PROJECT CO RESPONSIBILITIES AND CONSTRUCTION OBLIGATIONS Clause Samples

PROJECT CO RESPONSIBILITIES AND CONSTRUCTION OBLIGATIONS. ‌ 11.1 General Responsibilities, Standards and Contract Time‌ (a) Project Co shall perform and complete the Work:‌ (i) so as to satisfy and in strict accordance with the Contract Documents; (ii) in accordance with the Works Schedule and in this regard, shall commence the Work no later than the day following Financial Close and, subject to adjustment as provided for in this Project Agreement,‌ (A) complete the Phases by the applicable Phased Occupancy Dates; (B) achieve Substantial Completion by the Scheduled Substantial Completion Date; and (C) achieve Final Completion by the Scheduled Final Completion Date; (iii) in compliance with Applicable Law, including giving all required notices; (iv) in compliance with all Permits, Licences and Approvals and so as to preserve the existence and continued effectiveness of any such Permits, Licences and Approvals; (v) in accordance with Good Industry Practice and to meet the standards followed by professionals, manufacturers, contractors and trades who are experienced in work on health facilities and other public buildings that are comparable to the Facility; (vi) in a timely and professional manner; (vii) with due regard to the health and safety of persons and property; (viii) subject to the other provisions of this Project Agreement, in a manner that will not impair the ability of and that will enable the Contracting Authority and the Contracting Authority Parties to comply with Applicable Law; (ix) in a manner that does not permit any use of any part of the Site that could constitute a nuisance in, at or on the Site, and that does not allow any waste, damage or disfiguration to the Site; (x) subject to the provisions of this Project Agreement and to the extent reasonably practicable, in a manner which will not impair the on-going operation of the Existing Facility; (xi) in accordance with all other terms of this Project Agreement and the other Contract Documents; and (xii) using IO’s online project management software system, (including workflows, processes and filing structures) for project management, document management, document submittal and review processes, request for information processes, change management processes, and other communications between Project Co, Consultant and Contracting Authority, as directed by Contracting Authority at its Sole Discretion from time to time. Project Co shall be responsible for its costs and expenses with respect to the implementation and use of such system. (b) Project Co s...
View SourceView Similar (3)
PROJECT CO RESPONSIBILITIES AND CONSTRUCTION OBLIGATIONS. 36 11.1 General Responsibilities, Standards and Contract Time 36 11.2 General Construction Obligations 37 11.3 Liability Unaffected 39 11.4 Project Co Delay 40 11.5 Permits, Licences and Approvals 40 11.6 Safety 40 11.7 Minimize Disturbance and Work in Existing Facility 42 11.8 Subcontractors and Suppliers 43 11.9 Labour and Products 45 11.10 Documents at the Site 47 11.11 Shop Drawings 47 11.12 Use of the Work 49 11.13 Cutting and Remedial Work 49 11.14 Cleanup 50 11.15 Project Co Attending Meetings 50 11.16 Defective Work 51 11.17 Project Co Design Contingency 51 11.18 Procedure for Addressing Design Issues 53 11.19 Construction by CMH or Other Contractors 56 11.20 Temporary Supports, Structures and Facilities 58 11.21 Protection of Work and Property 59
View SourceView Similar (2)
PROJECT CO RESPONSIBILITIES AND CONSTRUCTION OBLIGATIONS 
View Source

Related to PROJECT CO RESPONSIBILITIES AND CONSTRUCTION OBLIGATIONS

  • BUILDER’S RISK FOR NEW CONSTRUCTION PROJECTS If the project is NEW CONSTRUCTION, then the following provisions apply: (1) The State will require Contractor to purchase and maintain Builder's Risk Insurance. The Contractor shall name the Contractor and the State of Vermont as their interest may occur. Other parties shall be insured as the State may reasonably require. (2) Contractor shall effect and maintain insurance on portions of the work stored off-site, on site and in transit. Boiler & Machinery Insurance may be used in conjunction with this coverage if it is required to meet the testing requirement. (3) Any deductible applicable to loss covered by insurance provided hereunder shall be borne by the Contractor. (4) Except as provided for in (1) above the State and Contractor waive all rights against each other and the Subcontractor, Sub-subcontractors, agents and employees of the other.

