Design-Builder’s Requests for Equitable Adjustments Sample Clauses

The 'Design-Builder’s Requests for Equitable Adjustments' clause defines the process by which the design-builder can formally request changes to the contract price, schedule, or other terms when unforeseen circumstances or changes in project scope occur. Typically, this clause outlines the required documentation, timeframes for submission, and the types of events that may justify an adjustment, such as owner-directed changes or unexpected site conditions. Its core function is to provide a structured mechanism for addressing and compensating for changes, thereby ensuring fairness and minimizing disputes between the parties.
Design-Builder’s Requests for Equitable Adjustments. If Design-Builder believes that any event arising out of or relating to the Work causes a material increase in its cost of, or time required for the performance of, any part of the Work, and that under the terms of the Contract Documents such event entitles Design-Builder to an adjustment to the Contract Sum or the Guaranteed Completion Date(s), then Design-Builder shall comply with the following processes.
View SourceView Similar (7)

Related to Design-Builder’s Requests for Equitable Adjustments

  • Price Adjustments for OGS Centralized Contracts Periodic price adjustments will occur no more than twice per year on a schedule to be established solely by OGS. Pricing offered shall be fixed for the first twelve (12) months of the Contract term. Such price increases will only apply to the OGS Centralized Contracts and shall not be applied retroactively to Authorized User Agreements or any Mini-bids already submitted to an Authorized User. Price decreases may be made at any time. Additionally, some price decreases shall be calculated in accordance with Appendix B, section 17, Pricing.

  • Equitable Adjustments to Prices Whenever any provision of this Indenture requires the Company to calculate the average of the Last Reported Sale Prices, or any function thereof, over a period of multiple days (including to calculate the Stock Price or an adjustment to the Conversion Rate), or to calculate Daily VWAPs over an Observation Period, the Company will make proportionate adjustments, if any, to such calculations to account for any adjustment to the Conversion Rate pursuant to Section 5.05(A)(i) that becomes effective, or any event requiring such an adjustment to the Conversion Rate where the Ex-Dividend Date or effective date, as applicable, of such event occurs, at any time during such period or Observation Period, as applicable.

  • Mechanical Adjustments If the Company shall pay a dividend in shares of its Common Stock (other than payments of Common Stock as interest on preferred stock), subdivide (split) its outstanding shares of Common Stock, combine (reverse split) its outstanding shares of Common Stock, issue by reclassification of its shares of Common Stock any shares or other securities of the Company, or distribute as a stock dividend to holders of its Common Stock any securities of the Company or of another entity, the number of shares of Common Stock or other securities the Holder hereof is entitled to purchase pursuant to the Warrants immediately prior thereto shall be adjusted so that the Holder shall be entitled to receive upon exercise the number of shares of Common Stock or other securities which he, she or it would have owned or would have been entitled to receive after the happening of any of the events described above had the Warrant been exercised immediately prior to the happening of such event, and the Exercise Price shall be correspondingly adjusted; provided, however, that no adjustment in the number of shares and/or the Exercise Price shall be required unless such adjustment would require an increase or decrease of at least one percent (1%) in such number and/or price; and provided further, however, that any adjustments which by reason of this Section 11 are not required to be made shall be carried forward and taken into account in any subsequent adjustment. An adjustment made pursuant to this Section 11 shall become effective immediately after the record date in the case of a stock dividend or other distribution and shall become effective immediately after the effective date in the case of a subdivision, combination or reclassification. The Holder shall be entitled to participate in any subscription or other rights offering made to holders of Common Stock as if he, she or it had purchased the full number of shares as to which the Warrant remains unexercised immediately prior to the record date for such rights offering.

  • Equitable Adjustments (1) If the Contracting Officer confirms that Government conduct effected a change as alleged by the Contractor, and the conduct causes an increase or decrease in the Contractor's cost of, or the time required for, performance of any part of the work under this contract, whether changed or not changed by such conduct, an equitable adjustment shall be made-- (i) In the contract price or delivery schedule or both; and (ii) In such other provisions of the contract as may be affected. (2) The contract shall be modified in writing accordingly. In the case of drawings, designs or specifications which are defective and for which the Government is responsible, the equitable adjustment shall include the cost and time extension for delay reasonably incurred by the Contractor in attempting to comply with the defective drawings, designs or specifications before the Contractor identified, or reasonably should have identified, such defect. When the cost of property made obsolete or excess as a result of a change confirmed by the Contracting Officer under this clause is included in the equitable adjustment, the Contracting Officer shall have the right to prescribe the manner of disposition of the property. The equitable adjustment shall not include increased costs or time extensions for delay resulting from the Contractor's failure to provide notice or to continue performance as provided, respectively, in (b) and (c) above.

  • REQUESTS FOR FLEXIBLE WORKING ARRANGEMENTS 49.1 Employee may request change in working arrangements s.65 of the Act. Note 1: Section 65 of the Act provides for certain Employees to request a change in their working arrangements because of their circumstances, as set out in s.65(1A).