Disputes with Subcontractors Sample Clauses

The "Disputes with Subcontractors" clause establishes the procedures and responsibilities for handling disagreements that arise between the main contractor and any subcontractors involved in a project. Typically, this clause outlines steps such as notification requirements, escalation processes, and possible involvement of mediation or arbitration to resolve issues efficiently. By clearly defining how disputes are to be managed, the clause helps prevent project delays and ensures that conflicts are addressed in a structured manner, thereby minimizing disruption and protecting the interests of all parties involved.
POPULAR SAMPLE Copied 1 times
Disputes with Subcontractors. Wherever any provision of any section of the Plans and Specifications conflicts with any agreement or regulation of any kind at any time in force among members of any Trade Associations, Unions or Councils which regulate or distinguish what Work shall or shall not be included in the Work of any particular trade, the Contractor shall make all necessary arrangements to reconcile any such conflict without delay, damage, increase to the Contract Sum or recourse to the University. The University will not arbitrate disputes among subcontractors nor between the Contractor and one or more subcontractors concerning responsibility for performing any part of the Project. In case the progress of the Work is affected by any undue delay in furnishing or installing any items of material or equipment required under the Contract Documents because of conflict involving any agreement or regulation of the type described above, the University’s Representative may require that other material or equipment of equal kind and quality be provided at no additional cost to the University.
View SourceView Similar (3)
Disputes with Subcontractors. Applications for Payment may not include requests for payment of amounts the Contractor does not intend to pay to a Subcontractor because of a dispute or other reason.
View SourceView Similar (2)
Disputes with Subcontractors. Contractor shall inform ComEd of any material dispute arising between Contractor and any of its Subcontractors or between any Subcontractor and another Subcontractor that may cause a delay in the performance of Services. Contractor shall use its best efforts to avoid disputes regarding the Work and shall resolve such disputes as they arise. Contractor shall comply with Article 19 regarding any Subcontractor labor disputes.
View SourceView Similar (8)
Disputes with Subcontractors. If a Managing Contractor has a dispute with a subcontractor in respect of any aspect of the Services and either the Managing Contractor or the subcontractor pursues any court action, arbitration or adjudication application under the SOP Act, then: (a) the Managing Contractor will be responsible for carriage of the dispute, provided it must: (i) keep the Principal's Representative fully informed of all aspects of the dispute; and (ii) act in accordance with the reasonable instructions of the Principal's Representative (including in respect of lodging any appeals against any decisions made in respect of the dispute); (b) subject to the Principal's Representative prior written approval (which may be given or withheld at the Principal’s Representative's absolute discretion), any external legal, expert or consultants costs incurred by the Managing Contractor arising out of the defence of any court action, arbitration or adjudication will form part of the Actual Reimbursable Costs; and (c) the Managing Contractor's own internal costs of administering the court action, arbitration or adjudication application will not form part of the Actual Reimbursable Costs.
View Source

Related to Disputes with Subcontractors

  • Contracts with Subcontractors a. Grantee may enter into contracts with subcontractors unless restricted or otherwise prohibited in the Contract. b. Grantees are prohibited from subcontracting with for-profit organizations under this Contract. c. Prior to entering into a subcontract agreement equaling or exceeding $100,000, Grantee will obtain written approval from the System Agency. d. Grantee will obtain written approval from System Agency before modifying any subcontract agreement to cause the agreement to exceed $100,000. e. Grantee will establish written policies and procedures for competitive procurement and monitoring of subcontracts and will develop a subcontracting monitoring plan. f. monitor subcontractors for both financial and programmatic performance and will maintain pertinent records. g. submit quarterly monitoring reports to the System Agency in a format determined by the System Agency. h. ensure that subcontracts are fully aware of the requirements placed upon them by state/federal statutes, rules, and regulations and by the provisions of this Contract. i. ensure all subcontracts, must be in writing and include the following: 1. Name and address of all parties and the subcontractor’s Vendor Identification Number (VIN) or Employee Identification Number (EIN); 2. Detailed description of the services to be provided; 3. Measurable method and rate of payment and total not-to-exceed amount of the contract; 4. Clearly defined and executable termination clause; and 5. Beginning and ending dates that coincide with the dates of the Contract. j. ensure and be responsible for the performance of the subcontractor(s). k. not contract with a subcontractor, at any tier, that is debarred, suspended, or excluded from or ineligible for participation in federal assistance programs or if the subcontractor would be otherwise ineligible to abide by the terms of this Contract.

  • Agreements with Subcontractors Business Associate shall enter into a Business Associate Agreement with any Subcontractor to whom it provides PHI received from Covered Entity or created or received by Business Associate on behalf of Covered Entity in which the Subcontractor agrees to the same restrictions and conditions that apply through this Agreement to Business Associate with respect to such PHI. Business Associate must enter into this Business Associate Agreement before any use by or disclosure of PHI to such agent. The written agreement must identify Covered Entity as a direct and intended third party beneficiary with the right to enforce any breach of the agreement concerning the use or disclosure of PHI. Business Associate shall provide a copy of the Business Associate Agreement it enters into with a subcontractor to Covered Entity upon request. Business associate may not make any disclosure of PHI to any Subcontractor without prior written consent of Covered Entity.

  • Contractors and Subcontractors Drug-Free Workplace Act of 1988 1) Publish and give a policy statement to all covered employees informing them that the unlawful manufacture, distribution, dispensation, possession or use of a controlled substance is prohibited in the covered workplace and specifying the actions that will be taken against employees who violate the policy. 2) Establish a drug-free awareness program to make employees aware of a) the dangers of drug abuse in the workplace; b) the policy of maintaining a drug-free workplace; c) any available drug counseling, rehabilitation, and employee assistance programs; and d) the penalties that may be imposed upon employees for drug abuse violations. 3) Notify employees that as a condition of employment on a federal contract or grant, the employee must a) abide by the terms of the policy statement; and b) notify the employer, within five (5) calendar days, if he or she is convicted of a criminal drug violation in the workplace. 4) Notify the contracting or granting agency within ten (10) days after receiving notice that a covered employee has been convicted of a criminal drug violation in the workplace. 5) Impose a penalty on or require satisfactory participation in a drug abuse assistance or rehabilitation program by any employee who is convicted of a reportable workplace drug conviction. 6) Make an ongoing, good faith effort to maintain a drug-free workplace by meeting the requirements of the act.

  • Third Party Contractors Tenant shall obtain and deliver to Landlord, Third Party Contractor’s certificates of insurance and applicable endorsements at least seven (7) business days prior to the commencement of work in or about the Premises by any vendor or any other third-party contractor (collectively, a “Third Party Contractor”). All such insurance shall (a) name Landlord as an additional insured under such party’s liability policies as required by Section 10.3.1 above and this Section 10.6, (b) provide a waiver of subrogation in favor of Landlord under such Third Party Contractor’s commercial general liability insurance, (c) be primary and any insurance carried by Landlord shall be excess and non-contributing, and (d) comply with Landlord’s minimum insurance requirements.

  • CONTRACTOR's Agents and Subcontractors To impose the same restrictions and conditions set forth in this Personal Information and Security Contract on any subcontractors or other agents with whom CONTRACTOR subcontracts any activities under the Agreement that involve the disclosure of DHCS PI or PII to such subcontractors or other agents.