Performance Obligations Sample Clauses

Performance Obligations. The Purchaser shall have performed in all respects all obligations required to be performed by it under this Agreement at or prior to the Closing.

Performance Obligations. The Contractor must meet all performance criteria set out (if any) in the Specifications.

Performance Obligations. By the Project Completion Date, Business shall complete the Project, make the total investment pledged for the Project and in accordance with the Award Budget as detailed in Exhibit B and comply with all other performance requirements described in this Contract. The Business shall promptly provide IEDA with written notice of any major changes that would impact the success of the Project.

Performance Obligations. 7.1 The Distributor will use reasonable efforts to ensure that its or the Publisher’s performance will meet or exceed industry standards and practices. Additionally, the Distributor agrees to the following performance standards set out in this Section 7. 7.2 The Distributor shall acquaint the Publisher with the content of this Agreement. The Distributor shall ensure that all Distributor´s obligations under this Agreement will be fulfilled and that the Publisher will not prevent such fulfillment. The Distributor may under no circumstances exclude or limit its liability due to any lack of cooperation from the Publisher. The Distributor shall ensure that the Publisher will provide its cooperation in duly and timely manner so all obligations stipulated herein may be orderly fulfilled.

Performance Obligations. 1. The consortium shall: (a) take all necessary and reasonable measures to ensure that the framework agreement and the specific agreements are carried out in accordance with the terms and conditions of this framework agreement; (b) make appropriate internal arrangements to ensure the efficient implementation of the framework agreement and the specific agreements, and shall ensure that any agreement concluded between the partners to this end does not contradict the provisions of the framework agreement and the specific agreements. Such agreement(s) may, inter alia, specify the organisation of the work to be carried out, decision-making and dispute settlement procedures, and specify provisions concerning access rights within the limits established in this framework agreement; (c) inform the Agency of any event which might affect the implementation of the framework agreement and the specific agreements and the rights of the Agency and of any circumstance affecting the conditions of participation referred to the Financial Regulation and any requirements of the framework agreement, including any change of control; (d) provide all detailed data requested by the Agency for the purposes of the proper administration of the framework agreement and the specific agreements. 2. Each partner shall: (a) ensure that all information to be provided to the Agency is sent via the coordinator, except for those cases foreseen in the framework agreement; (b) make appropriate arrangements for the proper performance of its work identified in work programmes. To this end, the partner shall designate one or more persons who shall manage and monitor its work, ensure that the tasks assigned are correctly performed, and inform the Agency of the name and contact details of the person designated and of any changes to that information; (c) inform the Agency of any event which might affect the implementation of the framework agreement and the specific agreements and the rights of the Agency; (d) provide the Agency and Court of Auditors directly with information requested in the framework of controls and audits, as provided for in Article II.23; (e) ensure that any agreements or contracts entered into between the partner and any subcontractor, or other third party, contain provisions extending the Agency and the Court of Auditors’ right to audit any work carried out under the specific agreements for which costs are claimed from the Agency financial contribution; (f) undertake to ensure that...

Performance Obligations. EPC Services and Cost Responsibilities. Provision and Application of Security.

Performance Obligations. The Supplier must: (a) carry out the Supplier's Activities: (i) in accordance with this Agreement, including the Order Documents; (ii) with all due skill, care and diligence and in a proper, regular and timely manner; (iii) in a manner that encourages the most efficient use of resources and promotes the achievement of any Customer objectives specified in the Order Documents; (iv) to a high standard and in accordance with Best Industry Practice for work of a similar nature to the Supplier's Activities; (v) in a manner that is safe to both people and the environment; (vi) in a manner that minimises any disruption, interference or inconvenience to the Customer or its operations, Personnel or Other Suppliers; (vii) to enable all Deliverables to operate in accordance with this Agreement, and to meet the Acceptance Criteria applicable to them; (viii) to ensure that all timeframes under this Agreement are met, including all Key Milestones and Dates for Delivery; (ix) in accordance with any relevant Statement of Work; (x) in accordance with the Specifications; and (xi) otherwise in accordance with the other requirements of this Agreement; and (b) provide Deliverables to the Customer which: (i) are of high quality and are fit for the purpose for which they are required as detailed in, or reasonably ascertainable from, the Order Documents; (ii) achieve Acceptance; (iii) where applicable, will (on delivery, or at the time of performance of the relevant Supplier’s Activities in relation to the applicable Deliverable(s)): A. have been tested and verified, in accordance with Best Industry Practice, to be free from any Viruses; and B. be compatible and interoperable with those features or characteristics of the Customer Environment described in the Order Documents and will not detrimentally affect the operation or performance of the Customer Environment or any part thereof.

Performance Obligations. Provision of Notice of License Terms to Authorized Users—Licensee shall make reasonable efforts to provide Authorized Users with appropriate notice of the terms and conditions under which access to the Licensed Materials is granted under this Agreement including, in particular, any limitations on access or use of the Licensed Materials as set forth in this Agreement. Protections from Unauthorized Use—Licensee shall make reasonable efforts to inform Authorized Users of the restrictions on used of the Licensed Materials. In the event of any unauthorized use of the Licensed Materials by an Authorized Users, (a) Licensor may terminate such Authorized User’s access to the Licensed Materials, and/or (b) Licensee may terminate such Authorized User’s access to the Licensed Materials upon Licensor’s request.

Performance Obligations. (a) supervise the overall technical implementation of the grant action as laid down in Annex I; (b) administer and distribute the Fusion for Energy financial contribution regarding its allocation between beneficiaries and activities, in accordance with this grant agreement and the decisions taken by the consortium. The coordinator shall ensure that all the appropriate payments are made to the other beneficiaries without unjustified delay; (c) keep the records and financial accounts making it possible to determine at any time what portion of the Fusion for Energy financial contribution has been paid to each beneficiary for the purposes of the action; (d) inform Fusion for Energy of the distribution of the Fusion for Energy financial contribution and the date of transfers to the beneficiaries, when required by this grant agreement or by Fusion for Energy; (e) review the reports and deliverables to verify their consistency with the action tasks before transmitting them to Fusion for Energy; (f) make the appropriate arrangements for providing the financial guarantee or the joint guarantee of the beneficiaries participating in the action, when requested under Art. [I.6.]; and (g) act on behalf of all beneficiaries when signing a request, an acceptance or rejection letter concerning an amendment or termination of this grant agreement. The coordinator may not subcontract the above-mentioned tasks.