Guaranty of Claims with Respect to Temporary Firehouse Sample Clauses

Guaranty of Claims with Respect to Temporary Firehouse. If, following Substantial Completion of the Temporary Firehouse, County has any claims against the Architect under the Architect Agreement for the Temporary Firehouse or against the General Contractor under the Warranty Provisions of the Construction Contract for the Temporary Firehouse, which claims arise out of design or construction errors, omissions or defects with respect to the Temporary Firehouse (collectively, “Temporary Firehouse Claims”), Developer hereby guarantees to County, and to its successors and assigns, the collection of all damages, debts, obligations and liabilities of any kind and nature arising from or out of the Temporary Firehouse Claims. Developer’s guaranty obligation as aforesaid is limited and conditional in that it is a guaranty of collection only and Developer shall be obligated (and County shall first have a cause of action for Developer’s guaranty obligation) only after County has reduced its Temporary Firehouse Claims to a monetary judgment and (i) execution of the judgment against the Architect or General Contractor (as applicable) and against any available surety has been returned unsatisfied, or (ii) the Architect or General Contractor (as applicable) and any available surety have become insolvent or the judgment in question has been discharged (with respect to the General Contractor or Architect (as applicable) and any available surety) in whole or in part in a bankruptcy or similar proceeding. Notwithstanding the foregoing, in no event shall Developer’s total liability under the guaranty described this Section 3.08(c) exceed the total hard and soft costs of designing and constructing the Temporary Firehouse to Substantial Completion.
View Source

Related to Guaranty of Claims with Respect to Temporary Firehouse

  • Prior Notice to Owners with Respect to Certain Matters Subject to the provisions and limitations of Section 4.04, with respect to the following matters, the Owner Trustee shall not take action unless at least 30 days before the taking of such action, the Owner Trustee shall have notified the Certificateholders in writing of the proposed action and the Owners shall not have notified the Owner Trustee in writing prior to the 30th day after such notice is given that such Owners have withheld consent or provided alternative direction: (a) the initiation of any claim or lawsuit by the Issuer (except claims or lawsuits brought in connection with the collection of the Receivables) and the compromise of any action, claim or lawsuit brought by or against the Issuer (except with respect to the aforementioned claims or lawsuits for collection of the Receivables); (b) the election by the Issuer to file an amendment to the Certificate of Trust (unless such amendment is required to be filed under the Statutory Trust Statute); (c) the amendment of the Indenture by a supplemental indenture in circumstances where the consent of any Noteholder is required; (d) the amendment of the Indenture by a supplemental indenture in circumstances where the consent of any Noteholder is not required and such amendment materially adversely affects the interests of the Owners; (e) the amendment, change or modification of the Administration Agreement, except to cure any ambiguity or to amend or supplement any provision in a manner or add any provision that would not materially adversely affect the interests of the Owners; or (f) the appointment pursuant to the Indenture of a successor Note Registrar, paying agent for the Notes or Indenture Trustee or pursuant to this Agreement of a successor Certificate Registrar, or the consent to the assignment by the Note Registrar, Paying Agent, Indenture Trustee or Certificate Registrar of its obligations under the Indenture or this Agreement, as applicable.

  • Amendments, etc. with Respect to the Obligations; Waiver of Rights The Guarantor shall remain obligated hereunder notwithstanding that, without any reservation of rights against the Guarantor, and without notice to or further assent by the Guarantor, any demand for payment of any of the Obligations made by the Administrative Agent or any Lender may be rescinded by the Administrative Agent or such Lender, and any of the Obligations continued, and the Obligations, or the liability of any other party upon or for any part thereof, or any collateral security or guarantee therefor or right of offset with respect thereto, may, from time to time, in whole or in part, be renewed, extended, amended, modified, accelerated, compromised, waived, surrendered or released by the Administrative Agent or any Lender, and the Credit Agreement, any other Loan Document and any other documents executed and delivered in connection therewith may be amended, modified, supplemented or terminated, in whole or in part, as the Administrative Agent (or the Required Lenders, as the case may be) may deem advisable from time to time, and any guarantee or right of offset at any time held by the Administrative Agent or any Lender for the payment of the Obligations may be sold, exchanged, waived, surrendered or released. Neither the Administrative Agent nor any Lender shall have any obligation to protect, secure, perfect or insure any Lien at any time held by it as security for the Obligations or for this Guarantee or any property subject thereto and the Guarantor hereby waives any defense based on any acts or omissions of the Administrative Agent or any Lender in the administration of the Obligations, any guarantee or other liability in respect thereof or any security for the Obligations or this Guarantee. When making any demand hereunder against the Guarantor, the Administrative Agent or any Lender may, but shall be under no obligation to, make a similar demand on the Borrower or any other guarantor, and any failure by the Administrative Agent or any Lender to make any such demand or to collect any payments from the Borrower or any such other guarantor or any release of the Borrower or such other guarantor shall not relieve the Guarantor of its obligations or liabilities hereunder, and shall not impair or affect the rights and remedies, express or implied, or as a matter of law, of the Administrative Agent or any Lender against the Guarantor. For the purposes hereof “demand” shall include the commencement and continuance of any legal proceedings.

  • Other Agreements with Respect to Indemnification and Contribution The provisions of this Section 10 hereof shall not affect any agreements among the Fund and the Manager with respect to indemnification of each other or contribution between themselves.

  • Amendments, Etc. With Respect to the Obligations Each Guarantor shall remain obligated hereunder notwithstanding that, without any reservation of rights against any Guarantor and without notice to or further assent by any Guarantor, any demand for payment of any of the Obligations made by the Purchasers may be rescinded by the Purchasers and any of the Obligations continued, and the Obligations, or the liability of any other Person upon or for any part thereof, or any collateral security or guarantee therefor or right of offset with respect thereto, may, from time to time, in whole or in part, be renewed, extended, amended, modified, accelerated, compromised, waived, surrendered or released by the Purchasers, and the Purchase Agreement and the other Transaction Documents and any other documents executed and delivered in connection therewith may be amended, modified, supplemented or terminated, in whole or in part, as the Purchasers may deem advisable from time to time, and any collateral security, guarantee or right of offset at any time held by the Purchasers for the payment of the Obligations may be sold, exchanged, waived, surrendered or released. The Purchasers shall have no obligation to protect, secure, perfect or insure any Lien at any time held by them as security for the Obligations or for the guarantee contained in this Section 2 or any property subject thereto.

  • Other Agreements with Respect to Indemnification The provisions of this Section shall not affect any agreement among the Company and the Selling Shareholders with respect to indemnification.