transit, fail to be delivered to the Company provided that:
8.11.1 in the case of damage to such Goods in transit, the Company shall within 30 days of delivery give notice in writing to the Supplier that the Goods have been damaged;
8.11.2 in the case of non-delivery, the Company shall (provided that the Company has been notified of dispatch within 10 days of the notified date of delivery) give notice to the Supplier that the Goods have not been delivered.
8.12 If the Goods require assembly and installation, the Supplier shall:
8.12.1 carry out such work in accordance with Condition 2.4 above;
8.12.2 comply with the Company's requirements relating to access to and use and security of, the Company's premises and shall keep the Company's premises clean and tidy at all time; and
8.12.3 following any such assembly or installation, restore the Company’s premises on which it has been installing the Goods to the condition they were in before it commenced such installation.
Appears in 1 contract
Sources: User Agreement
Delivery and Acceptance. 8.1 The Goods shall be delivered to and the Services shall be performed at the Company's place of business or if some other place of delivery is 2.1 Unless otherwise agreed by the Company in writing by delivery of the Goods or provision of the Services at that place during the Company's normal office hours. The PO, Supplier shall off-load the Goods shall, at its own risk expense, deliver the Goods during a Working Day, properly packed and secured to the place specified in the PO or such other location as directed may subsequently be advised in writing by the Company.
8.2 The Company to Supplier. All Goods shall be delivered and/or the Services shall be performed on the date or within the period specified in the Order or if no such period is specified then within 28 days of the Order, unless the Company notifies the Supplier of a change in the required delivery date (giving the Supplier as much notice of the revised delivery date as practicable) in which case the Supplier shall deliver the Goods and/or perform the Services on or by the revised delivery date. Time for delivery of the Goods or performance of the Services relevant Completion Dates, and time shall be of the essence of the Agreement.
8.3 The Supplier shall ensure that each delivery of Goods is accompanied by a delivery note which is prominently displayed and which shows, inter alia, the order number, date of order, number of packages and contents and, in the case of part delivery, the outstanding balance remaining relation to be delivered. For the avoidance of doubt, the Supplier shall only be permitted to deliver in part where the Company has confirmed in writing or on the Order Form that it is willing to accept delivery in part.
8.4 If the Goods are not delivered or the Services are not performed on the due date then, without prejudice to any other rights which it may have, the Company reserves the right to:
8.4.1 terminate the Agreement in whole or in part without being liable to compensate the Supplier for any losses arising as a result of such cancellation or to make any payment to the Supplier other than in respect of Goods actually delivered or Services actually rendered to the Company prior to the date of such termination;
8.4.2 refuse to accept any subsequent delivery of the Goods or provision of the Services which the Supplier attempts to make;
8.4.3 recover from the Supplier any expenditure reasonably incurred by the Company in obtaining the Goods or Services in substitution from another supplier; and
8.4.4 claim damages for any reasonable additional costs, loss or expenses incurred by the Company which are in any way attributable to the Supplier's failure to deliver the Goods or provide the Services on the due date.
8.5 Any signature on behalf of the Company on the delivery note is not evidence that the correct number or type of Goods has been delivered or that the Goods supplied are in good condition or otherwise meet the requirements of the Agreement or the relevant Order. The Company shall not be deemed to have accepted the Goods or Services until it has had a reasonable time to inspect them following delivery and has not notified the Supplier of its rejection of the Goods or Services within that time. The Company shall also have the right to reject the Goods and/or Services as though they had not been accepted for a reasonable time after any latent defect in the Goods or Services has become apparent. If the Company does not accept the Goods and/or Services as conforming to the Agreement, the relevant Order or any Specification, it may exercise any of the remedies set out in Condition 17.
8.6 No Goods supplied or Services performed under the Agreement earlier than the date for delivery set out in the Order, or in any delivery schedule, will be accepted or paid for unless the Company notifies the Supplier in writing of its intention to accept the same.
8.7 The Supplier shall supply the Company on delivery of the Goods with full and clear operating, storage, handling and safety instructions, warning notices clearly displayed and other information as may be necessary for their proper use, maintenance and repair for the Company to accept delivery of the Goods.
8.8 Unless 2.2 Supplier shall supply Company in good time with any instruction or other information required to enable Company to take delivery of the Goods.
2.3 Company shall accept Goods immediately after Supplier has demonstrated to Company’s satisfaction that the Goods (i) comply with the PO pursuant to which they are supplied; (ii) comply with the relevant Agreement; and (iii) are in accordance with the Specification, and “Acceptance” shall be construed accordingly for the purposes of this Schedule 1.
2.4 Company may reject any Goods delivered earlier or later than the relevant Completion Date, unless previously agreed in writing by the Parties provided that Company shall use its reasonable endeavours to accommodate deliveries effected prior to the relevant Completion Date.
2.5 If the Goods (or any parts of them) are not delivered by the relevant Completion Date, Company may terminate in whole or in part the relevant Agreement without cost or liability. Prior to exercising such right of termination, the Company expressly agrees otherwise in writing, containers shall provide the Supplier with 5 Working Days notice of its intention to exercise such right of termination and packing must be supplied free but will be returned to the Supplier, if required by written notice from allow the Supplier to the Company, at the Supplier's risk and expense.
8.9 expedite delivery. Where more than one item of Goods is involved Company exercises this option for termination: (a) Supplier shall refund to Company in the Order and the full any payments made by Company agrees to accept delivery by instalments, the Agreement shall be construed as a separate contract Supplier in respect of each instalment. Nevertheless failure such Goods; (b) no further payment will be due from Company in respect of such Goods; (c) following receipt of payment in full of all monies due to deliver any instalment it in relation to the Goods in respect of which an Agreement has been terminated (whether in whole or in part) Company shall entitle the Company make such Goods available for collection by Supplier and Supplier shall collect such Goods at its option own expense within 5 Working Days of the payment, and if Supplier fails to treat collect within this period, Company may dispose of such Goods in its absolute discretion without notice or liability to Supplier; (d) title in the Agreement as repudiatedGoods will revert to Supplier following receipt by Company from Supplier of payment in full of the refund due to Company; and (e) risk in the Goods shall revert immediately to Supplier.
8.10 If the Goods are delivered 2.6 Supplier undertakes at its own expense to the Company in excess of the quantities ordered the Company shall not be bound to pay for the excess and any excess will be and will remain at the Supplier's risk and will be returnable at the Supplier's expense.
8.11 The Supplier shall, free of charge and within 30 days from the giving of notice as provided below, either repair or replace (as at the Company shall electoption of Company) such of the Goods as may either be lost or damaged in transit or having been placed in transit, fail and Acceptance will not be deemed to be have taken place until replacement or repaired items have been delivered to the Company provided that:
8.11.1 in the case satisfaction of damage to such Goods in transit, the Company shall within 30 days of delivery give notice in writing to the Supplier that the Goods have been damaged;
8.11.2 in the case of non-delivery, the Company shall (provided that the Company has been notified of dispatch within 10 days of the notified date of delivery) give notice to the Supplier that the Goods have not been deliveredCompany.
8.12 If the Goods require assembly and installation, the Supplier shall:
8.12.1 carry out such work in accordance with Condition 2.4 above;
8.12.2 comply with the Company's requirements relating to access to and use and security of, the Company's premises and shall keep the Company's premises clean and tidy at all time; and
8.12.3 following any such assembly or installation, restore the Company’s premises on which it has been installing the Goods to the condition they were in before it commenced such installation.
Appears in 1 contract
Sources: Purchase Agreement
Delivery and Acceptance. 8.1 The Goods shall be delivered to and the Services shall be performed at the Company's place of business or if some other place of delivery is agreed by the Company in writing by delivery of the Goods or provision of the Services at that place during the Company's normal office hours. The Supplier shall off-load the Goods at its own risk as directed by the Company.
8.2 The Goods shall be delivered and/or the Services shall be performed on the date or within the period specified in the Order or if no such period is specified then within 28 [14] days of the Order, unless the Company notifies the Supplier of a change in the required delivery date (giving the Supplier as much notice of the revised delivery date as practicable) in which case the Supplier shall deliver the Goods and/or perform the Services on or by the revised delivery date. Time for delivery of the Goods or performance of the Services shall be of the essence of the Agreement.
8.3 The Supplier shall ensure that each delivery of Goods is accompanied by a delivery note which is prominently displayed and which shows, inter alia, the order number, date of order, number of packages and contents and, in the case of part delivery, the outstanding balance remaining to be delivered. For the avoidance of doubt, the Supplier shall only be permitted to deliver in part where the Company has confirmed in writing or on the Order Form that it is willing to accept delivery in part.
