Force Majeure Events a) Neither Party shall be responsible or liable for or deemed in breach hereof because of any delay or failure in the performance of its obligations hereunder (except for obligations to pay money due prior to occurrence of Force Majeure events under this Agreement) or failure to meet milestone dates due to any event or circumstance (a "Force Majeure Event") beyond the reasonable control of the Party experiencing such delay or failure, including the occurrence of any of the following:
i) acts of God;
ii) typhoons, floods, lightning, cyclone, hurricane, drought, famine, epidemic, plague or other natural calamities;
iii) acts of war (whether declared or undeclared), invasion or civil unrest;
iv) any requirement, action or omission to act pursuant to any judgment or order of any court or judicial authority in India (provided such requirement, action or omission to act is not due to the breach by the SPG or of any Law or any of their respective obligations under this Agreement);
v) inability despite complying with all legal requirements to obtain, renew or maintain required licenses or Legal Approvals;
vi) earthquakes, explosions, accidents, landslides; fire;
vii) expropriation and/or compulsory acquisition of the Project in whole or in part by Government Instrumentality;
viii) chemical or radioactive contamination or ionizing radiation; or
ix) damage to or breakdown of transmission facilities of GETCO/ DISCOMs;
x) Exceptionally adverse weather condition which are in excess of the statistical measure of the last hundred (100) years.
FORCE MAJEURE CLAUSE Contractor shall be excused from performance hereunder during the time and to the extent that it is prevented from obtaining delivery, or performing by act of God, fire, strike, loss, or shortage of transportation facilities, lock-out, commandeering of materials, product, plant, or facilities by the government, when satisfactory evidence thereof is presented to the District, provided that it is satisfactorily established that the
Force Majeure Exclusions 11.4.1 Force Majeure shall not include (i) any event or circumstance which is within the reasonable control of the Parties and (ii) the following conditions, except to the extent that they are consequences of an event of Force Majeure:
a. Unavailability, late delivery, or changes in cost of the plant, machinery, equipment, materials, spare parts or consumables for the Power Project;
▇. ▇▇▇▇▇ in the performance of any contractor, sub-contractor or their agents;
c. Non-performance resulting from normal wear and tear typically experienced in power generation materials and equipment;
d. Strikes at the facilities of the Affected Party;
e. Insufficiency of finances or funds or the agreement becoming onerous to perform; and
f. Non-performance caused by, or connected with, the Affected Party’s:
i. Negligent or intentional acts, errors or omissions;
ii. Failure to comply with an Indian Law; or
iii. Breach of, or default under this Agreement.
Force Majeur In case the Show Facility is damaged or destroyed, or in case of war, government regulations or any other circumstances whatsoever which will make it impossible or impractical for Show Management to permit Exhibitor to occupy the exhibit space described in this Agreement, this Agreement will terminate and Exhibitor will waive any claim for damages for compensation except the pro rata return of the amount paid for space rented, diminished only by a pro rata portion of the amounts expended to produce the Show.
Force Majeure Report Following the giving of a Force Majeure Notice:
(a) the Affected Party shall give a Force Majeure Report as soon as practicable, and in any event within 7 days of service of the Force Majeure Notice; and
(b) the Force Majeure Report shall constitute a full report on the Relevant Force Majeure Event, amplifying the information provided in the Force Majeure Notice and containing such information as may reasonably be required by the Non-affected Party, including the effect which the Relevant Force Majeure Event is estimated to have on the Affected Party’s performance of the Relevant Obligations.