Owner’s Right to Modify Clause Samples

POPULAR SAMPLE Copied 2 times
Owner’s Right to Modify. Notwithstanding the Project Schedule, Owner has the right to modify or otherwise change the sequence of the Work and Contractor shall comply therewith and adjust schedules accordingly. If Contractor believes such modification or change causes a delay or acceleration in the completion of the Work, Contractor shall provide written notice to Owner in accordance with Sections 11.6 and/or 11.8 below. Any such modifications or changes in sequence applies only to scheduling and shall not be construed to mean a change in the method or means employed by Contractor for the execution of the Work.
View SourceView Similar (5)
Owner’s Right to Modify. Assets Owner shall have the right to withdraw Assets from the Consultant at Owner's discretion. Withdrawal of Assets by Owner shall terminate the servicing fee earned by Consultant in respect of such Assets unless Consultant has established a verifiable course of action and course of dealing with the Borrower in relation to such Assets that substantially contributes to the final resolution of an Asset or group of Assets in which case, Consultant shall be entitled to any incentive fee that may have been due under the terms of this Agreement.
View Source

Related to Owner’s Right to Modify

  • Right to Modify BNYM may alter, modify or change the Licensed System or any component, code, language, function, format, design, architecture, security measure or other element of whatsoever nature of the Licensed System and implement such alterations, modifications and changes into the Documentation and/or the Licensed System as Updates or Upgrades applicable to Company's continued use of the Licensed System after such implementation; provided, however, at no time shall this section be interpreted in such a manner as to allow BNYM by such alterations, modifications or changes to alter the License granted by Section 2.1 or modify any other service obligation of BNYM under this Agreement.

  • Owner’s Right to Stop Work The Owner reserves the right, for itself and for any designated Construction Inspector retained by Owner, upon observation of apparent nonconforming Work, to immediately stop the affected Work. If the Work is later determined by the Design Professional to be in fact conforming Work, then Contractor shall be entitled upon timely claim to a Change Order for payment by Owner of any reasonable Actual Costs actually incurred by Contractor in connection with the stop Work order and resumption of the Work, as well as an extension in the time for performance of the Work to the extent Contractor is delayed by Owner's stop Work order. The Design Professional shall determine the time, which shall be binding upon both Owner and Contractor, as set forth in Section 3, Part 3.

  • Owner’s Right to Make Changes Without invalidating the Contract, the Owner, by Change Order and without notice to the sureties, may authorize or order extra work or changes by altering, adding to, or deducting from the Work or the Contract Time, the Contract Sum being adjusted accordingly. All Change Orders shall be performed under the conditions of the original Contract except that any claim for extension of time caused thereby shall be adjusted at the time of signing of the Change Order. (See Change Order formats in Section 7.) Prior to the issuance of the Proceed Order, the Contractor and the Owner shall advise each other in writing of their designees authorized to accept and approve changes to the Contract Sum and the limits to each designee's authority. Should any designee or limits of authority change during the time this Contract is in effect, the Contractor or Owner shall give written notice to the other as provided in Article 1.

  • BUYER’S RIGHT TO CANCEL If after completion of an appraisal by a licensed appraiser, Buyer receives written notice from the Lender or the appraiser that the Property has appraised for less than the Purchase Price (a “Notice of Appraised Value”), Buyer may cancel the REPC by providing written notice to Seller (with a copy of the Notice of Appraised Value) no later than the Financing & Appraisal Deadline referenced in Section 24(c); whereupon the ▇▇▇▇▇▇▇ Money Deposit shall be released to Buyer without the requirement of further written authorization from Seller.

  • Owner’s Rights B.1.1 The Owner shall have the right to perform work related to the project and to award contracts in connection with the project that are not part of the Consultant’s responsibilities under the AGREEMENT. The consultant shall notify the Owner in writing if any such independent action will in any way compromise the Consultants’ ability to meet their responsibilities under the AGREEMENT. B.1.2 The Owner reserves the right to approve the consultant’s personnel and to require a replacement satisfactory to the Owner. The Owner reserves the right to have such person replaced if, in the judgment of the Owner, any such person proves unsatisfactory. However, such replacement must fit within the rate/fee structure; in the alternative, the Owner shall have the option for a higher rate person for which the Consultant shall be compensated at the higher rate. B.1.3 The Owner shall have the right to effect the removal of any of the Consultant’s employees at any time during the duration of the AGREEMENT if that employee is deemed not to be of the level of competence or ability required under the AGREEMENT, or said employee is for any reason found to be unsuitable for the work. In such case, the Consultant shall promptly submit the name and qualifications of a replacement for approval by the Owner. B.1.4 The Owner shall have the right to assign the administration of any or all contracts related to this project from the Owner to another State Agency, Authority or Commission at any time during the life of the project. In doing so, the Consultant agrees to continue to perform all contractual work under the AGREEMENT. The Consultant shall make no claim against the Owner in the event of such assignment. B.1.5 The Owner may make changes in the scope of services within the general scope of the AGREEMENT. The Owner may also make changes to the scope of the project which may give rise to changes in the scope of the Consultant services. In such case, the Consultant shall be entitled to an adjustment in fee and in other terms and conditions of the AGREEMENT.