  • Design and Construction of the Project Highway 10.1 Obligations prior to commencement of Works (i) Within 20 (twenty) days of the Appointed Date, the Contractor shall: (a) appoint its representative, duly authorised to deal with the Authority in respect of all matters under or arising out of or relating to this Agreement; (b) appoint a design director (the “Design Director”) who will head the Contractor’s design unit and shall be responsible for surveys, investigations, collection of data, and preparation of preliminary and detailed designs; (c) undertake and perform all such acts, deeds and things as may be necessary or required before commencement of Works under and in accordance with this Agreement, the Applicable Laws and Applicable Permits; and (d) make its own arrangements for quarrying of materials needed for the Project Highway under and in accordance with the Applicable Laws and Applicable Permits. (ii) The Authority shall, appoint an engineer (the “Authority’s Engineer”) before the Appointed Date to discharge the functions and duties specified in this Agreement, and shall notify to the Contractor the name, address and the date of appointment of the Authority’s Engineer forthwith. (iii) Within 30 (thirty) days of the Appointed Date, the Contractor shall submit to the Authority and the Authority’s Engineer a programme (the “Programme”) for the Works, developed using networking techniques, for review and consent of the Engineer, giving the following details: (a) Part I : Contractor’s organisation for the Project, the general methods and arrangements for design and construction, environmental management plan, Quality Assurance Plan including design quality plan, traffic management and safety plan covering safety of users and workers during construction (including use of ‘ROBOTS’ for diversion and control of traffic), Contractor’s key personnel and equipment. (b) Part II : Programme for completion of all stages of construction given in Schedule-H and Project Milestones of the Works as specified in Project Completion Schedule set forth in Schedule-J. The Programme shall include: i. the order in which the Contractor intends to carry out the Works, including the anticipated timing of design and stages of Works; ii. the periods for reviews under Clause 10.2; iii. the sequence and timing of inspections and tests specified in this Agreement; and iv. the particulars for the pre-construction reviews and for any other submissions, approvals and consents specified in the Agreement. The Contractor shall submit a revised Programme whenever the previous Programme is inconsistent with the actual progress or with the Contractor’s obligations. (c) Part III : Monthly cash flow forecast. (iv) The Contractor shall compute, on the basis of the Drawings prepared in accordance with Clause 10.2 (iv), and provide to the Authority’s Engineer, the length, area and numbers, as the case may be, in respect of the various items of work specified in Schedule-H and comprising the Scope of the Project. The Parties expressly agree that these details shall form the basis for estimating the interim payments for the Works in accordance with the provisions of Clause 19.3. For the avoidance of doubt, the sum of payments to be computed in respect of all the items of work shall not exceed the Contract Price, as may be adjusted in accordance with the provisions of this Agreement. (v) The Contractor shall appoint a safety consultant (the “Safety Consultant”) to carry out a safety audit at the design stage of the Project Highway in accordance with the Applicable Laws and Good Industry Practice. The Safety Consultant shall be appointed after proposing to the Authority a panel of three (3) names of qualified and experienced firms from which the Authority may choose one (1) to be the Safety Consultant. Provided, however, that if the panel is not acceptable to the Authority and the reasons for the same are furnished to the Contractor, the Contractor shall propose to the Authority a revised panel of three (3) names from the firms empanelled as safety consultants by the [Ministry of Road Transport and Highways] for obtaining the consent of the Authority. The Contractor shall also obtain the consent of the Authority for the key personnel of the Safety Consultant who shall have adequate experience and qualifications in safety audit of the highway projects. The Authority shall, within 15 (fifteen) days of receiving a proposal from the Contractor hereunder, convey its decision, with reasons, to the Contractor, and if no such decision is conveyed within the said period, the Contractor may proceed with engaging of the Safety Consultant. (vi) The safety audit pursuant to Clause 10.1 (v) shall be carried out by the Safety Consultant in respect of all such design details that have a bearing on safety of Users as well as pedestrians and animals involved in or associated with accidents. The recommendations of the Safety Consultant shall be incorporated in the design of the Project Highway and the Contractor shall forward to the Authority’s Engineer a certificate to this effect together with the recommendations of the Safety Consultant. In the event that any works required by the Safety Consultant shall fall beyond the scope of Schedule-B, Schedule-C or Schedule-D, the Contractor shall make a report thereon and seek the instructions of the Authority for Change in Scope. For the avoidance of doubt, the Safety Consultant to be engaged by the Contractor shall be independent of the design and implementation team of the Contractor.

