PROJECT PARTICULARS Sample Clauses

The 'PROJECT PARTICULARS' clause serves to define and document the key details and specific information relevant to a particular project within a contract. This typically includes items such as the project name, location, scope, parties involved, timelines, and any unique requirements or specifications. By clearly outlining these particulars, the clause ensures that all parties have a shared understanding of the project's essential parameters, reducing the risk of misunderstandings and providing a reference point for interpreting other contractual obligations.
PROJECT PARTICULARS. A. THE PROJECT Name: Clock Tower Restoration Nature/Scope of Works: Structural Repair and Maintenance of the Clock Tower Location: The Coach House, Marble Hill House, Richmond Road, Twickenham, TW1 2NL B. THE EMPLOYER: The Historic Buildings and Monuments Commission for England also referred to as English Heritage, ▇ ▇▇▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇, ▇▇▇-▇▇▇ ▇▇▇▇▇▇▇, ▇▇▇▇▇▇ ▇▇▇▇ ▇▇▇ All communications to the Employer should be directed to the Employer’s Representative who will also act as Contract Administrator hereinafter referred to as BTM: ▇▇▇▇▇▇ ▇▇▇▇▇▇ English Heritage 1 Waterhouse Square, ▇▇▇-▇▇▇ ▇▇▇▇▇▇▇, ▇▇▇▇▇▇ ▇▇▇▇ ▇▇▇ Tel: ▇▇▇▇ ▇▇▇ ▇▇▇▇ ▇▇▇▇▇▇.▇▇▇▇▇▇@▇▇▇▇▇▇▇-▇▇▇▇▇▇▇▇.▇▇▇.▇▇
View Source
PROJECT PARTICULARS. THE PROJECT - Name: Upgrade of play area undersurfacing and play equipment - Location: The Dove Park, Whitethorns Park, Castle Meadow and Hopton Grove Park. - Length of contract: To be confirmed by Contractor.
View Source
PROJECT PARTICULARS. 1 Construction of ▇▇▇▇▇▇▇▇▇ Drive and the roundabout is ongoing. Coordinate with PEI TIE's Contractor for that project as needed. 1.2
View Source
PROJECT PARTICULARS. Project title:
View Source
PROJECT PARTICULARS. Contract for (Consultancy Discipline): [Enter Consultancy Service] Using the: Standard Conditions of Engagement for Consultancy Services (Technical COE1) Title (as Contract Notice): Location:
View Source
PROJECT PARTICULARS. Contract for (Consultancy Discipline): Applicant entry [Enter Consultancy Service] Using the: Standard Conditions of Engagement for Consultancy Services (Technical COE1) Title (as Contract Notice): Applicant entry Location: Applicant entry Legal Name of Firm: Applicant entry Address (Registered head Office): Applicant entry Address(es) of Other Relevant Office(s): Applicant entry Date Business Commenced Trading: Applicant entry Company Email: Applicant entry Company Telephone: Applicant entry Name and address of parent company (if applicable): Applicant entry Parent company interest in applicant (e.g. wholly owned by single parent company: Applicant entry Name of Authorised Representative: Applicant entry Address (if different from above): Applicant entry Email Address: Applicant entry Telephone: Applicant entry Nature of Applicant (e.g. partnership, sole trader, private limited company, public limited company, Joint Venture, subsidiary company etc.) Nature of Applicant: Applicant entry Where applicable, Applicant should enter name and address all Consortium/Joint Venture company members: Name and Address 1: Applicant entry Name and Address 2: Applicant entry Name and Address 3: Applicant entry Name and Address 4: Applicant entry Applicant should enter name and address all of sub-consultants (if any) to be used to fulfil any specialist skills requirements identified in the Contract Notice: Name and Address 1: Applicant entry Name and Address 2: Applicant entry Name and Address 3: Applicant entry This Suitability Assessment Declaration comprises two separate parts. DoE-QC1, This document by the Contracting Authority and uploaded to eTenders to provide the information for Applicants about the submission requirements and the Qualification Criteria that will be applied to determine the suitability of Applicants to perform the services. Suitability Assessment Questionnaire Part 2, is completed by Applicants, having been uploaded to eTenders by the Contracting Authority along with DoE-QC1. The Applicant Declaration included in SAQ Part 2 – Section 3, must be completed and signed by the Applicant. Applicants must also complete the Applicant’s Self Declaration re Article 57 (QC1, Appendix A, Capital Works Management Framework website - ▇▇▇▇▇://▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇▇.▇▇▇.▇▇/wp-content/uploads/Appendix-A-QC1-and-QC2-09-02-2022.docx) and provide any evidence or information required by this Question...
View Source
PROJECT PARTICULARS. THE PROPERTY THE PROJECT PROFESSIONAL CONSULTANTS [PROFESSIONAL CONSULTANT], Employer’s Agent. [[PROFESSIONAL CONSULTANT], Principal Designer.] [PROFESSIONAL CONSULTANT], Quantity Surveyor. [PROFESSIONAL CONSULTANT], [ROLE]. [PROFESSIONAL CONSULTANT], [ROLE]. KEY PERSONNEL [KEY PERSON], [ROLE]. [KEY PERSON], [ROLE]. [KEY PERSON], [ROLE]. CONTRACT PARTICULARS Date for Completion: [DATE OR DATES FOR SECTIONAL COMPLETION] Liquidated damages for delay: £[SUM] per [week or pro rata for part thereof] OR £[RATE FOR EACH SECTION] per [week or pro rata for part thereof] Rectification Period: [12] months from the date of practical completion of the Works Insurance of the Works - Insurance Options [Insurance Option A applies OR Insurance Option B applies OR Insurance Option C applies] PCSA Retention Percentage [%]: Pre-Construction Services [ATTACHED] Personnel and resources [The parties have attached and initialled a schedule of personnel and resources required. OR [RESOURCE OR PERSONNEL] [NUMBER] [RESOURCE OR PERSONNEL] [NUMBER] [RESOURCE OR PERSONNEL] [NUMBER]
View Source