8.4 If the Goods are not delivered or the Services are not performed on the due date then, without prejudice to any other rights which it may have, the Company reserves the right to:
8.4.1 terminate the Agreement in whole or in part without being liable to compensate the Supplier for any losses arising as a result of such cancellation or to make any payment to the Supplier other than in respect of Goods actually delivered or Services actually rendered to the Company prior to the date of such termination;
8.4.2 refuse to accept any subsequent delivery of the Goods or provision of the Services which the Supplier attempts to make;
8.4.3 recover from the Supplier any expenditure reasonably incurred by the Company in obtaining the Goods or Services in substitution from another supplier; and
8.4.4 claim damages for any reasonable additional costs, loss or expenses incurred by the Company which are in any way attributable to the Supplier's failure to deliver the Goods or provide the Services on the due date.
8.5 Any signature on behalf of the Company on the delivery note is not evidence that the correct number or type of Goods has been delivered or that the Goods supplied are in good condition or otherwise meet the requirements of the Agreement or the relevant Order. The Company shall not be deemed to have accepted the Goods or Services until it has had a reasonable time to inspect them following delivery and has not notified the Supplier of its rejection of the Goods or Services within that time. The Company shall also have the right to reject the Goods and/or or Services as though they had not been accepted for a reasonable time after any latent defect in the Goods or Services has become apparent. If the Company does not accept the Goods and/or or Services as conforming to the Agreement, the relevant Order or any Specification, it may exercise any of the remedies set out in Condition 1716.
8.6 No Goods supplied or Services performed under the Agreement earlier than the date for delivery set out in the Order, or in any delivery schedule, will be accepted or paid for unless the Company notifies the Supplier Seller in writing of its intention to accept the same.
8.7 The Supplier shall supply the Company on delivery of the Goods with full and clear operating, storage, handling and safety instructions, warning notices clearly displayed and other information as may be necessary for their proper use, maintenance and repair for the Company to accept delivery of the Goods.
8.8 Unless the Company expressly agrees otherwise in writing, containers and packing must be supplied free but will be returned to the Supplier, if required by written notice for each shipment from the Supplier to the Company, at the Supplier's risk and expense.
8.9 Where more than one item of Goods is involved in the Order and the Company agrees to accept delivery by instalments, the Agreement shall be construed as a separate contract in respect of each instalment. Nevertheless failure to deliver delivery any instalment shall entitle the Company at its option to treat the Agreement as repudiated.
8.10 If the Goods are delivered to the Company in excess of the quantities ordered the Company shall not be bound to pay for the excess and any excess will be and will remain at the Supplier's risk and will be returnable at the Supplier's expense. Container deliveries may vary individual product quantities by 15% subject to providing 10 day prior notice.
8.11 The Supplier shall, free of charge and within 30 days from the giving of notice as provided below, either repair or replace (as the Company shall elect) such of the Goods as may either be damaged in transit or having been placed in transit, fail to be delivered to the Company provided that:
8.11.1 in the case of damage to such Goods in transit, the Company shall within 30 days of delivery give notice in writing to the Supplier that the Goods have been damaged;
8.11.2 in the case of non-delivery, the Company shall (provided that the Company has been notified of dispatch within 10 21 days of the notified date of delivery) give notice to the Supplier that the Goods have not been delivered.
8.12 If the Goods require assembly and installation, the Supplier shall:
8.12.1 carry out such work in accordance with Condition 2.4 2.3 above;
8.12.2 comply with the Company's requirements relating to access to and use and security of, the Company's premises and shall keep the Company's premises clean and tidy at all time; and;
8.12.3 following any such assembly or installation, restore the Company’s premises on which it has been installing the Goods to the condition they were in before it commenced such installation.
Appears in 1 contract
Sources: Terms & Conditions of Purchase of Goods or Services
Delivery and Acceptance. 8.1 The Goods shall be delivered to and the Services shall be performed at the Company's place of business or if some other place of delivery is agreed by the Company in writing by delivery of the Goods or provision of the Services at that place during the Company's normal office hours. The Supplier shall off-load the Goods at its own risk as directed by the Company.
8.2 The Goods shall be delivered and/or the Services shall be performed on the date or within the period specified in the Order or if no such period is specified then within 28 days of the Order, unless the Company notifies the Supplier of a change in the required delivery date (giving the Supplier as much notice of the revised delivery date as practicable) in which case the Supplier shall deliver the Goods and/or perform the Services on or by the revised delivery date. Time for delivery of the Goods or performance of the Services shall be of the essence of the Agreement.
8.3 The Supplier shall ensure that each delivery of Goods is accompanied by a delivery note which is prominently displayed and which shows, inter alia, the order number, date of order, number of packages and contents and, in the case of part delivery, the outstanding balance remaining to be delivered. For the avoidance of doubt, the Supplier shall only be permitted to deliver in part where the Company has confirmed in writing or on the Order Form that it is willing to accept delivery in part.
8.4 If the Goods are not delivered or the Services are not performed on the due date then, without prejudice to any other rights which it may have, the Company reserves the right to:
8.4.1 terminate the Agreement in whole or in part without being liable to compensate the Supplier for any losses arising as a result of such cancellation or to make any payment to the Supplier other than in respect of Goods actually delivered or Services actually rendered to the Company prior to the date of such termination;
8.4.2 refuse to accept any subsequent delivery of the Goods or provision of the Services which the Supplier attempts to make;
8.4.3 recover from the Supplier any expenditure reasonably incurred by the Company in obtaining the Goods or Services in substitution from another supplier; and
8.4.4 claim damages for any reasonable additional costs, loss or expenses incurred by the Company which are in any way attributable to the Supplier's failure to deliver the Goods or provide the Services on the due date.
8.5 Any signature on behalf of the Company on the delivery note is not evidence that the correct number or type of Goods has been delivered or that the Goods supplied are in good condition or otherwise meet the requirements of the Agreement or the relevant Order. The Company shall not be deemed to have accepted the Goods or Services until it has had a reasonable time to inspect them following delivery and has not notified the Supplier of its rejection of the Goods or Services within that time. The Company shall also have the right to reject the Goods and/or Services as though they had not been accepted for a reasonable time after any latent defect in the Goods or Services has become apparent. If the Company does not accept the Goods and/or Services as conforming to the Agreement, the relevant Order or any Specification, it may exercise any of the remedies set out in Condition 17.
8.6 No Goods supplied or Services performed under the Agreement earlier than the date for delivery set out in the Order, or in any delivery schedule, will be accepted or paid for unless the Company notifies the Supplier in writing of its intention to accept the same.
8.7 The Supplier shall supply the Company on delivery of the Goods with full and clear operating, storage, handling and safety instructions, warning notices clearly displayed and other information as may be necessary for their proper use, maintenance and repair for the Company to accept delivery of the Goods.
8.8 Unless the Company expressly agrees otherwise in writing, containers and packing must be supplied free but will be returned return ed to the Supplier, if required by written notice from the Supplier to the Company, at the Supplier's risk and expense.
8.9 Where more than one item of Goods is involved in the Order and the Company agrees to accept delivery by instalments, the Agreement shall be construed as a separate contract in respect of each instalment. Nevertheless failure to deliver any instalment shall entitle the Company at its option to treat the Agreement as repudiated.
8.10 If the Goods are delivered to the Company in excess of the quantities ordered the Company shall not be bound to pay for the excess and any excess will be and will remain at the Supplier's risk and will be returnable at the Supplier's expense.
8.11 The Supplier shall, free of charge and within 30 days from the giving of notice as provided below, either repair or replace (as the Company shall elect) such of the Goods as may either be damaged in transit or having been placed in transit, fail to be delivered to the Company provided that:
8.11.1 in the case of damage to such Goods in transit, the Company shall within 30 days of delivery give notice in writing to the Supplier that the Goods have been damaged;
8.11.2 in the case of non-delivery, the Company shall (provided that the Company has been notified of dispatch within 10 days of the notified date of delivery) give notice to the Supplier that the Goods have not been delivered.
8.12 If the Goods require assembly and installation, the Supplier shall:
8.12.1 carry out such work in accordance with Condition 2.4 above;
8.12.2 comply with the Company's requirements relating to access to and use and security of, the Company's premises and shall keep the Company's premises clean and tidy at all time; and
8.12.3 following any such assembly or installation, restore the Company’s premises on which it has been installing the Goods to the condition they were in before it commenced such installation.
