Due to Force Majeure Clause Samples

POPULAR SAMPLE Copied 41 times
Due to Force Majeure. If the Services are used in violation of any law, rule or regulation, or for a purpose other than that declared by the Subscriber at the time of subscription;
View SourceView Similar (48)
Due to Force Majeure. If (a) Company wholly suspends the Work on the Facility for six (6) consecutive months due to the occurrence of a Force Majeure suffered by Company; or (b) Contractor is prevented from performing the Work for a period of six (6) consecutive months as a result of the occurrence of a Force Majeure suffered by Contractor, then the affected Party may terminate this Contract at no cost or penalty, other than the payment of all accrued payment obligations due and payable pursuant to this Contract (excluding loss of anticipated profits for the Work not yet performed by Contractor) upon not less than fifteen (15) Days prior written notice to the other Party; provided, however, that nothing in this Section 19.3 shall relieve or excuse either Party from its obligations under Sections 19.5 and 19.6.
View SourceView Similar (6)
Due to Force Majeure. Client or Hexagon, as the case may be, may terminate the Contract / Order anytime during its term if a delay or failure to perform its obligations exceeds sixty (60) days due to the occurrence of a Force Majeure event. In such case, the party affected by the Force Majeure event may terminate the Contract / Order by providing immediate written notice to the other party.
View SourceView Similar (3)
Due to Force Majeure. Either Party shall have the right to terminate this Agreement or any active Work Plan(s) by written notice to the other Party upon the occurrence of a Force Majeure Event preventing the other Party from performing its obligations hereunder as provided in Section 19 for * days or more; provided, however, that the right to terminate under this clause shall be limited to the Work Plan(s) affected.
View SourceView Similar (2)
Due to Force Majeure. The Concessionaire shall have to replenish the Performance Security to its original value on such appropriation by the Authority.
View SourceView Similar (2)
Due to Force Majeure. (a) For purposes of this Section 9.1:
View SourceView Similar (2)
Due to Force Majeure. If for any reason a Party is forced to terminate this Agreement, a notice of termination shall be sent to the other Party through a reliable means of communication. Termination shall not affect any accrued rights or duties, and the provisions of the Confidentiality and Intellectual property rights clauses of this Agreement.
View Source
Due to Force Majeure. The affected Party shall Notify the other as soon as reasonably practicable of the Force Majeure event and take all reasonable steps to mitigate its effects. A further Notification shall be issued immediately the circumstances of Force Majeure end.
View Source

Related to Due to Force Majeure

  • Termination due to Force Majeure 13.5.1 If the Force Majeure Event or its effects continue to be present beyond the period as specified in Article 4.5.3, either Party shall have the right to cause termination of the Agreement. In such an event, this Agreement shall terminate on the date of such Termination Notice.

  • Termination Due to Force Majeure Event If the period of Force Majeure continues or is in the reasonable judgment of the Parties likely to continue beyond a period of 120 (one hundred and twenty) Days, the Parties may mutually decide to terminate this Agreement or continue this Agreement on mutually agreed revised terms. If the Parties are unable to reach an agreement in this regard, the Affected Party shall after the expiry of the said period of 120 (one hundred and twenty ) Days be entitled to terminate the Agreement in which event, the provisions of Articles 16 and 17 shall, to the extent expressly made applicable, apply.

  • Force Majeure If by reason of Force Majeure, either party hereto shall be rendered unable wholly or in part to carry out its obligations under this Agreement through no fault of its own then such party shall give notice and full particulars of Force Majeure in writing to the other party within a reasonable time after occurrence of the event or cause relied upon. Upon delivering such notice, the obligation of the affected party, so far as it is affected by such Force Majeure as described, shall be suspended during the continuance of the inability then claimed but for no longer period, and such party shall endeavor to remove or overcome such inability with all reasonable dispatch. In the event that Vendor’s obligations are suspended by reason of Force Majeure, all TIPS Sales accepted prior to the Force Majeure event shall be the legal responsibility of Vendor and the terms of the TIPS Sale Supplemental Agreement shall control Vendor’s failure to fulfill for a Force Majeure event.

  • Force Majeure Event 16.1 If a Force Majeure Event gives rise to a failure or delay in either party performing any obligation under this Agreement (other than any obligation to make a payment), that obligation will be suspended for the duration of the Force Majeure Event. 16.2 A party that becomes aware of a Force Majeure Event which gives rise to, or which is likely to give rise to, any failure or delay in that party performing any obligation under this Agreement, must: (a) promptly notify the other; and (b) inform the other of the period for which it is estimated that such failure or delay will continue. 16.3 A party whose performance of its obligations under this Agreement is affected by a Force Majeure Event must take reasonable steps to mitigate the effects of the Force Majeure Event.

  • Force Majeure Events a) Neither Party shall be responsible or liable for or deemed in breach hereof because of any delay or failure in the performance of its obligations hereunder (except for obligations to pay money due prior to occurrence of Force Majeure events under this Agreement) or failure to meet milestone dates due to any event or circumstance (a "Force Majeure Event") beyond the reasonable control of the Party experiencing such delay or failure, including the occurrence of any of the following: i) acts of God; ii) typhoons, floods, lightning, cyclone, hurricane, drought, famine, epidemic, plague or other natural calamities; iii) acts of war (whether declared or undeclared), invasion or civil unrest; iv) any requirement, action or omission to act pursuant to any judgment or order of any court or judicial authority in India (provided such requirement, action or omission to act is not due to the breach by the SPG or of any Law or any of their respective obligations under this Agreement); v) inability despite complying with all legal requirements to obtain, renew or maintain required licenses or Legal Approvals; vi) earthquakes, explosions, accidents, landslides; fire; vii) expropriation and/or compulsory acquisition of the Project in whole or in part by Government Instrumentality; viii) chemical or radioactive contamination or ionizing radiation; or ix) damage to or breakdown of transmission facilities of GETCO/ DISCOMs; x) Exceptionally adverse weather condition which are in excess of the statistical measure of the last hundred (100) years.