Installation; Strict Compliance with Approved Plans Sample Clauses

Installation; Strict Compliance with Approved Plans. Licensee shall not commence any work at the License Area until the City provides Licensee with the Acknowledgement Letter or an equivalent letter to confirm the Commencement Date. Licensee shall perform all work in connection with the License Area in strict compliance with the Approved Plans and in a diligent, skillful and workmanlike manner. All installed Equipment must be high quality, safe, fire resistant, modern in design and attractive in appearance, all as approved by the City. After any work at the License Area concludes, Licensee shall restore the License Area and any other City Property to the condition that existed immediately prior to the work commenced.
View Source
Installation; Strict Compliance with Approved Plans. Licensee shall not commence any work at the License Area until the City provides an NTP with an executed Site License and the approved construction encroachment permit attached. Licensee shall perform all work in connection with the License Area in strict compliance with the approved permits and in a diligent, skillful and workmanlike manner. All installed Equipment shall be compliant with the Design Guidelines. After any work by Licensee at the License Area concludes, Licensee shall restore the License Area and any other City Property affected by such work to the condition that existed immediately prior to the work commenced, normal wear and tear excepted.
View Source

Related to Installation; Strict Compliance with Approved Plans

  • Compliance with Accessibility Standards All parties to this Agreement shall ensure that the plans for and the construction of all projects subject to this Agreement are in compliance with standards issued or approved by the Texas Department of Licensing and Regulation (TDLR) as meeting or consistent with minimum accessibility requirements of the Americans with Disabilities Act (P.L. 101-336) (ADA).

  • Lessee's Compliance with Applicable Requirements Except as otherwise provided in this Lease, Lessee shall, at Lessee's sole expense, fully, diligently and in a timely manner, materially comply with all Applicable Requirements, the requirements of any applicable fire insurance underwriter or rating bureau, and the recommendations of Lessor's engineers and/or consultants which relate in any manner to the Premises, without regard to whether said requirements are now in effect or become effective after the Start Date. Lessee shall, within ten (10) days after receipt of Lessor's written request, provide Lessor with copies of all permits and other documents, and other information evidencing Lessee's compliance with any Applicable Requirements specified by Lessor, and shall immediately upon receipt, notify Lessor in writing (with copies of any documents involved) of any threatened or actual claim, notice, citation, warning, complaint or report pertaining to or involving the failure of Lessee or the Premises to comply with any Applicable Requirements.

  • Suspension of unsafe Construction Works (i) Upon recommendation of the Authority’s Engineer to this effect, the Authority may by notice require the Contractor to suspend forthwith the whole or any part of the Works if, in the reasonable opinion of the Authority’s Engineer, such work threatens the safety of the Users and pedestrians. (ii) The Contractor shall, pursuant to the notice under Clause 11.17 (i), suspend the Works or any part thereof for such time and in such manner as may be specified by the Authority and thereupon carry out remedial measures to secure the safety of suspended works, the Users and pedestrians. The Contractor may by notice require the Authority’s Engineer to inspect such remedial measures forthwith and make a report to the Authority recommending whether or not the suspension hereunder may be revoked. Upon receiving the recommendations of the Authority’s Engineer, the Authority shall either revoke such suspension or instruct the Contractor to carry out such other and further remedial measures as may be necessary in the reasonable opinion of the Authority, and the procedure set forth in this Clause 11.17 shall be repeated until the suspension hereunder is revoked. (iii) Subject to the provisions of Clause 21.6, all reasonable costs incurred for maintaining and protecting the Works or part thereof during the period of suspension (the “Preservation Costs”), shall be borne by the Contractor; provided that if the suspension has occurred as a result of any breach of this Agreement by the Authority, the Preservation Costs shall be borne by the Authority. (iv) If suspension of Works is for reasons not attributable to the Contractor, the Authority’s Engineer shall determine any Time Extension to which the Contractor is reasonably entitled.

  • Compliance with Applicable Requirements In carrying out its obligations under this Agreement, the Sub-Adviser shall at all times comply with: (a) all applicable provisions of the 1940 Act, and any rules and regulations adopted thereunder; (b) the provisions of the registration statement of the Trust, as it may be amended or supplemented from time to time, under the Securities Act and the 1940 Act; (c) the provisions of the Declaration of Trust of the Trust, as it may be amended or supplemented from time to time; (d) the provisions of any By-laws of the Trust, if adopted and as it may be amended from time to time, or resolutions of the Board as may be adopted from time to time; (e) the provisions of the Internal Revenue Code of 1986, as amended, applicable to the Trust or the Funds; (f) any other applicable provisions of state or federal law; and In addition, any code of ethics adopted by the Sub-Adviser must comply with Rule 17j-1 under the 1940 Act, as it may be amended from time to time, and any broadly accepted industry practices, if requested by the Trust or the Adviser.

  • DECLARATION OF COMPLIANCE WITH APPLICABLE STANDARDS 1. Does the Work report experiments involving human subjects? [ ] YES [ ] NO  If Yes, were the reported experiments in accordance with the ethical standards of the committee responsible for human experimentation (institutional and national), and with the Helsinki Declaration of 1975, as revised in 2013 (▇▇▇▇://▇▇▇▇▇▇.▇▇▇.▇▇▇/ecodes/node/3931 )? [ ] YES [ ] NO (If Yes, the Assignor must submit a copy of the approval and consent-to-disclose form to ▇▇▇▇▇▇▇ Science Publishers by fax or email.) Please state whether Ethical Approval was given, by whom and the relevant Judgement’s reference number. (If No, the Assignor must mention an institutional or regional guideline.) 2. Does the Work report experiments involving animals? [ ] YES [ ] NO  If Yes, were the reported experiments in accordance with the standards set forth in one of below national guidelines and regulations: o The US National Research Council's "Guide for the Care and Use of Laboratory Animals," o The US Public Health Service's "Policy on Humane Care and Use of Laboratory Animals," and "Guide for the Care and Use of Laboratory Animals." o UK : the Animals (Scientific Procedures) Act 1986 Amendment Regulations (SI 2012/3039). [ ] YES [ ] NO 6 [v.122016] Conflicts of interest arise when authors, reviewers, or editors have interests (such as financial or personal interests) that are not made clear and that may influence their judgment on the content of their work. Authors and editors who submit work for publication with ▇▇▇▇▇▇▇ Science are required to disclose and acknowledge all forms of financial support relating to the work to be published, all commercial or financial involvement that might present an appearance of a conflict of interest in respect of the work, and all agreements relating to sponsorship of any research upon which the work is based. Are there any actual, or potential, conflicts of interest? [ ] YES [ ] NO If Yes, details of the actual or potential conflicts of interest must be set-out in the spaces provided below. Does Assignor require assistance in having the English grammar and style of the Work checked and improved by ▇▇▇▇▇▇▇ Science? [ ] YES [ ] NO If Yes, ▇▇▇▇▇▇▇ Science will provide a quote in respect of the same.