Related to PROJECT PARTICULARS

  • Project Documentation All documentation provided to the City other than Project drawings shall be furnished on a Microsoft compatible compact disc.

  • Project Documents In addition to any other pertinent and necessary Project documents, the following documents shall be used in the development of the Project: A. TxDOT 2011 Texas Manual of Uniform Traffic Control Devices for Streets and Highways, including latest revisions B. Texas Department of Transportation's Standard Specifications for Construction of Highways, Streets, and Bridges, 2014 or 2024, as applicable and as amended

  • Material Project Documents (a) The Company shall at all times (i) perform and observe all of the covenants under the Material Project Documents to which it is a party and take reasonable actions to enforce all of its rights thereunder, other than to the extent the same could not reasonably be expected to have a Material Adverse Effect, (ii) subject to the provisions of clause (b) of this Section 9.8, maintain the System Leases (other than Leases constituting System Leases only pursuant to clause (5) of the definition thereof) in full force and effect, and (iii) maintain the Leases (other than the System Leases referred to in the foregoing clause (ii) of this Section 9.8(a)) to which it or any of its Subsidiaries is a party in full force and effect, except to the extent the same could not reasonably be expected to have a Material Adverse Effect. (b) If the term of a Lease with the Company or one of its Subsidiaries expires and the Qualified Lessee under such Lease has either ceased operating the related assets or has ceased paying rent as required under the applicable Lease, the Company shall, or shall cause a Subsidiary, as applicable, to enter into a supplement or a new Lease with respect to the related leasehold assets with a Qualified Lessee that provides for rent that, when combined with all other expected revenue, will, in the reasonable judgment of the Company, as of the commencement date of such supplement or new Lease, generate sufficient revenue to satisfy the requirements of Section 9.9 and will not otherwise result in a materially worse position for the Company as compared to the terms of the applicable expired Lease. Each such new Lease shall have a term of at least five years. Notwithstanding the foregoing, if (i) such expired Lease relates to transmission and/or distribution assets that are not generating significant revenue, (ii) the failure to renew such Lease would not constitute a Material Adverse Effect and (iii) the Company reasonably believes it will generate sufficient revenue and hold sufficient assets (without giving effect to the leasehold assets with respect to such Lease) to satisfy the requirements of Section 9.9, then this Section 9.8(b) will not require a supplement or new lease with respect to such leasehold assets.

