Payment of Additional Costs If termination of this contract is due to the failure of the Engineer to fulfill its contract obligations, the State may take over the project and prosecute the work to completion, and the Engineer shall be liable to the State for any additional cost to the State.
BUILDER’S RISK FOR CONSTRUCTION RENOVATION PROJECTS If the project is CONSTRUCTION RENOVATION of an existing structure, and the State has already determined that Contractor will not be obligated to obtain and maintain Builder’s Risk insurance, then the following provisions apply:
(1) The State will maintain property insurance upon the construction site and will not require Contractor to purchase and maintain Builder's Risk Insurance upon the entire work at the site.
(2) The decision of the State to waive the requirement that the Contractor maintain builder’s risk coverage does not waive Contractor’s liability for damage to the State’s real and personal property. Contractor’s liability for loss to the State’s real and personal property will be limited to the first $100,000 of each and every property loss at the work site provided such loss is covered under the State’s property insurance coverage. If the Contractor elects to meet this obligation by purchase of commercial insurance, this insurance shall name the Contractor and the State of Vermont as Named Insureds and shall include the interests of the Contractor and Subcontractors. Other parties shall be insured as the State may reasonably require.
(3) Contractor shall effect and maintain insurance on portions of the work stored off-site, on site and in transit. Boiler & Machinery Insurance may be used in conjunction with this coverage if it is required to meet the testing requirement. The cost of any deductible applicable to loss covered by insurance provided hereunder shall be borne by the Contractor.
(4) Except as provided for in 11.2.2 (1)-(3) above the State and Contractor waive all rights against each other and the Subcontractor, Sub-subcontractors, agents and employees of the other.
SCOPE, WAIVER AND ALTERATION OF AGREEMENT (1) No agreement, alteration, understanding, variation, waiver or modification of any of the terms and conditions or covenants herein shall be made by any employee or group of employees with the Board unless executed in writing between the parties hereto and the same has been ratified by the Union and the Board.
(2) The waiver of any breach or condition of this Agreement by either party shall not constitute a precedent in the future enforcement of the terms and conditions herein.
(3) If any Article or Section of this Agreement or any supplement thereto should be held invalid by operation of law or by any tribunal of competent jurisdiction, or if compliance with or enforcement of any Article or Section should be restrained by such tribunal, the remainder of this Agreement and supplements shall not be affected thereby and the parties shall enter into immediate collective bargaining negotiations for the purpose of arriving at a mutually satisfactory replacement for such Article or Section.
Amendments; Waivers; No Additional Consideration No provision of this Agreement may be waived or amended except in a written instrument signed by the Company, Parent and the Shareholders. No waiver of any default with respect to any provision, condition or requirement of this Agreement shall be deemed to be a continuing waiver in the future or a waiver of any subsequent default or a waiver of any other provision, condition or requirement hereof, nor shall any delay or omission of any Party to exercise any right hereunder in any manner impair the exercise of any such right.
Construction of Agreement The parties mutually acknowledge that they and their attorneys have participated in the preparation and negotiation of this Agreement. In cases of uncertainty this Agreement shall be construed without regard to which of the parties caused the uncertainty to exist.