Appears in 1 contract
Sources: Terms & Conditions of Purchase of Goods or Services
Delivery and Acceptance. 8.1 4.1 Supplier shall carefully test and inspect the Goods prior to dispatch to ensure that they comply with the requirements of the Agreement and, if so requested by Company, give Company reasonable notice of such tests which Company shall be entitled to attend. Supplier shall provide Company with full details of all inspection and testing criteria, data and results traceable to international standards. At any time prior to delivery of the Goods to the Company the Company shall have the right to inspect and test the Goods (or engage a third party for carrying out the same) at all times at its cost, unless the Goods prove to be defective in which case the cost will be for Supplier’s account.
4.2 The Goods shall be delivered to and the Services shall be performed at Delivery Point on the Company's place of business or if some other place agreed date(s) of delivery is agreed by the Company set out in writing by delivery of the Goods or provision of the Services at that place during the Company's normal office hours. The Supplier shall off-load the Goods at its own risk as directed by the Company.
8.2 The Goods shall this Agreement, and where appropriate be delivered and/or the Services shall be performed on the date or within the period specified in the Order or if no such period is specified then within 28 days of the Order, unless the Company notifies the Supplier of a change in the required delivery date (giving the Supplier as much notice of the revised delivery date as practicable) in which case the Supplier shall deliver the Goods and/or perform the Services on or by the revised delivery dateaccompanied with all original certifications and test reports. Time for delivery of the Goods or performance of the Services shall be of the essence essence.
4.3 Supplier shall promptly notify Company of the Agreementdispatch of the Goods along with the full shipping details applicable to the Goods and their transportation and the anticipated date of arrival of the Goods at their destination.
8.3 The Supplier shall ensure that each delivery of Goods is accompanied by a delivery note which is prominently displayed 4.4 Property, risk and which shows, inter alia, the order number, date of order, number of packages and contents and, title in the case of part delivery, Goods shall pass to Company on delivery at the outstanding balance remaining to be delivered. For the avoidance of doubt, the Supplier shall only be permitted to deliver in part where the Company has confirmed in writing or on the Order Form that it is willing to accept delivery in part.
8.4 If the Goods are not delivered or the Services are not performed on the due date thenDelivery Point, without prejudice to any other rights right of rejection Company may be entitled to under this Agreement or otherwise.
4.5 Goods supplied which it may haveare contaminated beyond use at the time of delivery shall be regenerated or disposed of by the Supplier. Title and risk to such Goods will transfer to the Supplier at the time that contamination is identified and notified to the Supplier who will bear all expenses for the said processes. In the event that the Company contaminates the Goods, the Company reserves will be liable for the right to:processes of regeneration and disposal.
8.4.1 terminate 4.6 If the delivery date(s) cannot be met by the Supplier, the Supplier shall notify Company as soon as reasonably possible and Company shall be entitled to (a) charge the liquidated damages at Clause 5 below, and (b) if the maximum amount of liquidated damages is reached, cancel the Agreement in whole or in part without Company being liable to compensate the Supplier, and/or (c) acquire replacement Goods from another source, with the Supplier paying Company for any losses arising as a result of such cancellation additional, direct costs reasonably incurred by Company in doing so.
4.7 The costs for wrapping, packing, cartons, boxes, crating, containers or carriage is deemed to make any payment to be included in the Supplier other than in respect Agreement Price.
4.8 Partial delivery of Goods actually delivered or Services actually rendered to will not be accepted unless it is agreed between the Company prior to the date of such termination;Parties in writing.
8.4.2 refuse to accept any subsequent delivery of 4.9 Where the Goods or provision of the Services which the Supplier attempts to make;
8.4.3 recover from the Supplier any expenditure reasonably incurred by the Company in obtaining the Goods or Services in substitution from another supplier; and
8.4.4 claim damages for any reasonable additional costs, loss or expenses incurred by the Company which are in any way attributable to the Supplier's failure to deliver the Goods or provide the Services on the due date.
8.5 Any signature on behalf of the Company on the delivery note is part thereof do not evidence that the correct number or type of Goods has been delivered or that the Goods supplied are in good condition or otherwise meet comply with the requirements of the Agreement or the relevant Order. The Company shall not be deemed to have accepted the Goods or Services until it has had a reasonable at any time to inspect them following delivery and has not notified the Supplier of its rejection of the Goods or Services within that time. The Company shall also have the right to reject the Goods and/or Services as though they had not been accepted for a reasonable time after any latent defect in the Goods or Services has become apparent. If the Company does not accept the Goods and/or Services as conforming to the Agreement, the relevant Order or any Specification, it may exercise any of the remedies set out in Condition 17.
8.6 No Goods supplied or Services performed under during the Agreement earlier than the date for delivery set out in the Order, or in any delivery schedule, will be accepted or paid for unless the Company notifies the Supplier in writing of its intention to accept the same.
8.7 The Supplier shall supply the Company including on delivery of or during the Goods with full and clear operating, storage, handling and safety instructions, warning notices clearly displayed and other information as may be necessary for their proper use, maintenance and repair for the Company to accept delivery of the Goods.
8.8 Unless the Company expressly agrees otherwise in writing, containers and packing must be supplied free but will be returned to the Supplier, if required by written notice from the Supplier to the Company, at the Supplier's risk and expense.
8.9 Where more than one item of Goods is involved in the Order and the Company agrees to accept delivery by instalments, the Agreement shall be construed as a separate contract in respect of each instalment. Nevertheless failure to deliver any instalment shall entitle the Company at its option to treat the Agreement as repudiated.
8.10 If the Goods are delivered to the Company in excess of the quantities ordered the Company shall not be bound to pay for the excess and any excess will be and will remain at the Supplier's risk and will be returnable at the Supplier's expense.
8.11 The Supplier shall, free of charge and within 30 days from the giving of notice as provided below, either repair or replace (as the Company shall elect) such of the Goods as may either be damaged in transit or having been placed in transit, fail to be delivered to the Company provided that:
8.11.1 in the case of damage to such Goods in transitDefects Liability Period, the Company shall within 30 days of delivery give notice in writing to have the Supplier that the Goods have been damaged;
8.11.2 in the case of non-delivery, the Company shall (provided that the Company has been notified of dispatch within 10 days of the notified date of delivery) give notice to the Supplier that the Goods have not been delivered.
8.12 If the Goods require assembly and installation, the Supplier shallright to:
8.12.1 carry out such work in accordance with Condition 2.4 above;
8.12.2 comply with the Company's requirements relating to access to and use and security of, the Company's premises and shall keep the Company's premises clean and tidy at all time; and
8.12.3 following any such assembly or installation, restore the Company’s premises on which it has been installing the Goods to the condition they were in before it commenced such installation.
Appears in 1 contract
Sources: Terms and Conditions for Goods
Delivery and Acceptance. 8.1 The Goods shall be delivered to and the Services shall be performed at the Company's place of business or if some other place of delivery is a) Unless agreed otherwise by the Company us in writing or expressly stated in the quotation provided to you we will arrange for the Carrier to transport the Product.
b) Delivery dates for the supply of the Product are estimates only and time is not of the essence. We will not be liable for any loss (including loss of profit), costs, damages, charges or expenses caused directly or indirectly by any delay in the delivery of the Goods Product, nor will any delay entitle you to terminate or provision of rescind the Services at that place during the Company's normal office hours. The Supplier shall off-load the Goods at its own risk as directed by the CompanyContract.
8.2 The Goods shall be delivered and/or the Services shall be performed on the date or within the period specified in the Order or if no such period is specified then within 28 days of the Order, unless the Company notifies the Supplier of a change in the required delivery date (giving the Supplier as much notice of the revised delivery date as practicablec) in which case the Supplier shall deliver the Goods and/or perform the Services on or by the revised delivery date. Time If for any reason you do not take delivery of the Goods Product, or performance of we are unable to deliver the Services Product, your Property on the estimated delivery dates because you have not provided appropriate instructions, documents, licences, authorisations, etc., then such Product will be deemed to have been delivered and risk shall pass to you. We may at our option store such Product until actual delivery whereupon you will be of the essence of the Agreementliable for all related costs and expenses (including without limitation storage and insurance) and invoice you for all related costs and expenses incurred by us.
8.3 The Supplier d) You shall ensure that each delivery promptly notify the Carrier of Goods is accompanied any damage to, loss from or non-receipt of any Product and/or your Property if transportation has been arranged by a delivery note which is prominently displayed and which shows, inter alia, the order number, date of order, number of packages and contents and, in the case of part delivery, the outstanding balance remaining to be delivered. For the avoidance of doubt, the Supplier shall only be permitted to deliver in part where the Company has confirmed in writing or on the Order Form that it is willing to accept delivery in part.
