Owner’s Right to Stop Work The Owner reserves the right, for itself and for any designated Construction Inspector retained by Owner, upon observation of apparent nonconforming Work, to immediately stop the affected Work. If the Work is later determined by the Design Professional to be in fact conforming Work, then Contractor shall be entitled upon timely claim to a Change Order for payment by Owner of any reasonable Actual Costs actually incurred by Contractor in connection with the stop Work order and resumption of the Work, as well as an extension in the time for performance of the Work to the extent Contractor is delayed by Owner's stop Work order. The Design Professional shall determine the time, which shall be binding upon both Owner and Contractor, as set forth in Section 3, Part 3.
Right to Grieve Where an employee feels that she has been aggrieved by a decision of the Employer related to promotion, demotion or transfer, the employee may grieve the decision at Step 3 of the grievance procedure in Article 9 of this Agreement within seven (7) days of being notified of the results.
HHS Right to Use Contractor agrees that HHS has the right to use, produce, and distribute copies of and to disclose to HHS employees, agents, and contractors and other governmental entities all or part of this Contract or any related Solicitation Response as HHS deems necessary to complete the procurement process or comply with state or federal laws.
Owner’s Right to Make Changes Without invalidating the Contract, the Owner, by Change Order and without notice to the sureties, may authorize or order extra work or changes by altering, adding to, or deducting from the Work or the Contract Time, the Contract Sum being adjusted accordingly. All Change Orders shall be performed under the conditions of the original Contract except that any claim for extension of time caused thereby shall be adjusted at the time of signing of the Change Order. (See Change Order formats in Section 7.) Prior to the issuance of the Proceed Order, the Contractor and the Owner shall advise each other in writing of their designees authorized to accept and approve changes to the Contract Sum and the limits to each designee's authority. Should any designee or limits of authority change during the time this Contract is in effect, the Contractor or Owner shall give written notice to the other as provided in Article 1.
Right to Defend Upon receipt of notice of any matter for which indemnification might be claimed by an Indemnified Party, the Indemnifying Party shall be entitled to defend, contest or otherwise protect against any such matter at its own cost and expense, and the Indemnified Party must cooperate in any such defense or other action. The Indemnified Party shall have the right, but not the obligation, to participate at its own expense in defense thereof by counsel of its own choosing, but the Indemnifying Party be entitled to control the defense unless the Indemnified Party has relieved the Indemnifying Party from liability with respect to the particular matter or the Indemnifying Party fails to assume defense of the matter. In the event the Indemnifying Party shall fail to defend, contest or otherwise protect in a timely manner against any matter, the Indemnified Party shall have the right, but not the obligation, thereafter to defend, contest or otherwise protect against the same and make any compromise or settlement thereof and recover the reasonable cost thereof from the Indemnifying Party including, without limitation, reasonable attorneys' fees, disbursements and all amounts paid as a result of such suit, action, investigation, claim or proceeding or the compromise or settlement thereof; provided, however, that the Indemnified Party must send a written notice to the Indemnifying Party of any such proposed settlement or compromise, which settlement or compromise the Indemnifying Party may reject, in its reasonable judgment, within ten (10) days of receipt of such notice. Failure to reject such notice within such ten (10) day period shall be deemed an acceptance of such settlement or compromise. The Indemnified Party shall have the right to effect a settlement or compromise over the objection of the Indemnifying Party; provided, that if (i) the Indemnifying Party is contesting such claim in good faith or (ii) the Indemnifying Party has assumed the defense from the Indemnified Party, the Indemnified Party waives any right to indemnity therefor. If the Indemnifying Party undertakes the defense of such matters, the Indemnified Party shall not, so long as the Indemnifying Party does not abandon the defense thereof, be entitled to recover from the Indemnifying Party any legal or other expenses subsequently incurred by the Indemnified Party in connection with the defense thereof other than the reasonable costs of investigation undertaken by the Indemnified Party with the prior written consent of the Indemnifying Party.