  • Project Plans The Contractor: must carry out the Contractor's Activities in accordance with, and otherwise implement, the Project Plans; and for the purposes of subparagraph (i), must: prepare Project Plans based, where applicable, on the draft Project Plans lodged by the Contractor in its tender for the Contractor's Activities, and otherwise in accordance with the requirements of the Contract and submit them to the Contract Administrator so as to ensure that there is no delay or disruption to the Contractor's Activities and in any event no later than the number of days specified in the Contract Particulars after the Award Date for each Project Plan; not commence any of the Contractor's Activities to which any Project Plan applies, unless the Contract Administrator has had the number of days specified in the Contract Particulars for each Project Plan to review the Project Plan and has not rejected the Project Plan; if any Project Plan is rejected, submit an amended Project Plan to the Contract Administrator; in any event, finalise each Project Plan so as to ensure that there is no delay or disruption to the Contractor's Activities and in any event in accordance with the requirements of the Contract to the satisfaction of the Contract Administrator; after each Project Plan has been finalised: regularly review, update and amend each Project Plan in accordance with the process set out in each Project Plan (and otherwise at least on each anniversary of the Award Date); update or amend a Project Plan on request of the Contract Administrator; and continue to correct any defects in or omissions from a Project Plan (whether identified by the Contract Administrator or the Contractor), and submit an updated or amended Project Plan to the Contract Administrator, after which: the Contractor must continue to comply with the requirements of the then current Project Plan until the process in subparagraph (ii) has been completed in respect of the updated or amended Project Plan; and subsubparagraphs B - E will apply (to the extent applicable); and document and maintain detailed records of all: reviews, updates, amendments and submissions of each Project Plan; audits or other monitoring of each Project Plan; and training and awareness programs and communications provided to Contractor and subcontractor personnel in respect of each Project Plan (including each updated or amended Project Plan). The Contractor will not be relieved from compliance with any of its obligations under the Contract or otherwise at law or in equity as a result of: the implementation of, and compliance with, the requirements of any Project Plan; any direction by the Contract Administrator concerning a Project Plan or the Contractor's compliance or non-compliance with a Project Plan; any audit or other monitoring by the Contract Administrator or anyone else acting on behalf of the Commonwealth of the Contractor's compliance with a Project Plan; or any failure by the Contract Administrator, or anyone else acting on behalf of the Commonwealth, to detect any defect in or omission from a Project Plan including where any such failure arises from any negligence on the part of the Contract Administrator or other person.

  • Project Plan Development of Project Plan Upon the Authorized User’s request, the Contractor must develop a Project Plan. This Project Plan may include Implementation personnel, installation timeframes, escalation procedures and an acceptance plan as appropriate for the Services requested. Specific requirements of the plan will be defined in the RFQ. In response to the RFQ, the Contractor must agree to furnish all labor and supervision necessary to successfully perform Services procured from this Lot. Project Plan Document The Contractor will provide to the Authorized User, a Project Plan that may contain the following items: • Name of the Project Manager, Contact Phone Numbers and E-Mail Address; • Names of the Project Team Members, Contact Phone Numbers and E-Mail Address; • A list of Implementation milestones based on the Authorized User’s desired installation date; • A list of responsibilities of the Authorized User during system Implementation; • A list of designated Contractor Authorized Personnel; • Escalation procedures including management personnel contact numbers; • Full and complete documentation of all Implementation work; • Samples of knowledge transfer documentation; and • When applicable, a list of all materials and supplies required to complete the Implementation described in the RFQ. Materials and Supplies Required to Complete Implementation In the event that there are items required to complete an Implementation, the Contractor may request the items be added to its Contract if the items meet the scope of the Contract. Negotiation of Final Project Plan If the Authorized User chooses to require a full Project Plan, the State further reserves the right for Authorized Users to negotiate the final Project Plan with the apparent RFQ awardee. Such negotiation must not substantively change the scope of the RFQ plan, but can alter timeframes or other incidental factors of the final Project Plan. The Authorized User will provide the Contractor a minimum of five (5) business days’ notice of the final negotiation date. The Authorized User reserves the right to move to the next responsible and responsive bidder if Contractor negotiations are unsuccessful.