8.4 If the Goods are your behalf. We shall not delivered or the Services are not performed on the due date then, without prejudice to any other rights which it may have, the Company reserves the right to:
8.4.1 terminate the Agreement in whole or in part without being be liable to compensate the Supplier for any losses arising as a result of such cancellation or to make any payment to the Supplier other than in respect of Goods actually delivered or Services actually rendered to the Company prior to the date of such termination;
8.4.2 refuse to accept any subsequent delivery of the Goods or provision of the Services which the Supplier attempts to make;
8.4.3 recover from the Supplier any expenditure reasonably incurred by the Company in obtaining the Goods or Services in substitution from another supplier; and
8.4.4 claim damages for any reasonable additional costsdamage, loss or expenses incurred by the Company which are in any way attributable to the Supplier's failure to deliver the Goods or provide the Services on the due datenon-receipt.
8.5 Any signature on behalf of the Company on the delivery note is not evidence that the correct number or type of Goods has been delivered or that the Goods supplied are in good condition or otherwise meet the requirements of the Agreement or the relevant Order. The Company shall not e) You will be deemed to have accepted the Goods or Services until it has had a reasonable time to inspect them following delivery Product as being in accordance with the Contract, we shall have no liability for any defect and/or failure and has not notified the Supplier of its rejection of the Goods or Services within that time. The Company you shall also have the right to reject the Goods and/or Services as though they had not been accepted for a reasonable time after any latent defect in the Goods or Services has become apparent. If the Company does not accept the Goods and/or Services as conforming to the Agreement, the relevant Order or any Specification, it may exercise any of the remedies set out in Condition 17.
8.6 No Goods supplied or Services performed under the Agreement earlier than the date for delivery set out in the Order, or in any delivery schedule, will be accepted or paid for unless the Company notifies the Supplier in writing of its intention to accept the same.
8.7 The Supplier shall supply the Company on delivery of the Goods with full and clear operating, storage, handling and safety instructions, warning notices clearly displayed and other information as may be necessary for their proper use, maintenance and repair for the Company to accept delivery of the Goods.
8.8 Unless the Company expressly agrees otherwise in writing, containers and packing must be supplied free but will be returned to the Supplier, if required by written notice from the Supplier to the Company, at the Supplier's risk and expense.
8.9 Where more than one item of Goods is involved in the Order and the Company agrees to accept delivery by instalments, the Agreement shall be construed as a separate contract in respect of each instalment. Nevertheless failure to deliver any instalment shall entitle the Company at its option to treat the Agreement as repudiated.
8.10 If the Goods are delivered to the Company in excess of the quantities ordered the Company shall not be bound to pay for the excess and any excess will be and will remain at the Supplier's risk and will be returnable at the Supplier's expense.
8.11 The Supplier shall, free of charge and price unless: (a) within 30 days from the giving of notice as provided below, either repair or replace fifteen (as the Company shall elect15) such of the Goods as may either be damaged in transit or having been placed in transit, fail to be delivered to the Company provided that:
8.11.1 in the case of damage to such Goods in transit, the Company shall within 30 days of delivery give notice in writing to the Supplier that the Goods have been damaged;
8.11.2 in the case of non-delivery, the Company shall (provided that the Company has been notified of dispatch within 10 days of the notified date of delivery of the Product, you notify us in writing of any defect apparent upon inspection of the Product to conform with the Contract; or (b) you notify us in writing of any failure of the Product to conform to the Contract within a reasonable time where the defect and/or failure would not be so apparent within fifteen (15) days of the date of delivery) give notice to the Supplier that the Goods have not been delivered.
8.12 If f) You shall be responsible for checking that all documentation supplied by us to you is accurate and free from error. We agree to remedy any inaccuracies/errors in such documentation provided that you have notified us of the Goods require assembly and installationinaccuracies/errors within thirty (30) days of receipt of the relevant document(s). Beyond such period, we reserve the Supplier shall:
8.12.1 carry out such work in accordance with Condition 2.4 above;
8.12.2 comply with the Company's requirements relating right to access to and use and security of, the Company's premises and shall keep the Company's premises clean and tidy at all time; and
8.12.3 following charge an administration fee for any such assembly or installation, restore the Company’s premises on which it has been installing the Goods to the condition they were in before it commenced such installationamendments made.
Appears in 1 contract
Sources: Website Terms and Conditions
Delivery and Acceptance. 8.1 The Goods shall be delivered 7.1 Subject to and the Services shall be performed at the Company's place of business without limitation or if some other place of delivery is agreed by the Company in writing by delivery of the Goods or provision of the Services at that place during the Company's normal office hours. The Supplier shall off-load the Goods at its own risk as directed by the Company.
8.2 The Goods shall be delivered and/or the Services shall be performed on the date or within the period specified in the Order or if no such period is specified then within 28 days of the Order, unless the Company notifies the Supplier of a change in the required delivery date (giving the Supplier as much notice of the revised delivery date as practicable) in which case the Supplier shall deliver the Goods and/or perform the Services on or by the revised delivery date. Time for delivery of the Goods or performance of the Services shall be of the essence of the Agreement.
8.3 The Supplier shall ensure that each delivery of Goods is accompanied by a delivery note which is prominently displayed and which shows, inter alia, the order number, date of order, number of packages and contents and, in the case of part delivery, the outstanding balance remaining to be delivered. For the avoidance of doubt, the Supplier shall only be permitted to deliver in part where the Company has confirmed in writing or on the Order Form that it is willing to accept delivery in part.
8.4 If the Goods are not delivered or the Services are not performed on the due date then, without prejudice to any other rights which it may haveParagraph 8.2, the Company reserves the right to:
8.4.1 terminate the Agreement in whole or in part without being liable to compensate the Supplier for any losses arising as a result of such cancellation or to make any payment to the Supplier other than in respect of Goods actually delivered or Services actually rendered to the Company prior to the date of such termination;
8.4.2 refuse to accept any subsequent delivery of the Goods or provision of the Services which the Supplier attempts to make;
8.4.3 recover from the Supplier any expenditure reasonably incurred by the Company in obtaining the Goods or Services in substitution from another supplier; and
8.4.4 claim damages for any reasonable additional costs, loss or expenses incurred by the Company which are in any way attributable to the Supplier's failure to deliver the Goods or provide the Services on the due date.
8.5 Any signature on behalf of the Company on the delivery note is not evidence that the correct number or type of Goods has been delivered or that the Goods supplied are in good condition or otherwise meet the requirements of the Agreement or the relevant Order. The Company Astley shall not be deemed to have accepted the Goods or any Services until it ▇▇▇▇▇▇ has had confirmed both the receipt and acceptance of such Services from the Subcontractor. Such confirmation being either a reasonable time to inspect them following delivery signed Acceptance Note completed by the relevant authorised representative of Astley or any other specific ‘Sign–off’ Procedure applicable and has not notified the Supplier of its rejection required by ▇▇▇▇▇▇ at that time, including providing Astley with a written or electronic record of the Goods same.
7.2 If any Services delivered to Astley do not comply with Paragraph 6.1, or any other terms of this Agreement, then, without limiting any other right or remedy that Astley may have, ▇▇▇▇▇▇ may reject those Services and:
(a) require the Subcontractor to rectify or carry out again the rejected Services at the Subcontractor's risk and expense within that time. The Company shall also have five (5) business days of being requested to do so or within such shorter time as Astley may specify; or
(b) require the right Subcontractor to reject the Goods and/or Services as though they had not been accepted for a reasonable time after any latent defect compensate Astley in the Goods or Services has become apparent. If the Company does not accept the Goods and/or Services as conforming an amount equal to the price paid or payable regarding the rejected Services; and
(c) claim consequential and any other damages for any other costs, expenses or losses resulting from the Subcontractor's delivery of Services which are not in conformity with the terms of this Agreement, the relevant Order or any Specification, it may exercise any of the remedies set out in Condition 17.
8.6 No Goods supplied or 7.3 The Subcontractor shall deliver the Services performed under in accordance with the terms of this Agreement earlier than and to the date for delivery address set out in the OrderPurchase Order or specific Works instruction, unless otherwise advised in writing by an authorised representative of Astley. Time shall be of the essence for delivery of all Services and for the performance by the Subcontractor of its other obligations under this Agreement. If the Services are not delivered in accordance with the details set out in the Purchase Order or specific Works Instruction then, without limiting any other right or remedy Astley may have under this Agreement in law or in equity, Astley may at their option:
(a) in relation to the required Services, refuse to take any subsequent attempted delivery schedule, will be accepted or paid for unless of such Services; and
(b) obtain substitute Services as applicable from another subcontractor and recover from the Company notifies the Supplier Subcontractor any costs and expenses reasonably incurred by ▇▇▇▇▇▇ in writing of its intention to accept the sameobtaining such substitute Services.
