No Extension of Time. If Owner’s determination proves valid that good cause existed to believe a violation had occurred, Contractor is not entitled to an extension of time for any delay arising directly or indirectly from the arbitration procedures.
Appears in 41 contracts
Sources: Grant Agreement, Grant Agreement, General Construction Services Contract
No Extension of Time. If the Owner’s determination proves valid that good cause existed to believe a violation had occurred, the Contractor is not entitled to an extension of time for any delay arising directly or indirectly from the arbitration proceduresprocedures set forth herein.
Appears in 41 contracts
Sources: Construction Management Agreement, Construction Management Agreement, Design Build Contract
No Extension of Time. If the Owner’s determination proves valid that good cause existed to believe a violation had occurred, the Contractor is not entitled to an extension of time for any delay arising directly or indirectly from the arbitration procedures.
Appears in 21 contracts
Sources: Construction Management Agreement, Construction Management Agreement, Owner and Contractor Agreement
No Extension of Time. If the Owner’s determination proves valid that good cause existed to believe a violation had occurred, the Contractor is not entitled to an extension of time for any delay arising directly or indirectly from of the arbitration proceduresprocedures set forth herein.
Appears in 1 contract
Sources: Contract
No Extension of Time. If Owner’s determination proves valid that good cause existed to believe a violation had occurred, Contractor is not entitled to an extension of time for any delay arising directly or indirectly from the arbitration procedures.
Appears in 1 contract
Sources: Grant Agreement