Extension of Performance Security Clause Samples

POPULAR SAMPLE Copied 13 times
Extension of Performance Security. The Contractor may initially provide the Performance Security for a period of 2 (two) years; provided that it shall procure the extension of the validity of the Performance Security, as necessary, at least 2 (two) months prior to the date of expiry thereof. Upon the Contractor providing an extended Performance Security, the previous Performance Security shall be deemed to be released and the Authority shall return the same to the Contractor within a period of 7 (seven) business days from the date of submission of the extended Performance Security.
View SourceView Similar (86)
Extension of Performance Security. 34 7.3 Appropriation of Performance Security 34 7.4 Release of Performance Security 35 7.5 Retention Money 35
View Source
Extension of Performance Security. The Contractor may initially provide the Performance Security for a period
View Source

Related to Extension of Performance Security

  • Release of Performance Security (i) The Authority shall return the Performance Security to the Contractor within 60 (sixty) days of the expiry of the Maintenance Period or the Defects Liability Period, whichever is later, under this Agreement. Notwithstanding the aforesaid, the Parties agree that the Authority shall not be obliged to release the Performance Security until all Defects identified during the Defects Liability Period have been rectified. (ii) The Authority shall return the Additional Performance Security to the Contractor within 28 (twenty eight) days from the date of issue of Completion Certificate under Article 12 of this Agreement. (iii) The Authority shall be liable to pay interest @ 9% (nine per cent) per annum for any delay in the return of Performance Security and Additional Performance Security, if any, beyond the period prescribed above for the period of delay.

  • Appropriation of Performance Security (i) Upon occurrence of a Contractor’s Default, the Authority shall, without prejudice to its other rights and remedies hereunder or in law, be entitled to encash and appropriate the relevant amounts from the Performance Security as Damages for such Contractor’s Default. (ii) Upon such encashment and appropriation from the Performance Security, the Contractor shall, within 30 (thirty) days thereof, replenish, in case of partial appropriation, to its original level the Performance Security, and in case of appropriation of the entire Performance Security provide a fresh Performance Security, as the case may be, and the Contractor shall, within the time so granted, replenish or furnish fresh Performance Security as aforesaid failing which the Authority shall be entitled to terminate the Agreement in accordance with Article 23. Upon replenishment or furnishing of a fresh Performance Security, as the case may be, as aforesaid, the Contractor shall be entitled to an additional Cure Period of 30 (thirty) days for remedying the Contractor’s Default, and in the event of the Contractor not curing its default within such Cure Period, the Authority shall be entitled to encash and appropriate such Performance Security as Damages, and to terminate this Agreement in accordance with Article 23.

  • Suspension of Performance Notwithstanding any other provision hereof, if an Event of Default or a Potential Event of Default has occurred and is continuing, the Non-Defaulting Party, upon written notice to the Defaulting Party, has the right (i) to suspend performance under any or all Transactions and (ii) to the extent an Event of Default has occurred and is continuing, to exercise any remedy available at law or in equity, except as limited be Section 5.7.

  • Availability of Performance Order If, and to the extent that, a breach of this contract has been caused by a Relevant Force Majeure Event, the Non-affected Party shall not be entitled to a Performance Order except to secure performance by the Affected Party of its obligations under this Clause 17.

  • Suspension of Performance or Disbursement Into Court If, at any time, (i) there shall exist any dispute between Broker, Issuer, NCPS, any Subscriber or any other person with respect to the holding or disposition of all or any portion of the Escrow Funds or any other obligations of NCPS hereunder, or (ii) if at any time NCPS is unable to determine, to NCPS’s reasonable satisfaction, the proper disposition of all or any portion of the Escrow Funds or NCPS’s proper actions with respect to its obligations hereunder, or (iii) if Broker and Issuer have not within 30 days of the furnishing by NCPS of a notice of resignation pursuant to Section 7 hereof appointed a successor NCPS to act hereunder, then NCPS may, in its reasonable discretion, take either or both of the following actions: a. suspend the performance of any of its obligations (including without limitation any disbursement obligations) under this Escrow Agreement until such dispute or uncertainty shall be resolved to the sole satisfaction of NCPS or until a successor NCPS shall have been appointed (as the case may be). b. petition (by means of an interpleader action or any other appropriate method) any court of competent jurisdiction in any venue convenient to NCPS, for instructions with respect to such dispute or uncertainty, and to the extent required or permitted by law, pay into such court all funds held by it in the Escrow Funds for holding and disposition in accordance with the instructions of such court. NCPS shall have no liability to Broker, Issuer, any Subscriber or any other person with respect to any such suspension of performance or disbursement into court, specifically including any liability or claimed liability that may arise, or be alleged to have arisen, out of or as a result of any delay in the disbursement of the Escrow Funds or any delay in or with respect to any other action required or requested of NCPS.