Incorrect Logic, Durations, Sequences, or Critical Path Sample Clauses

The 'Incorrect Logic, Durations, Sequences, or Critical Path' clause addresses errors or discrepancies in the scheduling and planning aspects of a project. It typically applies to situations where the project schedule contains mistakes in task dependencies, estimated durations, the order of activities, or the identification of critical path tasks. For example, if a task is scheduled to start before its prerequisite is completed, or if the critical path is misidentified, this clause would require correction. Its core function is to ensure the project schedule is accurate and reliable, thereby minimizing delays and misunderstandings that could arise from flawed planning.
Incorrect Logic, Durations, Sequences, or Critical Path. The Owner may reject or indicate durations, sequences, critical path or logic are not acceptable and request changes. The electronic copy of the schedule shall have adequate information so logic ties, duration, sequences and critical path may be reviewed electronically. Contractor is to diligently rebuild and resubmit the schedule to represent the Contractor's plan to complete the Work and maintain milestones at the next Progress meeting, or before the next progress meeting. If Contractor is not able to build a schedule that is acceptable to the Owner or Architect, the Owner reserves the right to utilize the unapproved originally submitted Baseline (See Article 8.3.2.12) and the comments submitted to hold Contractor accountable for timely delivery of Work and maintenance of Milestones. Furthermore, Contractor's representations in Baseline, if unacceptable, may also be used as a basis for termination of the Contract under Article 14 if Contractor fails to adequately maintain the schedule and falls significantly behind without undertaking the efforts to either submit and follow a recovery schedule or fail to submit a recovery schedule and make no effort toward recovery on the Project.
View SourceView Similar (3)
Incorrect Logic, Durations, Sequences, or Critical Path. The Owner may reject or indicate durations, sequences, critical path or logic are not acceptable and request changes. The electronic copy of the schedule shall have adequate information so logic ties, duration, sequences and critical path may be reviewed electronically. Contractor is to diligently rebuild and resubmit the schedule to represent the Contractor's plan to complete the Work and maintain milestones at the next Progress meeting, or before the next progress meeting. If Contractor is not able to build a schedule that is acceptable to the Owner or Architect, the Owner reserves the right to utilize the unapproved originally submitted Baseline (See Article 8.
View Source
Incorrect Logic, Durations, Sequences, or Critical Path. The Owner may reject or indicate durations, sequences, critical path or logic in the Baseline or Updated Schedule are not acceptable and request changes. The electronic copy of the Schedules shall have adequate information so logic ties, duration, sequences and critical path may be reviewed electronically. Trade Contractor is to diligently rebuild and resubmit the Schedules to represent the Design-Builder’s plan to complete the Work and maintain Milestones at the next progress meeting, or before the next progress meeting. If Design-Builder is not able to build a schedule that is acceptable to the Owner, the Owner reserves the right to build an acceptable Baseline Schedule from the information received.
View Source

Related to Incorrect Logic, Durations, Sequences, or Critical Path

  • Interconnection Customer Compensation for Actions During Emergency Condition The CAISO shall compensate the Interconnection Customer in accordance with the CAISO Tariff for its provision of real and reactive power and other Emergency Condition services that the Interconnection Customer provides to support the CAISO Controlled Grid during an Emergency Condition in accordance with Article 11.6.

  • Benchmarks for Measuring Accessibility For the purposes of this Agreement, the accessibility of online content and functionality will be measured according to the W3C’s Web Content Accessibility Guidelines (WCAG) 2.0 Level AA and the Web Accessibility Initiative Accessible Rich Internet Applications Suite (WAI-ARIA) 1.0 for web content, which are incorporated by reference.

  • Performance Deficiencies If the City or the Quality Control Manager determine in their reasonable belief that any of the Infrastructure Improvements are not being constructed in accordance with the Infrastructure Improvement Plans or this Agreement in any material respect, they shall immediately notify RCP and Bliss Sports II in writing stating the alleged deficiency and the City, the Quality Control Manager, the Architect, RCP and Bliss Sports II will meet within seven (7) days of the giving of such notice to discuss whether the Infrastructure Improvements are not being constructed in accordance with the Infrastructure Improvement Plans or this Agreement in any material respect and, if the City, RCP and Architect agree that they are not, then RCP shall cause Bliss Sports II to correct such deficiencies. The failure by the City to provide any notice of any observed deficiency shall not give rise to any liability to the City and shall not be considered a waiver of any right of the City under this Agreement, including, without limitation, the enforcement of the representations and warranties of Bliss Sports II under this Agreement and any warranties that may be made to the City by any Contracting Parties under the Infrastructure Construction Contract Documents with respect to the completion of the Infrastructure Improvements in accordance with the Infrastructure Improvement Plans and the Project Timeline.

  • Additional Acceptable Uses of Student Data Contractor is prohibited from using Student Data for any secondary use not described in this agreement except: a. for adaptive learning or customized student learning purposes; b. to market an educational application or product to a parent or legal guardian of a student if Contractor did not use Data, shared by or collected per this Contract, to market the educational application or product; c. to use a recommendation engine to recommend to a student i. content that relates to learning or employment, within the third-party contractor's internal application, if the recommendation is not motivated by payment or other consideration from another party; or

  • Professional Development; Adverse Consequences of School Exclusion; Student Behavior The Board President or Superintendent, or their designees, will make reasonable efforts to provide ongoing professional development to Board members about the adverse consequences of school exclusion and justice-system involvement, effective classroom management strategies, culturally responsive discipline, appropriate and available supportive services for the promotion of student attendance and engagement, and developmentally appropriate disciplinary methods that promote positive and healthy school climates, i.e., Senate Bill 100 training topics. The Board will conduct periodic self-evaluations with the goal of continuous improvement. New Board Member Orientation The orientation process for newly elected or appointed Board members includes: