ODR’s Response Sample Clauses

ODR’s Response. ODR will respond to the Time Extension Request by providing to Contractor written notice of the number of days granted, if any, and giving its reason if this number differs from the number of days requested by Contractor. 9.9.4.1 ODR will not grant time extensions for delays that do not affect the Contract Substantial Completion date. 9.9.4.2 ODR will respond to each properly submitted Time Extension Request within fifteen (15) days following receipt. If ODR cannot reasonably make a determination about Contractor’s entitlement to a time extension within that time, ODR will notify Contractor in writing. Unless otherwise agreed by Contractor, ODR has no more than fifteen (15) additional days to prepare a final response. If the ODR fails to respond within forty-five (45) calendar days from the date the Time Extension Request is received, the Contractor is entitled to a time extension in the amount requested.
View Source

Related to ODR’s Response

  • Company’s Response Upon receipt by the Company of a copy of a Purchase Notice, the Company shall as soon as practicable, but in no event later than one (1) Trading Day after receipt of such Purchase Notice, send via facsimile (or otherwise deliver), a confirmation of receipt of such Purchase Notice in the form attached hereto as Exhibit B (a "Company Confirmation of Purchase Notice") to (1) the Buyer and (2) along with a copy of the Purchase Notice, the Company's designated transfer agent (the "Transfer Agent"), which confirmation shall constitute an irrevocable instruction to the Transfer Agent to process such Purchase Notice in accordance with the terms herein. Upon receipt by the Transfer Agent of a copy of the executed Purchase Notice and a copy of the applicable Company Confirmation of Purchase Notice, the Transfer Agent shall, on the first (1st) Trading Day following the date of receipt of the Company Confirmation of Purchase Notice, (A) provided the Transfer Agent is participating in The Depository Trust Company's ("The DTC") Fast Automated Securities Transfer Program, credit such aggregate number of shares of Common Stock to which the Buyer shall be entitled to the Buyer's or its designee's balance account with The DTC through its Deposit Withdrawal At Custodian ("DWAC") system, or (B) if the Transfer Agent is not participating in The DTC Fast Automated Securities Transfer Program and DWAC system, issue and surrender to a common carrier for overnight delivery to the address as specified in the Purchase Notice, a certificate, registered in the name of the Buyer or its designee, for the number of shares of Common Stock to which the Buyer shall be entitled.

  • Incident Response Operator shall have a written incident response plan that reflects best practices and is consistent with industry standards and federal and state law for responding to a data breach, breach of security, privacy incident or unauthorized acquisition or use of any portion of Data, including PII, and agrees to provide LEA, upon request, an executive summary of the written incident response plan.

  • Emergency Response Partners must develop, maintain, and carry out a response plan for public water system emergencies, including disease outbreaks, spills, operational failures, and water system contamination. Partners must notify DWS in a timely manner of emergencies that may affect drinking water supplies.

  • Form and Timing of Response (a) Intermediary agrees to provide, promptly upon request of the Fund or its designee, the requested information specified in paragraph 1 above. If requested by the Fund or its designee, Intermediary agrees to use best efforts to determine promptly whether any specific person about whom it has received the identification and transaction information specified in paragraph 1 is itself a financial intermediary (“indirect intermediary”) and, upon further request of the Fund or its designee, promptly either (i) provide (or arrange to have provided) the information set forth in paragraph 1 for those shareholders who hold an account with an indirect intermediary or (ii) restrict or prohibit the indirect intermediary from purchasing, in nominee name on behalf of other persons, securities issued by the Fund. (b) Responses required by this paragraph must be communicated in writing and in a format mutually agreed upon by the parties. (c) To the extent practicable, the format for any transaction information provided to the Fund should be consistent with the NSCC Standardized Data Reporting Format

  • Timing of Company Response The Company shall respond to such claimant within 90 days after receiving the claim. If the Company determines that special circumstances require additional time for processing the claim, the Company can extend the response period by an additional 90 days by notifying the claimant in writing, prior to the end of the initial 90-day period, that an additional period is required. The notice of extension must set forth the special circumstances and the date by which the Company expects to render its decision.