8.7 7.4 The Supplier shall supply the Company on delivery rights and remedies of the Goods parties in connection with full and clear operatingthis Agreement are cumulative and, storageexcept as expressly stated in this Agreement, handling and safety instructionsare not exclusive of any other rights or remedies provided by this Agreement, warning notices clearly displayed and other information law, equity or otherwise. Except as may be necessary for their proper use, maintenance and repair for the Company to accept delivery of the Goods.
8.8 Unless the Company expressly agrees otherwise stated in writing, containers and packing must be supplied free but will be returned to the Supplier, if required by written notice from the Supplier to the Company, at the Supplier's risk and expense.
8.9 Where more than one item of Goods is involved this Agreement (or in the Order and the Company agrees to accept delivery by instalments, the Agreement shall be construed as a separate contract law or in respect of each instalment. Nevertheless failure to deliver any instalment shall entitle the Company at its option to treat the Agreement as repudiated.
8.10 If the Goods are delivered to the Company in excess of the quantities ordered the Company shall not be bound to pay for the excess and any excess will be and will remain at the Supplier's risk and will be returnable at the Supplier's expense.
8.11 The Supplier shall, free of charge and within 30 days from the giving of notice as provided below, either repair or replace (as the Company shall elect) such of the Goods as may either be damaged in transit or having been placed in transit, fail to be delivered to the Company provided that:
8.11.1 equity in the case of damage rights and remedies provided by law or equity) any right or remedy may be exercised wholly or partially from time to such Goods in transit, the Company shall within 30 days of delivery give notice in writing to the Supplier that the Goods have been damaged;
8.11.2 in the case of non-delivery, the Company shall (provided that the Company has been notified of dispatch within 10 days of the notified date of delivery) give notice to the Supplier that the Goods have not been deliveredtime.
8.12 If the Goods require assembly and installation, the Supplier shall:
8.12.1 carry out such work in accordance with Condition 2.4 above;
8.12.2 comply with the Company's requirements relating to access to and use and security of, the Company's premises and shall keep the Company's premises clean and tidy at all time; and
8.12.3 following any such assembly or installation, restore the Company’s premises on which it has been installing the Goods to the condition they were in before it commenced such installation.
Appears in 1 contract
Sources: Procurement Agreement
Delivery and Acceptance. 8.1 The 7.1 Delivery of the Goods shall be delivered made to and the Services Custom- er’s address within the UK or such other address within the UK as the Customer shall be performed at the Company's place of business or if some other place of delivery is agreed by notify to the Company in writing by (Delivery Location) and the Customer shall make all arrangements necessary to take delivery of the Goods or provision of the Services at that place during the Company's normal office hours. The Supplier shall off-load the Goods at its own risk as directed by the Companywhenever they are tendered for delivery.
8.2 The Goods shall be delivered and/or 7.2 If the Services shall be performed on the date or within the period specified in the Order or if no such period is specified then within 28 days of the Order, unless the Company notifies the Supplier of a change in the required delivery date (giving the Supplier as much notice of the revised delivery date as practicable) in which case the Supplier shall deliver the Goods and/or perform the Services on or by the revised delivery date. Time for Customer does not take delivery of the Goods it shall meet all Frama’s expenses incurred as a result of Frama’s inability to affect delivery including any cost of redelivery or performance storage of the Services shall be Goods.
7.3 Delivery is completed on the completion of unloading the Goods at the Delivery Location.
7.4 Any dates quoted for delivery are approximate only, and the time of delivery is not of the essence essence. Frama shall not be liable for any delay in delivery of the AgreementGoods that is caused by any event under clause 16 below or the Customer’s failure to provide Frama with adequate delivery instructions or any other instructions that are relevant to the supply of the Goods.
8.3 7.5 The Supplier shall ensure that each delivery of Goods is accompanied by a delivery note which is prominently displayed and which shows, inter alia, the order number, date of order, number of packages and contents and, in the case of part delivery, the outstanding balance remaining to be delivered. For the avoidance of doubt, the Supplier shall only be permitted to deliver in part where the Company has confirmed in writing or on the Order Form that it is willing to accept delivery in part.
8.4 If the Goods are not delivered or the Services are not performed on the due date then, without prejudice to any other rights which it may have, the Company reserves the right to:
8.4.1 terminate the Agreement to deliver Goods in whole or in part without being liable instal- ments and to compensate the Supplier for any losses arising as deliver a result of such cancellation or to make any payment to the Supplier other than separate invoice in respect of each instalment. Where Goods actually are delivered in instalments, the contract shall be severable and each instalment shall be deemed to constitute a separate contract. No default by Frama in respect of one or Services actually rendered more instalments shall entitle the Customer to treat the Company prior to the date of such termination;contract as repudiated or discharged.
8.4.2 refuse to accept any subsequent delivery of the Goods or provision of the Services which the Supplier attempts to make;
8.4.3 recover from the Supplier any expenditure reasonably incurred 7.6 Insofar as is permitted by the Company in obtaining the Goods or Services in substitution from another supplier; and
8.4.4 claim damages for any reasonable additional costslaw, loss or expenses incurred by the Company which are Frama shall not be liable in any way attributable for any loss or damage whatsoever due to the Supplier's failure by Frama to deliver the Goods (or provide the Services on the due dateany of them) promptly or at all.
8.5 Any signature on behalf of the Company on the delivery note is not evidence that the correct number or type of Goods has been delivered or that the Goods supplied are in good condition or otherwise meet the requirements of the Agreement or the relevant Order. 7.7 The Company Customer shall not be deemed to have accepted the Machine and any Goods or Services until it has had a reasonable time two days after delivery to inspect them following delivery and has the Delivery Location (“Acceptance”). After Acceptance, the Customer shall not notified the Supplier of its rejection of the Goods or Services within that time. The Company shall also have the right be entitled to reject the Goods and/or Services as though they had not been accepted for a reasonable time after any latent defect in the Goods or Services has become apparent. If the Company does not accept the Goods and/or Services as conforming to the Agreement, the relevant Order or any Specification, it may exercise any of the remedies set out in Condition 17.
8.6 No Goods supplied or Services performed under the Agreement earlier than the date for delivery set out in the Order, or in any delivery schedule, will be accepted or paid for unless the Company notifies the Supplier in writing of its intention to accept the same.
8.7 The Supplier shall supply the Company on delivery of the Goods with full and clear operating, storage, handling and safety instructions, warning notices clearly displayed and other information as may be necessary for their proper use, maintenance and repair for the Company to accept delivery of the Goods.
8.8 Unless 7.8 In the Company expressly event the Customer rejects any of the Goods which are not in accordance with Condition 7.7 above, the Customer shall give notice of rejection to Frama at the Customer’s cost and return any such Machine or Goods to Frama.
7.9 No Goods delivered to the Customer which are in accord- ance with clause 7.1 above will be accepted for return without the prior written consent of Frama and at Frama’s sole discretion.
7.10 If ▇▇▇▇▇ agrees otherwise in writing, containers and packing to accept any such Goods for return The Customer shall be liable to pay a handling charge of 20% of the Price. Such Goods must be supplied free but will returned by the Customer in its original packaging and at the cost and risk of the Customer.
7.11 Goods returned without the prior written approval from Frama may at Frama’s absolute discretion be returned to the Supplier, if required by written notice from the Supplier to the Company, Customer at the Supplier's risk and expenseCustomer’s cost or further stored at the Customer’s cost without prejudice to any rights or remedies the Company may have.
8.9 Where more than one item of 7.12 In the event the Customer does not reclaim or recover such Goods is involved in the Order and the Company agrees to accept delivery by instalments, the Agreement shall be construed as a separate contract in respect of each instalment. Nevertheless failure to deliver any instalment shall entitle the Company at its option to treat the Agreement as repudiated.
8.10 If the Goods are delivered to the Company in excess of the quantities ordered the Company shall not be bound to pay for the excess and any excess will be and will remain at the Supplier's risk and will be returnable at the Supplier's expense.
8.11 The Supplier shall, free of charge and within 30 days from the giving of notice as provided below, either repair or replace (as the Company shall elect) such of Frama may appropriate the Goods as may either be damaged in transit or having been placed in transit, fail to be delivered to the Company provided that:
8.11.1 in the case of damage to such Goods in transit, the Company shall within 30 days of delivery give notice in writing to the Supplier that the Goods have been damaged;
8.11.2 in the case of non-delivery, the Company shall (provided that the Company has been notified of dispatch within 10 days of the notified date of delivery) give notice to the Supplier that the Goods have not been deliveredfor resale.
8.12 If the Goods require assembly and installation, the Supplier shall:
8.12.1 carry out such work in accordance with Condition 2.4 above;
8.12.2 comply with the Company's requirements relating to access to and use and security of, the Company's premises and shall keep the Company's premises clean and tidy at all time; and
8.12.3 following any such assembly or installation, restore the Company’s premises on which it has been installing the Goods to the condition they were in before it commenced such installation.
