As-Built Drawings Within thirty (30) Days of the successful completion of the Acceptance Test, Seller shall provide for Company review a set of the proposed as‑built drawings for the Company-Owned Interconnection Facilities constructed by Seller (and/or its Contractors). Within thirty (30) Days of Company's receipt of the proposed as‑built drawings, Company shall provide Seller with either (i) its comments on the proposed as‑built drawings or (ii) notice of acceptance of the proposed as‑built drawings as final as‑built drawings. If Company provides comments on the proposed as‑built drawings, Seller shall incorporate such comments into a final set of as‑built drawings and provide such final as‑built drawings to Company within twenty (20) Days of Seller's receipt of Company's comments.
Approved Working Drawings The Final Working Drawings shall be approved by Landlord (the “Approved Working Drawings”) prior to the commencement of construction of the Premises by Tenant. After approval by Landlord of the Final Working Drawings, Tenant may submit the same to the appropriate municipal authorities for all applicable building permits. Tenant hereby agrees that neither Landlord nor Landlord’s consultants shall be responsible for obtaining any building permit or certificate of occupancy for the Premises and that obtaining the same shall be Tenant’s responsibility; provided, however, that Landlord shall cooperate with Tenant in executing permit applications and performing other ministerial acts reasonably necessary to enable Tenant to obtain any such permit or certificate of occupancy. No changes, modifications or alterations in the Approved Working Drawings may be made without the prior written consent of Landlord, which consent may not be unreasonably withheld.
Construction Drawings After approving the Additional Programming Information, Landlord shall cause the Architect and the Engineers to prepare and deliver to Tenant Construction Drawings that conform to the approved Space Plan and the approved Additional Programming Information. Such preparation and delivery shall occur within 15 business days after the later of Landlord’s approval of the Additional Programming Information or the mutual execution and delivery of this Agreement. Tenant shall approve or disapprove the Construction Drawings by notice to Landlord. If Tenant disapproves the Construction Drawings, Tenant’s notice of disapproval shall specify any revisions Tenant desires in the Construction Drawings. After receiving such notice of disapproval, Landlord shall cause the Architect and/or the Engineers to revise the Construction Drawings, taking into account the reasons for Tenant’s disapproval (provided, however, that Landlord shall not be required to cause the Architect or the Engineers to make any revision to the Construction Drawings that is inconsistent with the Landlord Requirements or that Landlord otherwise reasonably disapproves), and resubmit the Construction Drawings to Tenant for its approval. Such revision and resubmission shall occur within five (5) business days after the later of Landlord’s receipt of Tenant’s notice of disapproval or the mutual execution and delivery of this Agreement if such revision is not material, and within such longer period of time as may be reasonably necessary (but not more than 15 business days after the later of such receipt or such mutual execution and delivery) if such revision is material. Such procedure shall be repeated as necessary until Tenant has approved the Construction Drawings. The Construction Drawings approved by Landlord and Tenant are referred to in this Work Letter as the “Approved Construction Drawings”.
Agreement to Repay Letter of Credit Drawings (a) The Borrower agrees to reimburse each Issuing Lender, by making payment to the Administrative Agent in immediately available funds at the Payment Office, for any payment or disbursement made by such Issuing Lender under any Letter of Credit issued by it (each such amount, so paid until reimbursed by the Borrower, an “Unpaid Drawing”), by making payment in Dollars (in the case of all Dollar Denominated Letters of Credit), Euros (in the case of Euro Denominated Letters of Credit) or Sterling (in the case of Sterling Denominated Letters of Credit) not later than one Business Day following receipt by the Borrower of notice of such payment or disbursement (provided that no such notice shall be required to be given if a Default or an Event of Default under Section 11.05 shall have occurred and be continuing, in which case the Unpaid Drawing shall be due and payable immediately without presentment, demand, protest or notice of any kind (all of which are hereby waived by the Borrower)), with interest on the amount so paid or disbursed by such Issuing Lender, to the extent not reimbursed prior to 1:00 P.M. (New York City time) on the date of such payment or disbursement, from and including the date paid or disbursed to but excluding the date such Issuing Lender was reimbursed by the Borrower therefor at a rate per annum equal to the Base Rate as in effect from time to time plus the Applicable Margin as in effect from time to time for Revolving Loans that are maintained as Base Rate Loans; provided, however, to the extent such amounts are not reimbursed prior to 1:00 P.M. (New York time) on the third Business Day following notice to the Borrower by the Administrative Agent or the respective Issuing Lender of such payment or disbursement, interest shall thereafter accrue on the amounts so paid or disbursed by such Issuing Lender (and until reimbursed by the respective Account Party) at a rate per annum which shall be (x) in the case of Dollar Denominated Letters of Credit, Sterling Denominated Letters of Credit, the Base Rate in effect from time to time plus the Applicable Margin for Revolving Loans in each case maintained as Base Rate Loans, as in effect from time to time plus 2% and (y) in the case of Euro Denominated Letters of Credit, the Overnight Euro Rate in effect from time to time plus the Applicable Margin for Euro Denominated Loans as in effect from time to time plus any Mandatory Costs plus 2%, in each such case, with interest to be payable on demand, provided further, that it is understood and agreed, however, that the notices referred to above in this clause (a) and in the immediately preceding proviso shall not be required to be given if a Default or an Event of Default under Section 11.05 shall have occurred and be continuing (in which case the Unpaid Drawings shall be due and payable immediately without presentment, demand, protest or notice of any kind (all of which are hereby waived by each Credit Party) and shall bear interest at the rate provided in the foregoing proviso on and after the third Business Day following the respective Drawing). The respective Issuing Lender shall give the Borrower prompt notice of each Drawing under any Letter of Credit, provided that the failure to give, or any delay in giving, any such notice shall in no way affect, impair or diminish the Borrower’s obligations under this Agreement.
