Installation Procedures. (i) Prior to installation of Tenant's Rooftop Facilities and any modifications or changes thereto, Tenant shall submit to Landlord in writing all plans for Landlord's approval, and may only commence the installation after having obtained Landlord's written approval, which shall not be unreasonably withheld, conditioned, or delayed. The size, weight, style, type, materials, exact location, method of installation and other matters related to Tenant's Rooftop Facilities shall be subject to the prior written approval of Landlord, which shall not be unreasonably withheld, conditioned, or delayed. Landlord may supervise any roof work, provided Landlord does not unreasonably interfere with or delay Tenant exercising its rights or satisfying its obligations hereunder. (ii) In the event Tenant requires a supplemental electric power supply and/or usage in connection with Tenant's Rooftop Facilities, Tenant shall, at its sole cost and expense, obtain such supplemental power supply and pay any and all recurring charges associated with such supplemental power supply at the actual cost charged by the utility without ▇▇▇▇-up by Landlord. Any work performed in connection therewith shall comply with the provisions of the Lease. (iii) Landlord shall provide to Tenant reasonable access to the roof of the Building and other affected Common Areas of the Building to permit Tenant's maintenance and operation of Tenant's Rooftop Facilities as provided for herein. Access to the roof of the Building or other areas of the Building will be available by Tenant requesting access from Landlord according to the Building Rules and Regulations, and Landlord agrees to cooperate reasonably with Tenant in connection therewith. Tenant shall reimburse Landlord for all reasonable and actual costs and expenses incurred by Landlord with respect to any such access occurring at times other than the normal business hours of the Building. All such access to the roof of the Building and/or other Common Areas of the Building shall be subject to the continuing control of, and reasonable security and safety procedures established by, Landlord. (iv) Tenant's Rooftop Facilities (in particular, the antenna) shall not be more than [*****] in height above the parapet wall and not more than the weight that Landlord shall reasonably determine is appropriate for the roof (which Landlord shall specify to Tenant promptly upon Tenant's written request).
Appears in 1 contract
Installation Procedures. (i) Prior to installation of Tenant's Rooftop Facilities the Antenna Equipment and any modifications or changes thereto, Tenant shall submit to Landlord in writing all plans for Landlord's approvalapproval to Landlord, Attention: Vice President, Network and may Facilities, at 10 W▇▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇, ▇▇▇▇▇▇▇▇▇▇, ▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇ ▇▇▇ shall commence work only commence the installation after having obtained Landlord's written approval, which shall not be unreasonably withheld, conditioned, or delayed. The size, weight, style, typecolor, materials, exact location, location and method of installation and other matters related to Tenant's Rooftop Facilities shall be of the Antenna Equipment are subject to the prior written approval approved of Landlord, which shall not be unreasonably withheld, conditioned, or delayed. Landlord may supervise any roof work, provided Landlord does not unreasonably interfere with or delay Tenant exercising its rights or satisfying its obligations hereunder.
(ii) All of such installations, modifications or changes shall conform to Landlord's reasonable technical requirements, including but not limited to, design and installation specifications, interference control devices and weight and windload requirements.
(iii) The Antenna Equipment shall be clearly marked to show Tenant's name, address, telephone number, the name of the person to contact in case of emergency, FCC call sign, frequency and location; the transmissions lines shall be identified at the bottom and top of each line.
(iv) In the event Tenant requires a supplemental an electric power supply and/or usage in connection with Tenant's Rooftop Facilitiesdifferent from that currently provided by Landlord and included within the Base Fee, Tenant shall, at its sole cost and expense, obtain such supplemental power supply and pay any and all recurring charges associated with such supplemental power supply at the actual cost charged by the utility without ▇▇▇▇-up by Landlordsupply. Any work performed in connection therewith shall comply with the provisions of the Leasesubsections 5(a) and 5(b). Any power lines installed by Tenant shall run within Landlord's current easements. Any deviation from such easement rights shall be corrected at Tenant's expense, payable as an additional fee hereunder within ten (10) days of Tenant's receipt of an invoice therefor.
(v) In the event a zoning variance is required in connection with the installation or modification of the Antenna Equipment, Landlord shall have the right, at its discretion, to allow Tenant to obtain such variance at Tenant's sole cost and expense, provided however, that such variance and/or the conditions under which such variance would be granted shall in no way impair or affect the zoning otherwise affecting the Land and/or the Building. Landlord shall, at Tenant's request and expense, reasonably cooperate with Tenant in obtaining such variance.
(vi) In all matters where Landlord's approval is required and where Landlord makes a reasonable determination that interference or other disruption with the business of Landlord or other existing licensees is likely to result from Tenant's contemplated action, Landlord shall have the right to withhold such approval by written notice to Tenant, setting forth in reasonable detail the basis for Landlord's disapproval.
(vii) All work performed at the Building in connection with the installation and modification of the Antenna Equipment shall be performed at Tenant's expense by Tenant's employees or by contractors approved by Landlord in its good faith judgement; provided, however, at Landlord's sole election, Landlord shall be entitled to designate a contractor (which contractor has been selected by Tenant from a list of at least three contractors prepared by Landlord) to perform any such installation or modification that in Landlord's judgement may (i) affect the structure of the Building, the roof of the Building, the warranty for the roof of the Building or the safety of the Building; (ii) affect the electrical, mechanical or any other system of the Building or the functioning thereof; or (iii) interfere with the operation of the Building or the provision of services or utilities to Tenant or other tenants in the Building.
(viii) Landlord shall provide to Tenant reasonable sufficient access to the roof of Site during specified business hours (Monday through Friday 8:30 a.m. - 5:00 p.m.) for the Building and other affected Common Areas of the Building to permit Tenant's maintenance and operation of Tenant's Rooftop Facilities as provided for herein. Access to the roof of the Building or other areas of the Building will be available by Tenant requesting access from Landlord according to the Building Rules and Regulations, and Landlord agrees to cooperate reasonably with Tenant in connection therewith. Tenant shall reimburse Landlord for all reasonable and actual costs and expenses incurred by Landlord with respect to any such access occurring at times other than the normal business hours of the Building. All such access to the roof of the Building and/or other Common Areas of the Building shall be subject to the continuing control of, and reasonable security and safety procedures established by, Landlord.
(iv) Tenant's Rooftop Facilities (in particular, the antenna) shall not be more than [*****] in height above the parapet wall and not more than the weight that Landlord shall reasonably determine is appropriate for the roof (which Landlord shall specify to Tenant promptly upon Tenant's written request).
Appears in 1 contract