Appears in 1 contract
Sources: Terms of Business
Delivery and Acceptance. 8.1 The Goods (a) Every endeavour will be made to effect delivery within the date specified but dates and periods for delivery are only estimates and as such do not form an essential part of the Contract. In no circumstances whatsoever shall the Buyer be entitled to recover loss of profits from sub-sales or any special or consequential loss or damage whatsoever arising from or in connection with delay in delivery or non- delivery.
(b) Delivery shall be delivered to and the Services shall be performed at the Company's place of business Seller’s premises unless otherwise stipulated or if some other place of delivery is agreed by the Company Seller.
(c) Any subsequent request for amendment to design, quantity or specification or any suspension of work resulting from the Buyer's instruction, or lack of instruction is subject to acceptance by the Seller in writing by delivery and may result in a revision of the Goods or provision of the Services at that place during the Company's normal office hours. The Supplier shall off-load the Goods at its own risk as directed by the Companypreviously estimated delivery date.
8.2 The Goods (d) Where the Contract provides for the supply for goods by regular deliveries over a period, or by more than one single delivery, each such delivery shall be delivered and/or the Services shall be performed on the date or within the period specified in the Order or if no such period is specified then within 28 days of the Order, unless the Company notifies the Supplier of a change in the required delivery date (giving the Supplier as much notice of the revised delivery date as practicable) in which case the Supplier shall deliver the Goods and/or perform the Services on or by the revised delivery date. Time for delivery of the Goods or performance of the Services shall be of the essence of the Agreement.
8.3 The Supplier shall ensure that each delivery of Goods is accompanied by a delivery note which is prominently displayed and which shows, inter alia, the order number, date of order, number of packages and contents and, in the case of part delivery, the outstanding balance remaining considered to be delivered. For the avoidance of doubt, the Supplier shall only be permitted to deliver in part where the Company has confirmed in writing or on the Order Form that it is willing to accept delivery in part.
8.4 If the Goods are not delivered or the Services are not performed on the due date then, without prejudice to any other rights which it may have, the Company reserves the right to:
8.4.1 terminate the Agreement in whole or in part without being liable to compensate the Supplier for any losses arising as a result of such cancellation or separate contract and failure to make any payment delivery shall not terminate the contract as to the Supplier other than in respect of Goods actually delivered or Services actually rendered to the Company prior to the date of such termination;
8.4.2 refuse to accept any subsequent delivery of the Goods or provision of the Services which the Supplier attempts to make;
8.4.3 recover from the Supplier any expenditure reasonably incurred by the Company in obtaining the Goods or Services in substitution from another supplier; and
8.4.4 claim damages for any reasonable additional costs, loss or expenses incurred by the Company which are in any way attributable to the Supplier's failure to deliver the Goods or provide the Services on the due date.
8.5 Any signature on behalf of the Company on the delivery note is not evidence that the correct number or type of Goods has been delivered or that the Goods supplied are in good condition or otherwise meet the requirements of the Agreement or the relevant Orderdeliveries thereunder. The Company shall not be deemed to have accepted the Goods or Services until it has had a reasonable time to inspect them following delivery and has not notified the Supplier of its rejection of the Goods or Services within that time. The Company shall also have the right to reject the Goods and/or Services as though they had not been accepted for a reasonable time after any latent defect in the Goods or Services has become apparent. If the Company does not accept the Goods and/or Services as conforming to the Agreement, the relevant Order or any Specification, it may exercise any of the remedies set out in Condition 17.
8.6 No Goods supplied or Services performed under the Agreement earlier than the date for delivery set out in the Order, or in any delivery schedule, will be accepted or paid for unless the Company notifies the Supplier in writing of its intention to accept the same.
8.7 The Supplier shall supply the Company on delivery of the Goods with full and clear operating, storage, handling and safety instructions, warning notices clearly displayed and other information as may be necessary for their proper use, maintenance and repair for the Company to accept delivery of the Goods.
8.8 Unless the Company expressly agrees otherwise in writing, containers and packing must be supplied free but will be returned to the Supplier, if required by written notice from the Supplier to the Company, at the Supplier's risk and expense.
8.9 Where more than one item of Goods is involved in the Order and the Company agrees to accept delivery by instalments, the Agreement shall be construed as a separate contract in respect of each instalment. Nevertheless failure to deliver any instalment shall entitle the Company at its option to treat the Agreement as repudiated.
8.10 If the Goods are delivered to the Company in excess of the quantities ordered the Company Seller shall not be bound to pay deliver in any month more than the quantity specified, or if no monthly quantity is specified more than the pro rata amount of the total Contract quantity.
(e) If the Buyer fails to take a delivery or collect at the time specified in the contract or notified by the Seller, or the buyer has not provided appropriate instructions, documents, licenses or authorisations the goods shall be deemed delivered and the Seller (without prejudice to its other rights) shall be entitled to invoice the value thereof to the Buyer for settlement in accordance with Condition 4 hereof.
(f) The Seller may store the goods until delivery, whereupon the Buyer shall be liable for all related costs and expenses including storage and insurance.
(f) Where the Buyer has given no specific delivery instructions, the Seller shall not be bound to deliver until such instructions have been received, and if at the expiry of seven days after advising the Buyer that the goods are ready for delivery such instructions have not been received, the Seller shall be entitled to invoice the goods as at that date, and if the Buyer has not issued delivery instructions within one calendar month of the date of such invoice the Seller shall be entitled to charge the Buyer for the excess and any excess will be and will remain at the Supplier's risk and will be returnable at the Supplier's expensestorage of such goods.
8.11 The Supplier shall(g) Goods delivered shall be examined carefully by the Buyer and, free of charge if damaged or short-delivered, the Seller must be notified in writing within 3 days, and within 30 days from in default no claim may be made by the giving of notice as provided belowBuyer for damage or short-delivery.
(h) When the Seller undertakes delivery to the Buyer's address, either repair or replace (as the Company shall elect) such no claim for non-delivery of the Goods as may either goods shall be damaged in transit or having been placed in transit, fail to be delivered to made against the Company provided that:
8.11.1 in the case of damage to such Goods in transit, the Company shall within 30 days of delivery give Seller unless notice in writing to the Supplier that the Goods have been damaged;
8.11.2 in the case of non-delivery, delivery is given to the Company shall (provided that the Company has been notified of dispatch Seller within 10 days of the notified date of delivery) give notice invoice or of the advice of despatch, whichever is the earlier, and any claim on consequence of such non-delivery must be made to the Supplier Seller within 21 days of the date of invoice or of the date of advice of despatch (whichever is the earlier).
(i) The [Importer/Buyer] shall not sell, export or re-export, directly or indirectly, to the Russian Federation or for use in the Russian Federation any goods supplied under or in connection with this Agreement that fall under the scope of The Russia (Sanctions) (EU Exit) Regulations 2019 (“Sanctioned Goods”).
(j) The [Importer/Buyer] shall undertake its best efforts to ensure that the purpose of clause (1) is not frustrated by any third parties further down the commercial chain, including by possible resellers.
(k) The [Importer/Buyer] shall set up and maintain an adequate monitoring mechanism to detect conduct by any third parties further down the commercial chain, including by possible resellers, that would frustrate the purpose of clause (1).
(l) Any breach of clauses (1), (2) or (3) shall constitute a material breach of this Agreement, and the [Exporter/Seller] shall be entitled to seek appropriate remedies, including, but not limited to termination of this Agreement.
(m) The [Importer/Buyer] shall immediately inform the [Exporter/Seller] about any problems in applying clauses (1), (2) or (3), including any relevant activities by third parties that could frustrate the purpose of clause (1). The [Importer/Buyer] shall make available to the [Exporter/Seller] information concerning compliance with the obligations under clause (1), (2) and (3) within two weeks of the simple request of such information.
(n) Where the Exporter/Seller has reason to believe that any Sanctioned Goods have not been deliveredsold, exported or re-exported directly into the Russian Federation the Exporter/Seller shall be at liberty to notify the [relevant UK Authorities] irrespective of any confidentiality agreement between the parties.
8.12 If the Goods require assembly and installation, the Supplier shall:
8.12.1 carry out such work in accordance with Condition 2.4 above;
8.12.2 comply with the Company's requirements relating to access to and use and security of, the Company's premises and shall keep the Company's premises clean and tidy at all time; and
8.12.3 following any such assembly or installation, restore the Company’s premises on which it has been installing the Goods to the condition they were in before it commenced such installation.