(b) The obligations of the Borrower under this Section 3.05 to reimburse each Issuing Lender with respect to drafts, demands and other presentations for payment under Letters of Credit issued by it (each, a “Drawing”) (including, in each case, interest thereon) shall be absolute and unconditional under any and all circumstances and irrespective of any setoff, counterclaim or defense to payment which the Borrower or any Subsidiary of the Borrower may have or have had against any Lender (including in its capacity as an Issuing Lender or as a Participant), including, without limitation, any defense based upon the failure of any drawing under a Letter of Credit to conform to the terms of the Letter of Credit or any nonapplication or misapplication by the beneficiary of the proceeds of such Drawing; provided, however, that the Borrower shall not be obligated to reimburse any Issuing Lender for any wrongful payment made by such Issuing Lender under a Letter of Credit issued by it as a result of acts or omissions constituting willful misconduct or gross negligence on the part of such Issuing Lender (as determined by a court of competent jurisdiction in a final and non-appealable decision).
Construction Contract; Cost Budget Prior to execution of a construction contract, Tenant shall submit a copy of the proposed contract with the Contractor for the construction of the Tenant Improvements, including the general conditions with Contractor (the “Contract”) to Landlord for its approval, which approval shall not be unreasonably withheld, conditioned or delayed. Following execution of the Contract and prior to commencement of construction, Tenant shall provide Landlord with a fully executed copy of the Contract for Landlord’s records. Prior to the commencement of the construction of the Tenant Improvements, and after Tenant has accepted all bids and proposals for the Tenant Improvements, Tenant shall provide Landlord with a detailed breakdown, by trade, for all of Tenant’s Agents, of the final estimated costs to be incurred or which have been incurred in connection with the design and construction of the Tenant Improvements to be performed by or at the direction of Tenant or the Contractor (the “Construction Budget”), which costs shall include, but not be limited to, the costs of the Architect’s and Engineers’ fees and the Landlord Coordination Fee. The amount, if any, by which the total costs set forth in the Construction Budget exceed the amount of the Tenant Improvement Allowance is referred to herein as the “Over Allowance Amount”. In the event that an Over-Allowance Amount exists, then prior to the commencement of construction of the Tenant Improvements, Tenant shall supply Landlord with cash in an amount equal to the Over-Allowance Amount. The Over-Allowance Amount shall be disbursed by Landlord prior to the disbursement of any of the then remaining portion of the Tenant Improvement Allowance, and such disbursement shall be pursuant to the same procedure as the Tenant Improvement Allowance. In the event that, after the total costs set forth in the Construction Budget have been delivered by Tenant to Landlord, the costs relating to the design and construction of the Tenant Improvements shall change, any additional costs for such design and construction in excess of the total costs set forth in the Construction Budget shall be added to the Over-Allowance Amount and the total costs set forth in the Construction Budget, and such additional costs shall be paid by Tenant to Landlord immediately as an addition to the Over-Allowance Amount or at Landlord’s option, Tenant shall make payments for such additional costs out of its own funds, but Tenant shall continue to provide Landlord with the documents described in items (i), (ii), (iii) and (iv) of Section 2.2.2.1 of this Tenant Work Letter, above, for Landlord’s approval, prior to Tenant paying such costs. All Tenant Improvements paid for by the Over-Allowance Amount shall be deemed Landlord’s property under the terms of the Lease.