Access to the Authority and the Authority’s Engineer (i) The Right of Way given to the Contractor hereunder shall always be subject to the right of access of the Authority and the Authority’s Engineer and their employees and agents for inspection, viewing and exercise of their rights and performance of their obligations under this Agreement.
(ii) The Contractor shall ensure, subject to all relevant safety procedures, that the Authority has un-restricted access to the Site during any emergency situation, as decided by the Authority’s Engineer.
Obligations of the Authority (i) The Authority shall, at its own cost and expense, undertake, comply with and perform all its obligations set out in this Agreement or arising hereunder.
(ii) The Authority shall be responsible for the correctness of the Scope of the Project, Project Facilities, Specifications and Standards and the criteria for testing of the completed Works.
(iii) The Authority shall, upon submission of the Performance Security as per the RFP by the Contractor, shall provide to the Contractor:
(a) No less than 90% (ninety per cent) of the required Right of Way of the Construction Zone of total length of the Project Highway within a period of 30 (thirty) days from the date of this Agreement, which shall be in contiguous stretches of length not less than 1( One) kilometre.
(b) approval of the general arrangement drawings (the “GAD”) from railway authorities to enable the Contractor to construct road over- bridges/ under- bridges at level crossings on the Project Highway in accordance with the Specifications and Standards, and subject to the terms and conditions specified in such approval, within a period of 60 (sixty) days from the Appointed Date, and reimbursement of all the costs and expenses paid by the Contractor to the railway authorities for and in respect of the road over- bridges/ under bridges; and7
(c) all environmental clearances as required under Clause 4.3.8
(iv) Delay in providing the Right of Way or approval of GAD by railway authorities, as the case may be, in accordance with the provisions of Clause 3.1 (iii) shall entitle the Contractor to Damages in a sum calculated in accordance with the provisions of Clause 8.3 of this Agreement and Time Extension in accordance with the provisions of Clause 10.5 of this Agreement. For the avoidance of doubt, the Parties agree that the Damages for delay in approval of GAD by the railway authorities for a particular road over-bridge/ under-bridge shall be deemed to be equal to the Damages payable under the provisions of Clause 8.3 for delay in providing Right of Way for a length of 2 (two) kilometre for each such road over-bridge/ under-bridge.
Representations of the Adviser 4.1. The Adviser has all requisite power and authority to enter into and perform its obligations under this Agreement, and has taken all necessary corporate action to authorize its execution, delivery and performance of this Agreement.
4.2. The Adviser is registered as an investment adviser under the Advisers Act. None of the Adviser, its affiliates, or any officer, manager, partner or employee of the Adviser or its affiliates is subject to any event set forth in Section 9 of the 1940 Act that would disqualify the Adviser from acting as an investment adviser to an investment company under the 1940 Act. The Adviser will promptly notify the Sub-Adviser upon the Adviser’s discovery of an occurrence of any event that would disqualify the Adviser from serving as an investment adviser of an investment company pursuant to Section 9(a) of the 1940 Act or otherwise. The Adviser agrees to comply with the requirements of the 1940 Act, the Advisers Act, the 1933 Act, the Securities Exchange Act of 1934, as amended, the Commodity Exchange Act and the rules and regulations thereunder, as applicable, as well all other applicable federal and state laws, rules, regulations and case law that relate to the Adviser’s services described hereunder and the to the conduct of its business as a registered investment adviser and to maintain all licenses and registrations necessary to perform its duties hereunder in good order. The Adviser shall maintain compliance procedures that it reasonably believes are adequate to ensure its compliance with the foregoing.
4.3. The Adviser has the authority under the Investment Advisory Agreement to appoint the Sub-Adviser.
4.4. The Adviser further represents and warrants that it has received a copy of the Sub-Adviser’s current Form ADV.
4.5. The Adviser has provided the Sub-Adviser with each Fund’s most current prospectus and statement of additional information contained in the Trust’s registration statement and the Investment Policies, as in effect from time to time. The Adviser shall promptly furnish to the Sub-Adviser copies of all material amendments or supplements to the foregoing documents.
4.6. The Adviser or its delegate will provide timely information to the Sub-Adviser regarding such matters as inflows to and outflows from each Fund and the cash requirements of, and cash available for investment in, the Fund.
4.7. The Adviser or its delegate will timely provide the Sub-Adviser with copies of monthly accounting statements for each Fund, and such other information as may be reasonably necessary or appropriate in order for the Sub-Adviser to perform its responsibilities hereunder.
Obligations of the Academy Trust The Academy Trust must keep the Land clean and tidy and make good any damage or deterioration to the Land. The Academy Trust must not do anything to lessen the value or marketability of the Land without the Secretary of State’s consent.
Representations of the Manager The Manager represents, warrants and agrees that:
(i) Manager is a Delaware limited liability company established pursuant to the laws of the State of Delaware;
(ii) Manager is duly registered as an “investment adviser” under the Investment Advisers Act of 1940 (“Advisers Act”);
(iii) Manager has been duly appointed by the Trustees and Shareholders of the Fund to provide investment services to the Fund as contemplated by the Management Contract.
(iv) the execution, delivery and performance of this Agreement are within Manager’s powers, have been and remain duly authorized by all necessary corporate action and will not violate or constitute a default under any applicable law or regulation or of any decree, order, judgment, agreement or instrument binding on Manager;
(v) no consent (including, but not limited to, exchange control consents) of any applicable governmental authority or body is necessary, except for such consents as have been obtained and are in full force and effect, and all conditions of which have been duly complied with; and
(vi) this Agreement constitutes a legal, valid and binding obligation enforceable against Manager.