Fulfillment of Development Fee Requirement Clause Samples

Fulfillment of Development Fee Requirement. The sum of $2,968,000 (in 2019 Dollars), paid by Altec as described in Section 4.1(a) and Section 5.6, the deposit of security as described in Section 4.1(c), the grant of conservation easement described in Section 3.1 at the times set forth therein, together shall fulfill the HCP/NCCP requirement to pay a Development Fee for the Covered Project on the Montreux Property. No other fees or fee amounts shall be due under the HCP/NCCP for the maintenance of the Dedication Property or with respect to the Covered Project, except for any wetland impact fees, rural road fees, or temporary impact fees that may be required consistent with standard application of the HCP/NCCP (except no temporary impact or rural road fees shall be imposed for work done to maintain, repair, or replace in situ, existing roads and improvements); provided, however, that Altec shall pay for other costs provided in this Agreement, as well as any administrative fee imposed by Pittsburg. Once the Grading Permit fee set forth in Section 4.1(a)(i) is paid, no rural road or temporary impact fees shall thereafter be imposed on such phase.
View SourceView Similar (2)
Fulfillment of Development Fee Requirement. The sum of $13,690,000 (in 2019 Dollars), paid by ▇▇▇▇▇ as described in Section 4.3(a) and Section 5.6, the deposit of security as described in Section 4.3(c), and the grant of conservation easements described in Section 3.2, at the times set forth therein, together shall fulfill the HCP/NCCP requirement to pay the Development Fee for the Covered Project on the ▇▇▇▇▇ Property. No other fees or fee amounts shall be due under the HCP/NCCP with respect to the Covered Project, except for any wetland impact fees, rural road fees, or temporary impact fees that may be required consistent with standard application of the HCP/NCCP (except no temporary impact or rural road fees shall be imposed for work done to maintain, repair, or replace in situ, existing roads and improvements); provided, however, that ▇▇▇▇▇ shall pay for other costs provided in this Agreement, as well as any administrative fee imposed by Pittsburg. Once the Grading Permit fee set forth in Section 4.3(a)(i) above is paid, no rural road or temporary impact fees shall thereafter be imposed.
View Source

Related to Fulfillment of Development Fee Requirement

  • CONTRACT COMPLIANCE REQUIREMENT The HUB requirement on this Contract is 0%. The student engagement requirement of this Contract is 0 hours. The Career Education requirement for this Contract is 0 hours. Failure to achieve these requirements may result in the application of some or all of the sanctions set forth in Administrative Policy 3.10, which is hereby incorporated by reference.

  • Payment of Non-compliance Penalties Subject to Clause (e) above, the Supplier/Service Provider shall pay the Non-compliance Penalty indicated in the Non-compliance Penalty Certificate within 10 (ten) Business Days of Transnet issuing a valid Tax Invoice to the Supplier/Service Provider for the amount set out in that certificate. If Transnet does not issue a valid Tax Invoice to the Supplier/Service Provider for Non-compliance Penalties accrued during any relevant period, those Non- compliance Penalties shall be carried forward to the next period.

  • Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.

  • Termination for Non-Compliance with E-Verify Pursuant to section 448.095(5)(c)1., F.S., the Department shall terminate the Term Contract if it has a good faith belief that the Contractor has knowingly violated section 448.09(1), F.S. Pursuant to section 448.095(5)(c)2., F.S., if the Department has a good faith belief that a subcontractor knowingly violated section 448.09(1), F.S., the Department shall promptly notify the Contractor and order the Contractor to immediately terminate the contract with the subcontractor.

  • Penalties for Non-compliance to Service Level Agreement Where the Supplier/Service Provider fails to deliver the Goods/Services within the agreed and accepted milestone timelines and provided that the cause of the delay was not due to a fault of Transnet, penalties shall be imposed at …………………………………………………… .