Appears in 1 contract
Sources: Terms and Conditions for Supply of Goods or Services
Delivery and Acceptance. 8.1 The Goods shall be delivered to and the Services shall be performed at the Company's place of business or if some other place of delivery is agreed by the Company in writing by delivery of the Goods or provision of the Services at that place during the Company's normal office hours. The Supplier shall off-load the Goods at its own risk as directed by the Company.
8.2 The Goods shall be delivered and/or the Services shall be performed on the date or within the period specified in the Order or if no such period is specified then within 28 days of the Order, unless the Company notifies the Supplier of a change in the required delivery date (giving the Supplier as much notice of the revised delivery date as practicable) in which case the Supplier shall deliver the Goods and/or perform the Services on or by the revised delivery date. Time for delivery of the Goods or performance of the Services shall be of the essence of the Agreement.
8.3 The Supplier shall ensure that each delivery of Goods is accompanied by a delivery note which is prominently displayed and which shows, inter alia, the order number, date of order, number of packages and contents and, in the case of part delivery, the outstanding balance remaining to be delivered. For the avoidance of doubt, the Supplier shall only be permitted to deliver in part where the Company has confirmed in writing or on the Order Form that it is willing to accept delivery in part.
8.4 If the Goods are not delivered or the Services are not performed on the due date then, without prejudice to any other rights which it may have, the Company reserves the right to:
8.4.1 terminate the Agreement in whole or in part without being liable to compensate the Supplier for any losses arising as a result of such cancellation or to make any payment to the Supplier other than in respect of Goods actually delivered or Services actually rendered to the Company prior to the date of such termination;
8.4.2 refuse to accept any subsequent delivery of the Goods or provision of the Services which the Supplier attempts to make;
8.4.3 recover from the Supplier any expenditure reasonably incurred by the Company in obtaining the Goods or Services in substitution from another supplier; and
8.4.4 claim damages for any reasonable additional costs, loss or expenses incurred by the Company which are in any way attributable to the Supplier's failure to deliver the Goods or provide the Services on the due date.
8.5 Any signature on behalf of the Company on the delivery note is not evidence that the correct number or type of Goods has been delivered or that the Goods supplied are in good condition or otherwise meet the requirements of the Agreement or the relevant Order. The Company shall not be deemed to have accepted the Goods or Services until it has had a reasonable time to inspect them following delivery and has not notified the Supplier of its rejection of the Goods or Services within that time. The Company shall also have the right to reject the Goods and/or Services as though they had not been accepted for a reasonable time after any latent defect in the Goods or Services has become apparent. If the Company does not accept the Goods and/or Services as conforming to the Agreement, the relevant Order or any Specification, it may exercise any of the remedies set out in Condition 17.
8.6 No Goods supplied or Services performed under the Agreement earlier than the date for delivery set out in the Order, or in any delivery schedule, will be accepted or paid for unless the Company notifies the Supplier in writing of its intention to accept the same.
8.7 The Supplier shall supply the Company on delivery of the Goods with full and clear operating, storage, handling and safety instructions, warning notices clearly displayed and other information as may be necessary for their proper use, maintenance and repair for the Company to accept delivery of the Goods.
8.8 Unless the Company expressly agrees otherwise in writing, containers and packing must be supplied free but will be returned to the Supplier, if required by written notice from the Supplier to the Company, at the Supplier's risk and expense.
8.9 Where more than one item of Goods is involved in the Order and the Company agrees to accept delivery by instalments, the Agreement shall be construed as a separate contract in respect of each instalment. Nevertheless failure to deliver any instalment shall entitle the Company at its option to treat the Agreement as repudiated.
8.10 If the Goods are delivered to the Company in excess of the quantities ordered the Company shall not be bound to pay for the excess and any excess will be and will remain at the Supplier's risk and will be returnable at the Supplier's expense.
8.11 The Supplier shall, free of charge and within 30 days from the giving of notice as provided below, either repair or replace (as the Company shall elect) such of the Goods as may either be damaged in transit or having been placed in transit, fail to be delivered to the Company provided that:
8.11.1 in the case of damage to such Goods in transit, the Company shall within 30 days of delivery give notice in writing to the Supplier that the Goods have been damaged;
8.11.2 in the case of non-delivery, the Company shall (provided that the Company has been notified of dispatch within 10 days of the notified date of delivery) give notice to the Supplier that the Goods have not been delivered.
8.12 If the Goods require assembly and installation, the Supplier shall:
8.12.1 carry out such work in accordance with Condition 2.4 above;
8.12.2 8.5.1 comply with the Company's requirements relating to access to and use and security of, the Company's premises and shall keep the Company's premises clean and tidy at all time; and
8.12.3 8.5.2 following any such assembly or installation, restore the Company’s premises on which it has been installing the Goods to the condition they were in before it commenced such installation.
Appears in 1 contract
Sources: Terms & Conditions of Purchase of Goods or Services
Delivery and Acceptance. 8.1 5.1 The Goods shall be delivered to and the Services shall be performed at the Company's place of business or if some other place of delivery is agreed by the Company in writing by delivery of the Goods or provision performance of the Services shall take place at that place during the Company's normal office hours. The Supplier shall off-load the Goods at its own risk as directed address by the Company.
8.2 The Goods shall be delivered and/or the Services shall be performed on the date or within the period specified stated in the Order PO or if no such period is specified then within 28 days subsequent written notice, in either case during the Company’s usual business hours.
5.2 The time of the Order, unless the Company notifies the Supplier of a change in the required delivery date (giving the Supplier as much notice of the revised delivery date as practicable) in which case the Supplier shall deliver the Goods and/or perform the Services on or by the revised delivery date. Time for delivery of the Goods or and of performance of the Services shall be is of the essence of this Agreement. The stipulated time for delivery/performance shall be strictly adhered to. Without prejudice to the Agreement.
8.3 The Supplier shall ensure that each delivery of Goods is accompanied by a delivery note which is prominently displayed and which shows, inter alia, the order number, date of order, number of packages and contents and, in the case of part delivery, the outstanding balance remaining Supplier’s obligation to be delivered. For the avoidance of doubtdeliver/perform on time, the Supplier shall only be permitted to deliver in part where give the Company has confirmed notice in writing or on the Order Form that it immediately if any delay is willing to accept delivery in partforeseen.
8.4 5.3 If the Goods are not delivered to be delivered, or the Services are to be performed by installments, this Agreement will be treated as a single contract and not performed on severable.
5.4 The Supplier shall bear all taxes, duties, and charges including packaging, transportation and insurance, and all costs and expenses involved in the due date thenimportation of the Goods. The Supplier shall arrange and bear the responsibility for and the cost of prompt unloading, without prejudice stacking, packing, crating and storing of the Goods.
5.5 The Goods shall be marked in accordance with the Company’s instructions and any applicable regulations or requirements of the carrier, and properly packed and secured so as to any other rights which it may have, the reach their destination in an undamaged condition.
5.6 The Company reserves shall have the right to:
8.4.1 terminate to reject any Goods and/or Services which are not in accordance with this Agreement, in which event the Agreement in whole or in part without being liable to compensate liabilities under Clause 8 shall apply. Any return of the Supplier for any losses arising as a result of such cancellation or to make any payment Goods and/or Services to the Supplier other than in respect of Goods actually delivered or Services actually rendered to the Company prior to the date of such termination;
8.4.2 refuse to accept any subsequent delivery of the Goods or provision of the Services which shall be arranged by the Supplier attempts to make;
8.4.3 recover from and at the Supplier any expenditure reasonably incurred by the Company in obtaining the Goods or Services in substitution from another supplier; and
8.4.4 claim damages for any reasonable additional costs, loss or expenses incurred by the Company which are in any way attributable to the S Supplier's failure to deliver the Goods or provide the Services on the due date’s expense.
8.5 Any signature on behalf of the Company on the delivery note is not evidence that the correct number or type of Goods has been delivered or that the Goods supplied are in good condition or otherwise meet the requirements of the Agreement or the relevant Order. 5.7 The Company shall not be deemed to have accepted the Goods or and/or Services until it the Company has had a reasonable time to inspect them following delivery and has not notified the Supplier of its rejection of the Goods or Services or, if later, within that time. The Company shall also have the right to reject the Goods and/or Services as though they had not been accepted for a reasonable time after any latent defect in the Goods or Services has become apparent. If the Company does not accept the Goods and/or Services as conforming to the Agreement, the relevant Order or any Specification, it may exercise any of the remedies set out in Condition 17.
8.6 No Goods supplied or Services performed under the Agreement earlier than the date for delivery set out in the Order, or in any delivery schedule, will be accepted or paid for unless the Company notifies the Supplier in writing of its intention to accept the same.