  • BUILDER’S RISK FOR CONSTRUCTION RENOVATION PROJECTS If the project is CONSTRUCTION RENOVATION of an existing structure, and the State has already determined that Contractor will not be obligated to obtain and maintain Builder’s Risk insurance, then the following provisions apply: (1) The State will maintain property insurance upon the construction site and will not require Contractor to purchase and maintain Builder's Risk Insurance upon the entire work at the site. (2) The decision of the State to waive the requirement that the Contractor maintain builder’s risk coverage does not waive Contractor’s liability for damage to the State’s real and personal property. Contractor’s liability for loss to the State’s real and personal property will be limited to the first $100,000 of each and every property loss at the work site provided such loss is covered under the State’s property insurance coverage. If the Contractor elects to meet this obligation by purchase of commercial insurance, this insurance shall name the Contractor and the State of Vermont as Named Insureds and shall include the interests of the Contractor and Subcontractors. Other parties shall be insured as the State may reasonably require. (3) Contractor shall effect and maintain insurance on portions of the work stored off-site, on site and in transit. Boiler & Machinery Insurance may be used in conjunction with this coverage if it is required to meet the testing requirement. The cost of any deductible applicable to loss covered by insurance provided hereunder shall be borne by the Contractor. (4) Except as provided for in 11.2.2 (1)-(3) above the State and Contractor waive all rights against each other and the Subcontractor, Sub-subcontractors, agents and employees of the other.

  • SUPERVISION AND CONSTRUCTION PROCEDURES 4.3.1 The Contractor shall supervise and direct the Work, using his / her best skill and attention. The Contractor shall be solely responsible for all construction means, methods, techniques, sequences and procedures and for coordinating all portions of the Work under the Contract. All aspects of the Project shall be subject to the inspection and approval of the State. Contractor guarantees to repair, replace, re-execute or otherwise correct any defect in workmanship, materials, or the like that fails to conform to the requirements of this Contract or that appears during the progress of the Work or within one year of final acceptance by the State. 4.3.2 The Contractor shall be responsible to the State for the acts and omissions of his / her employees, Subcontractors and their agents and employees, and other persons performing any of the Work under a contract with the Contractor. 4.3.3 The Contractor shall not be relieved from his / her obligations to perform the Work in accordance with the Contract Documents either by the activities or duties of the Architect in his / her administration of the Contract, or by inspections, tests or approvals required or performed under Paragraph 7.7 by persons other than the Contractor. 4.3.4 The Contractor shall acquaint himself (herself / itself) with the limits of the property or right- of-way of the State and shall not trespass on other property. The Contractor shall adequately protect the project, adjacent property and the public, and shall be responsible for any damage or injury due to the Contractor’s act or neglect, and shall save the State harmless in respect thereto. 4.3.5 All work shall be done in such a manner as not to interfere with the State’s operating functions. Contractor and his employees shall familiarize themselves and comply with all rules and regulations applicable to the project. 4.3.6 The Contractor shall keep the premises free from liens arising out of or from the Project. Contractor shall obtain and submit waivers of liens with a request for a progress or final payment.

  • ARCHITECT’S RESPONSIBILITIES § 2.1 The Architect shall provide professional services as set forth in this Agreement. The Architect represents that it is properly licensed in the jurisdiction where the Project is located to provide the services required by this Agreement, or shall cause such services to be performed by appropriately licensed design professionals. § 2.2 The Architect shall perform its services consistent with the professional skill and care ordinarily provided by architects practicing in the same or similar locality under the same or similar circumstances. The Architect shall perform its services as expeditiously as is consistent with such professional skill and care and the orderly progress of the Project. § 2.3 The Architect shall identify a representative authorized to act on behalf of the Architect with respect to the Project. § 2.4 Except with the Owner’s knowledge and consent, the Architect shall not engage in any activity, or accept any employment, interest or contribution that would reasonably appear to compromise the Architect’s professional judgment with respect to this Project. § 2.5 The Architect shall maintain the following insurance until termination of this Agreement. If any of the requirements set forth below are in addition to the types and limits the Architect normally maintains, the Owner shall pay the Architect as set forth in Section 11.9. § 2.5.1 Commercial General Liability with policy limits of not less than « » ($ « » ) for each occurrence and « » ($ « » ) in the aggregate for bodily injury and property damage. § 2.5.2 Automobile Liability covering vehicles owned, and non-owned vehicles used, by the Architect with policy limits of not less than « » ($ « » ) per accident for bodily injury, death of any person, and property damage arising out of the ownership, maintenance and use of those motor vehicles, along with any other statutorily required automobile coverage. § 2.5.3 The Architect may achieve the required limits and coverage for Commercial General Liability and Automobile Liability through a combination of primary and excess or umbrella liability insurance, provided such primary and excess or umbrella liability insurance policies result in the same or greater coverage as the coverages