Developer’s Submittals and Schedules Clause Samples

The "Developer’s Submittals and Schedules" clause requires the developer to provide detailed documentation and timelines related to the project’s progress and deliverables. This typically includes submitting construction schedules, progress reports, and other relevant documents for review and approval by the owner or project manager. By mandating these submittals, the clause ensures transparency, facilitates coordination among stakeholders, and helps monitor compliance with project milestones, ultimately reducing the risk of delays and misunderstandings.
Developer’s Submittals and Schedules. Developer’s submittals shall comply with the provisions and requirements of the Specifications including, without limitation Submittals. 10.1 Schedule of Work, Schedule of Submittals, and Schedule of Values. 10.1.1 Developer shall comply with the construction schedule attached to the Facilities Lease as Exhibit F (“Construction Schedule”). [To be attached when available.] 10.1.2 Developer must provide all schedules both in hard copy and electronically, in a native format (e.g. Microsoft Project or Primavera) approved in advance by the District. 10.1.3 The District will review the schedules submitted and Developer shall make changes and corrections in the schedules as requested by the District and resubmit the schedules until approved by the District. 10.1.4 The District shall have the right at any time to discuss with Developer revisions to the schedule of values if, in the District's sole opinion, the schedule of values does not accurately reflect the value of the Work performed. 10.1.5 All schedules must be approved by the District before Developer can rely on them as a basis for payment. 10.1.6 Within TEN (10) calendar days after the date of the Notice to Proceed with Construction (unless otherwise specified in the Specifications), Developer shall prepare and submit to the District for review, in a form supported by sufficient data to substantiate its accuracy as the District may require:
View SourceView Similar (62)
Developer’s Submittals and Schedules. Developer’s submittals shall comply with the provisions and requirements of the Specifications including, without limitation Submittals. 10.1 Schedule of Work, Schedule of Submittals, and Schedule of Values. 10.1.1 Developer shall comply with the construction schedule attached to the Facilities Lease as Exhibit F (“Construction Schedule”). [To be attached when available.] 10.1.2 Developer must provide all schedules both in hard copy and electronically, in a native format (e.g. Microsoft Project or Primavera) approved in advance by the District. 10.1.3 The District will review the schedules submitted and Developer shall make changes and corrections in the schedules as requested by the District and resubmit the schedules until approved by the District. 10.1.4 The District shall have the right at any time to discuss with Developer revisions to the schedule of values if, in the District's sole opinion, the schedule of values does not accurately reflect the value of the Work performed. 10.1.5 All schedules must be approved by the District before Developer can rely on them as a basis for payment. 10.1.6 Within TEN (10) calendar days after the date of the Notice to Proceed with Construction (unless otherwise specified in the Specifications), Developer shall prepare and submit to the District for review, in a form supported by sufficient data to substantiate its accuracy as the District may require: 10.1.6.1 Preliminary Schedule A preliminary schedule of construction indicating the starting and completion dates of the various stages of the Work, including any information and following any form as may be specified in the Specifications. Once approved by District, this shall become the Construction Schedule. This schedule shall include and identify all tasks that are on the Project’s critical path with a specific determination of the start and completion of each critical path task as well as all Contract milestones and each milestone’s completion date(s) as may be required by the District. 10.1.6.1.1 The District is not required to approve a preliminary schedule of construction with early completion, i.e., one that shows early completion dates for the Work and/or milestones. Developer shall not be entitled to extra compensation if the District approves a Construction Schedule with an early completion date and Developer completes the Project beyond the date shown in the schedule but within the Contract Time. A Construction Schedule showing the Work completed in less ...
View Source
Developer’s Submittals and Schedules 
View SourceView Similar (9)

Related to Developer’s Submittals and Schedules

  • Recitals and Schedules References to this Agreement include the recitals and schedules which form part of this Agreement for all purposes. References in this Agreement to the Parties are references respectively to the Parties and their legal personal representatives, successors and permitted assigns.

  • Shift Schedules 1501 Shift schedules for a minimum of a four (4) week period shall be posted at least two (2) weeks in advance of the beginning of the scheduled period. Shifts within the minimum four (4) week period shall not be altered after posting except by mutual agreement between the nurse(s) concerned and the Employer. Requests for specific days off duty shall be submitted in writing at least two (2) weeks prior to posting and granted, if possible in the judgment of the Employer. 1502 Requests for interchanges in posted shifts or a portion thereof shall also be submitted in writing, co-signed by the nurse willing to exchange shifts with the applicant. Where reasonably possible, interchanges in posted shifts are to be completed within the posted shift schedule. It is understood that any change in shifts or days off initiated by the nurses and approved by the Employer shall not result in overtime costs to the Employer. 1503 Night shift shall be considered as the first shift of each calendar day. 1504 Master rotations for each nursing unit shall be planned by the Employer in meaningful consultation with the nurse(s) concerned. The process for meaningful consultation shall include:  Employer proposes a master rotation including the Employer established criteria and provides to Nurses concerned  Nurses are provided reasonable time to submit feedback and/or an alternate master rotation for consideration.  The amended or new master rotation is provided to Nurses for review. Nurses are provided with a reasonable time to submit feedback.  At each step of the consultation process the Union will be provided with the new or revised master rotation to ensure contract compliance.  Employer has the sole discretion to select the new master rotation and provides rationale for the selection. Master Rotations shall, unless otherwise mutually agreed between the nurse(s) concerned and the Employer, observe the conditions listed hereinafter: (a) a minimum of fifteen hours (15) off between assigned shifts. (b) (i) a minimum of forty-seven (47) hours off at one time, or

  • Exhibits and Schedules The Exhibits and Schedules shall be construed with and as an integral part of this Agreement to the same extent as if the same had been set forth verbatim herein.

  • LIST OF SCHEDULES AND EXHIBITS Schedules

  • Clauses and Schedules Any reference in this Agreement to a Clause or a sub-clause or a Schedule is, unless otherwise stated, to a clause or a sub-clause hereof or a schedule hereto.