8.7 5.8 The Supplier shall supply the Company on delivery of the Goods with full and clear operating, storage, handling and safety instructions, warning notices clearly displayed and other information as may be necessary for their proper use, maintenance and repair for the Company to accept delivery of the Goods.
8.8 Unless the Company expressly agrees otherwise in writing, containers and packing must be supplied free but will be returned to the Supplier, if required by written notice from the Supplier to the Company, at the Supplier's risk and expense.
8.9 Where more than one item of Goods is involved in the Order and the Company agrees to accept delivery by instalments, the Agreement shall be construed as a separate contract in respect of each instalment. Nevertheless failure to deliver any instalment shall entitle the Company at its option to treat the Agreement as repudiated.
8.10 If the Goods are delivered to the Company in excess of the quantities ordered the Company shall not be bound obliged to pay for the excess and any excess will be and will remain at the Supplier's risk and will be returnable at the Supplier's expense.
8.11 The Supplier shall, free of charge and within 30 days from the giving of notice as provided below, either repair or replace (as the Company shall elect) such of the Goods as may either be damaged in transit or having been placed in transit, fail to be delivered to the Company provided that:
8.11.1 in the case of damage to such Goods in transit, the Company shall within 30 days of delivery give notice in writing return to the Supplier that any packaging or packing material for the Goods, whether or not any Goods have been damaged;
8.11.2 in the case of non-delivery, the Company shall (provided that the Company has been notified of dispatch within 10 days of the notified date of delivery) give notice to the Supplier that the Goods have not been delivered.
8.12 If the Goods require assembly and installation, the Supplier shall:
8.12.1 carry out such work in accordance with Condition 2.4 above;
8.12.2 comply with are accepted by the Company's requirements relating to access to and use and security of, the Company's premises and shall keep the Company's premises clean and tidy at all time; and
8.12.3 following any such assembly or installation, restore the Company’s premises on which it has been installing the Goods to the condition they were in before it commenced such installation.
Appears in 1 contract
Sources: Purchasing Terms and Conditions
Delivery and Acceptance. 8.1 a. The Goods Vessel shall be delivered by Builder to Owner, afloat and in the Services water, at Gary, Indiana. Upon arrival at Gary, the Vessel shall be performed at the Company's place of business or inspected by Builder and Owner to determine if some other place of delivery is agreed by the Company in writing by delivery of the Goods or provision of the Services at that place during the Company's normal office hours. The Supplier shall off-load the Goods at its own risk as directed by the Company.
8.2 The Goods shall be delivered and/or the Services shall be performed on the date or within the period specified there are any defects in the Order or if no such period is specified then within 28 days of the Order, unless the Company notifies the Supplier of a change in the required delivery date (giving the Supplier as much notice of the revised delivery date as practicable) in which case the Supplier shall deliver the Goods and/or perform the Services on or by the revised delivery date. Time for delivery of the Goods or performance of the Services shall be of the essence of the Agreement.
8.3 The Supplier shall ensure that each delivery of Goods is accompanied by a delivery note which is prominently displayed and which shows, inter alia, the order number, date of order, number of packages and contents and, in the case of part delivery, the outstanding balance remaining to be delivered. For the avoidance of doubt, the Supplier shall only be permitted to deliver in part where the Company has confirmed in writing or on the Order Form that it is willing to accept delivery in part.
8.4 If the Goods are not delivered or the Services are not performed on the due date then, without prejudice to any other rights which it may have, the Company reserves the right to:
8.4.1 terminate the Agreement in whole or in part without being liable to compensate the Supplier for any losses arising Vessel as a result of such cancellation or to make any payment to the Supplier other than in respect of Goods actually delivered or Services actually rendered to delivery voyage from the Company prior to the date Builder's shipyard. Within five (5) days of such termination;inspection Owner shall notify Builder in writing of any defects caused by the delivery voyage, setting forth the nature and character of the defect in sufficient detail to fully apprise Builder of same. Builder shall proceed to resolve the defect as soon as practicable and, in any event, within five (5) business days unless prevented therefrom by a "Force Majeure" event. If there is any dispute regarding a complaint that cannot be resolved and settled by the parties, then such complaint or dispute shall be settled by arbitration in the manner provided for in Article 30 below.
8.4.2 refuse b. When the defects, if any, are resolved, Builder will give Owner written notification that the Vessel is delivered and ready for acceptance by Owner. Owner shall have five (5) days after receipt of the written notice of delivery within which to accept any subsequent delivery of or reject said Vessel in accordance with the Goods or provision of the Services which the Supplier attempts to make;
8.4.3 recover from the Supplier any expenditure reasonably incurred by the Company in obtaining the Goods or Services in substitution from another supplier; and
8.4.4 claim damages for any reasonable additional costs, loss or expenses incurred by the Company which are in any way attributable to the Supplier's failure to deliver the Goods or provide the Services provisions hereof. Failure on the due date.
8.5 Any signature on behalf part of the Company on the delivery note is not evidence that the correct number or type of Goods has been delivered or that the Goods supplied are in good condition or otherwise meet the requirements of the Agreement or the relevant Order. The Company shall not be deemed Owner to have accepted the Goods or Services until it has had a reasonable time to inspect them following delivery and has not notified the Supplier provide Builder with written notice of its rejection of the Goods or Services Vessel within that time. The Company shall also have the right to reject the Goods and/or Services as though they had not been accepted for a reasonable time five (5) days after any latent defect in the Goods or Services has become apparent. If the Company does not accept the Goods and/or Services as conforming to the Agreement, the relevant Order or any Specification, it may exercise any receipt of the remedies set out in Condition 17.
8.6 No Goods supplied or Services performed under the Agreement earlier than the date for written notice of delivery set out in the Order, or in any delivery schedule, will be accepted or paid for unless the Company notifies the Supplier in writing of its intention to accept the same.
8.7 The Supplier shall supply the Company on constitute conclusive constructive acceptance and delivery of said Vessel in accordance with the Goods with full provisions hereof. At the time of acceptance of the Vessel, Builder shall execute and deliver to Owner a Builder's Certificate (CG-1261) and ▇▇▇▇ of Sale (CG 1340) warranting that the Vessel is free and clear operatingof all liens and encumbrances, storageexcept as to Owner Furnished Equipment and Owner shall pay all monies due by reason of this Contract, handling and safety instructionsexcept the $50,000 hold back contemplated by Article 7a(12) above; provided, warning notices clearly displayed and other information as may be necessary for their proper usehowever, maintenance and repair for the Company that delivery or constructive delivery to accept delivery of the Goods.
8.8 Unless the Company expressly agrees otherwise in writing, containers and packing must be supplied free but will be returned to the Supplier, if required by written notice from the Supplier to the Company, at the Supplier's risk and expense.
8.9 Where more than one item of Goods is involved in the Order and the Company agrees to accept delivery by instalments, the Agreement shall be construed as a separate contract in respect of each instalment. Nevertheless failure to deliver any instalment shall entitle the Company at its option to treat the Agreement as repudiated.
8.10 If the Goods are delivered to the Company in excess of the quantities ordered the Company Owner shall not be bound evidenced or taken to pay mean that all monies due under this Contract have been so paid in full. Upon the receipt of a COI from the USCG for the excess Vessel and any excess will the final acceptance of the Vessel by Owner, Builder shall be relieved of all liability and will remain at responsibility hereunder except for the Supplier's risk obligations of Builder under Articles 6, 12, 13, 17, 20, 23 and will be returnable at the Supplier's expense30 of this Contract.
8.11 The Supplier shallc. When Builder gives Owner notice of delivery, free of charge and within 30 days from the giving of notice as provided below, either repair or replace (as the Company shall elect) such of the Goods as may either be damaged in transit or having been placed in transit, fail to be delivered to the Company provided that:
8.11.1 in the case of damage to such Goods in transit, the Company shall within 30 days of delivery give notice in writing to the Supplier that the Goods have been damaged;
8.11.2 in the case of non-delivery, the Company shall (provided that the Company has been notified of dispatch within 10 days of the notified date of delivery) give notice to the Supplier that the Goods have not been delivered.
8.12 If the Goods require assembly and installation, the Supplier shall:
8.12.1 carry out such work in accordance with Condition 2.4 above;
8.12.2 comply with the Company's requirements relating to access to and use and security of, the Company's premises and shall keep the Company's premises clean and tidy at all time; and
8.12.3 following event any such assembly complaint or installation, restore the Company’s premises on which it has been installing the Goods dispute as to the condition they were of the Vessel cannot be resolved and settled by the parties, then such complaint or dispute shall be settled by arbitration in before it commenced such installationthe manner provided for in Article 30 of this Contract.
Appears in 1 contract
Sources: Vessel Construction Contract (Majestic Star Casino LLC)