Exclusive Responsibility of Designated Entity Sample Clauses

The 'Exclusive Responsibility of Designated Entity' clause assigns sole accountability for certain tasks, obligations, or outcomes to a specifically named party within an agreement. In practice, this means that only the designated entity is responsible for performing specified duties, such as compliance with regulations, delivery of services, or maintenance of equipment, and other parties are expressly relieved of these responsibilities. This clause ensures clarity in roles and prevents disputes by clearly delineating which party is liable for particular aspects of the contract.
Exclusive Responsibility of Designated Entity. Designated Entity shall be solely responsible for all planning, design, engineering, procurement, construction, installation, management, operations, safety, and compliance with applicable laws and regulations associated with the Project, including but not limited to obtaining all necessary permits, siting, and other regulatory approvals. Transmission Provider shall have no responsibility to manage, supervise, or ensure compliance or adequacy of same.
View SourceView Similar (9)
Exclusive Responsibility of Designated Entity. As between the Parties, the Designated Entity shall be solely responsible for all planning, design, engineering, procurement, construction, installation, management, operations, safety, and compliance with Applicable Laws and Regulations, Applicable Reliability Requirements, and Transmission Owner Technical Standards associated with the Designated Project, including, but not limited to, scheduling, meeting Critical Path Milestones and Advisory Milestones, timely requesting review and consent to any project modifications, and obtaining all necessary permits, siting, and other regulatory approvals. The NYISO shall have no responsibility and shall have no liability regarding the management or supervision of the Designated Entity’s development of the Designated Project or the compliance of the Designated Entity with Applicable Laws and Regulations, Applicable Reliability Requirements, and Transmission Owner Technical Standards. The NYISO shall cooperate with the Designated Entity in good faith in providing information to assist the Designated Entity in obtaining all approvals and authorizations from Governmental Authorities required to develop, construct, and operate the Designated Project by the Required Designated Project In-Service Date, including, if applicable, information describing the NYISO’s basis for selecting the Transmission Project as the more efficient or cost-effective transmission solution to satisfy an identified Public Policy Transmission Need.
View SourceView Similar (7)
Exclusive Responsibility of Designated Entity. As between the Parties, the Designated Entity shall be solely responsible for all planning, design, engineering, procurement, construction, installation, management, operations, safety, and compliance with Applicable Laws and Regulations, Applicable Reliability Requirements, and Transmission Owner Technical Standards associated with the Designated Project, including, but not limited to, scheduling, meeting Critical Path Milestones and Advisory Milestones, timely requesting review and consent to any project modifications, and obtaining all necessary permits, siting, and other regulatory approvals. The NYISO shall have no responsibility and shall have
View SourceView Similar (3)

Related to Exclusive Responsibility of Designated Entity

  • Limitation of Responsibility Notwithstanding any other provisions ---------------------------- hereof, Committee Members shall be liable to the parties only for actions constituting bad faith, gross negligence or breach of an express provision of this Agreement (so long as such breach remains uncured after ten (10) days of receiving notice of the nature of such breach). In all other respects, Committee Members shall not be liable for negligence or mistakes of judgment.

  • Transfer of Responsibility on Expiry or Termination 15.1 The Contractor shall, at no cost to the Department, promptly provide such assistance and comply with such timetable as the Department may reasonably require for the purpose of ensuring an orderly transfer of responsibility upon the expiry or other termination of this Contract. The Department shall be entitled to require the provision of such assistance both prior to and, for a reasonable period of time after the expiry or other termination of this Contract. 15.2 Such assistance may include (without limitation) the delivery of documents and data in the possession or control of the Contractor which relate to this Contract, including the documents and data, if any, referred to in the Schedule. 15.3 The Contractor undertakes that it shall not knowingly do or omit to do anything that may adversely affect the ability of the Department to ensure an orderly transfer of responsibility.

  • Limitation of responsibility of Existing Lenders (a) Unless expressly agreed to the contrary, an Existing Lender makes no representation or warranty and assumes no responsibility to a New Lender for: (i) the legality, validity, effectiveness, adequacy or enforceability of the Finance Documents or any other documents; (ii) the financial condition of any Obligor; (iii) the performance and observance by any Obligor of its obligations under the Finance Documents or any other documents; or (iv) the accuracy of any statements (whether written or oral) made in or in connection with any Finance Document or any other document, and any representations or warranties implied by law are excluded. (b) Each New Lender confirms to the Existing Lender and the other Finance Parties that it: (i) has made (and shall continue to make) its own independent investigation and assessment of the financial condition and affairs of each Obligor and its related entities in connection with its participation in this Agreement and has not relied exclusively on any information provided to it by the Existing Lender in connection with any Finance Document; and (ii) will continue to make its own independent appraisal of the creditworthiness of each Obligor and its related entities whilst any amount is or may be outstanding under the Finance Documents or any Commitment is in force. (c) Nothing in any Finance Document obliges an Existing Lender to: (i) accept a re-transfer from a New Lender of any of the rights and obligations assigned or transferred under this Clause 24; or (ii) support any losses directly or indirectly incurred by the New Lender by reason of the non-performance by any Obligor of its obligations under the Finance Documents or otherwise.

  • No Responsibility for Certain Matters No Agent shall be responsible to any Lender for the execution, effectiveness, genuineness, validity, enforceability, collectibility or sufficiency of this Agreement or any other Loan Document or for any representations, warranties, recitals or statements made herein or therein or made in any written or oral statements or in any financial or other statements, instruments, reports or certificates or any other documents furnished or made by such Agent to Lenders or by or on behalf of Company to such Agent or any Lender in connection with the Loan Documents and the transactions contemplated thereby or for the financial condition or business affairs of Company or any other Person liable for the payment of any Obligations, nor shall such Agent be required to ascertain or inquire as to the performance or observance of any of the terms, conditions, provisions, covenants or agreements contained in any of the Loan Documents or as to the use of the proceeds of the Loans or the use of the Letters of Credit or as to the existence or possible existence of any Event of Default or Potential Event of Default. Anything contained in this Agreement to the contrary notwithstanding, Administrative Agent shall not have any liability arising from confirmations of the amount of outstanding Loans or the Letter of Credit Usage or the component amounts thereof.

  • Contractor Responsibility for System Agency’s Termination Costs If the System Agency terminates the Contract for cause, the Contractor shall be responsible to the System Agency for all costs incurred by the System Agency and the State of Texas to replace the Contractor. These costs include, but are not limited to, the costs of procuring a substitute vendor and the cost of any claim or litigation attributable to Contractor’s failure to perform any Work in accordance with the terms of the Contract.