NO EQUITABLE ADJUSTMENT Sample Clauses

The "No Equitable Adjustment" clause establishes that the parties agree not to seek changes in contract price, schedule, or other terms due to unforeseen circumstances or events not explicitly covered in the contract. In practice, this means that if unexpected costs or delays arise, the affected party cannot request additional compensation or time extensions unless the contract specifically allows for such adjustments. This clause serves to allocate risk by making each party responsible for managing their own unforeseen costs, thereby providing certainty and predictability in contract performance and administration.
NO EQUITABLE ADJUSTMENT. Design-Builder’s remedies are limited to those remedies specified herein. To the fullest extent permitted by law, Design-Builder agrees that it is not entitled nor will it seek equitable adjustment of any of the terms of this Contract including but not limited to Contract time and compensation. This provision shall take precedence over any conflicting Contract provisions.
View SourceView Similar (9)

Related to NO EQUITABLE ADJUSTMENT

  • Equitable Adjustment The Department may, in its sole discretion, make an equitable adjustment in the Term Contract terms or pricing if pricing or availability of supply is affected by extreme and unforeseen volatility in the marketplace, that is, by circumstances that satisfy all the following criteria: (1) the volatility is due to causes wholly beyond the Contractor’s control, (2) the volatility affects the marketplace or industry, not just the particular Term Contract source of supply, (3) the effect on pricing or availability of supply is substantial, and (4) the volatility so affects the Contractor that continued performance of the Term Contract would result in a substantial loss.

  • Equitable Adjustments (1) If the Contracting Officer confirms that Government conduct effected a change as alleged by the Contractor, and the conduct causes an increase or decrease in the Contractor's cost of, or the time required for, performance of any part of the work under this contract, whether changed or not changed by such conduct, an equitable adjustment shall be made-- (i) In the contract price or delivery schedule or both; and (ii) In such other provisions of the contract as may be affected. (2) The contract shall be modified in writing accordingly. In the case of drawings, designs or specifications which are defective and for which the Government is responsible, the equitable adjustment shall include the cost and time extension for delay reasonably incurred by the Contractor in attempting to comply with the defective drawings, designs or specifications before the Contractor identified, or reasonably should have identified, such defect. When the cost of property made obsolete or excess as a result of a change confirmed by the Contracting Officer under this clause is included in the equitable adjustment, the Contracting Officer shall have the right to prescribe the manner of disposition of the property. The equitable adjustment shall not include increased costs or time extensions for delay resulting from the Contractor's failure to provide notice or to continue performance as provided, respectively, in (b) and (c) above.

  • True-Up Adjustments From time to time, until the Retirement of the Recovery Bonds, the Servicer shall identify the need for True-Up Adjustments and shall take all reasonable action to obtain and implement such True-Up Adjustments, all in accordance with the following:

  • Equitable Adjustments to Prices Whenever any provision of this Indenture requires the Company to calculate the average of the Last Reported Sale Prices, or any function thereof, over a period of multiple days (including to calculate the Stock Price or an adjustment to the Conversion Rate), or to calculate Daily VWAPs over an Observation Period, the Company will make proportionate adjustments, if any, to such calculations to account for any adjustment to the Conversion Rate pursuant to Section 5.05(A)(i) that becomes effective, or any event requiring such an adjustment to the Conversion Rate where the Ex-Dividend Date or effective date, as applicable, of such event occurs, at any time during such period or Observation Period, as applicable.

  • Section 754 Adjustment To the extent an adjustment to the adjusted tax basis of any Partnership asset pursuant to Code Section 734(b) or Code Section 743(b) is required, pursuant to Regulations Section 1.704-1(b)(2)(iv)(m)(2) or Regulations Section 1.704-1(b)(2)(iv)(m)(4), to be taken into account in determining Capital Accounts as the result of a distribution to a Holder in complete liquidation of his interest in the Partnership, the amount of such adjustment to the Capital Accounts shall be treated as an item of gain (if the adjustment increases the basis of the asset) or loss (if the adjustment decreases such basis) and such gain or loss shall be specially allocated to the Holders in accordance with their interests in the Partnership in the event that Regulations Section 1.704-1(b)(2)(iv)(m)(2) applies, or to the Holders to whom such distribution was made in the event that Regulations Section 1.704-1(b)(2)(iv)(m)(4) applies.